CALIFORNIA LEGISLATURE 20192020 REGULAR SESSION Assembly Bill No. 1475Introduced by Assembly Member Bauer-Kahan(Coauthor: Senator Glazer)February 22, 2019 An act to amend Section 6971 of the Public Contract Code, relating to public contracts. LEGISLATIVE COUNSEL'S DIGESTAB 1475, as introduced, Bauer-Kahan. Construction Manager/General Contractor method: transportation planning agencies: bridge over Bollinger Canyon.Existing law authorizes regional transportation agencies, as defined, to use the Construction Manager/General Contractor project delivery method, as specified, to design and construct projects, including expressways that are not on the state highway system, and specified bridges, railroad grade separations, and a commuter rail project if there is an evaluation of the traditional design-bid-build method of construction and of the Construction Manager/General Contractor method and the board of the regional transportation agency adopts the procurement strategy in a public meeting. Existing law defines the term project for these purposes. Existing law requires specified information submitted under the Construction Manager/General Contractor method to be verified under oath.This bill would authorize the use of the Construction Manager/General Contractor method for the construction of the bridge over Bollinger Canyon to extend the Iron Horse Trail. For the purposes only of this authorization, the bill would include the County of Contra Costa and the Contra Costa Transportation Authority within the definition of a regional transportation agency. By expanding the scope of the crime of perjury, the bill would impose a state-mandated local program.This bill would make legislative findings and declarations as to the necessity of a special statute for the County of Contra Costa.The California Constitution requires the state to reimburse local agencies and school districts for certain costs mandated by the state. Statutory provisions establish procedures for making that reimbursement.This bill would provide that no reimbursement is required by this act for a specified reason.Digest Key Vote: MAJORITY Appropriation: NO Fiscal Committee: YES Local Program: YES Bill TextThe people of the State of California do enact as follows:SECTION 1. Section 6971 of the Public Contract Code is amended to read:6971. (a) The Legislature finds and declares that the the following:(1) The County of Riverside should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of the railroad grade separations and bridge rehabilitations and replacements specified in subparagraph (C) of paragraph (4) of subdivision (b) using Construction Manager/General Contractor authority. The passage of the Road Repair and Accountability Act of 2017 (Chapter 5 of the Statutes of 2017) provides additional transportation revenue to help close the significant funding shortfalls and address the substantial backlog of infrastructure projects that are in need of repair. The geography, topography, and location of these railroad grade separations and bridge rehabilitations and replacements projects present many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.(2) The County of Contra Costa should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of a bridge over Bollinger Canyon to extend the Iron Horse Trail using the Construction Manager/General Contractor authority. The geography, topography, and location of the bridge presents many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.(b) For purposes of this chapter, the following definitions apply:(1) Construction manager means a partnership, corporation, or other legal entity that is able to provide appropriately licensed contracting and engineering services as needed pursuant to a Construction Manager/General Contractor method contract.(2) Construction Manager/General Contractor method means a project delivery method in which a construction manager is procured to provide preconstruction services during the design phase of the project and construction services during the construction phase of the project. The contract for construction services may be entered into at the same time as the contract for preconstruction services, or at a later time. The execution of the design and the construction of the project may be in sequential phases or concurrent phases.(3) Preconstruction services means advice during the design phase, including, but not limited to, scheduling, pricing, and phasing to assist the regional transportation agency to design a more constructible project.(4) Project means any of the following:(A) The construction of an expressway that is not on the state highway system.(B) The construction of the following bridges that are not on the state highway system:(i) Yerba Buena Island (YBI) West Side Bridges Seismic Retrofit Project.(ii) Yankee Jims Road Bridge Project in the County of Placer (Replacement/Rehabilitation).(iii) Bridge over Bollinger Canyon to extend the Iron Horse Trail.(C) The construction of railroad grade separations and bridge rehabilitations and replacements in the County of Riverside, as specified in Item 2660-110-0042 of Section 2.00 of the Budget Act of 2016, as amended by Chapter 7 of the Statutes of 2017.(D) The construction, alteration, repair, rehabilitation, or improvement of the Golden Gate Bridge, as defined in Section 27502 of the Streets and Highways Code.(E) A Metrolink commuter rail project.(5) Regional transportation agency means any of the following:(A) A transportation planning agency described in Section 29532 or 29532.1 of the Government Code.(B) A county transportation commission established under Section 130050, 130050.1, or 130050.2 of the Public Utilities Code.(C) Any other local or regional transportation entity that is designated by statute as a regional transportation agency.(D) A joint exercise of powers authority established pursuant to Chapter 5 (commencing with Section 6500) of Division 7 of Title 1 of the Government Code, with the consent of a transportation planning agency or a county transportation commission for the jurisdiction in which the transportation project will be developed.(E) A local transportation authority created or designated pursuant to Division 12.5 (commencing with Section 131000) or Division 19 (commencing with Section 180000) of the Public Utilities Code.(F) The Santa Clara Valley Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.(G) The County of Placer.(H) The County of Riverside.(I) The Golden Gate Bridge, Highway and Transportation District established pursuant to Chapter 18 (commencing with Section 27500) of Part 3 of Division 16 of the Streets and Highways Code Code.(J) The Contra Costa Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.(K) The County of Contra Costa.(c) Nothing in this section shall extend any other authority to the County of Riverside Riverside, the County of Contra Costa, or the Golden Gate Bridge, Highway and Transportation District, as a transportation planning agency under any other law.SEC. 2. The Legislature finds and declares that a special statute is necessary and that a general statute cannot be made applicable within the meaning of Section 16 of Article IV of the California Constitution because of the unique circumstances regarding bridge transportation construction projects in the County of Contra Costa.SEC. 3. No reimbursement is required by this act pursuant to Section 6 of Article XIIIB of the California Constitution because the only costs that may be incurred by a local agency or school district will be incurred because this act creates a new crime or infraction, eliminates a crime or infraction, or changes the penalty for a crime or infraction, within the meaning of Section 17556 of the Government Code, or changes the definition of a crime within the meaning of Section 6 of Article XIIIB of the California Constitution.
CALIFORNIA LEGISLATURE 20192020 REGULAR SESSION Assembly Bill No. 1475Introduced by Assembly Member Bauer-Kahan(Coauthor: Senator Glazer)February 22, 2019 An act to amend Section 6971 of the Public Contract Code, relating to public contracts. LEGISLATIVE COUNSEL'S DIGESTAB 1475, as introduced, Bauer-Kahan. Construction Manager/General Contractor method: transportation planning agencies: bridge over Bollinger Canyon.Existing law authorizes regional transportation agencies, as defined, to use the Construction Manager/General Contractor project delivery method, as specified, to design and construct projects, including expressways that are not on the state highway system, and specified bridges, railroad grade separations, and a commuter rail project if there is an evaluation of the traditional design-bid-build method of construction and of the Construction Manager/General Contractor method and the board of the regional transportation agency adopts the procurement strategy in a public meeting. Existing law defines the term project for these purposes. Existing law requires specified information submitted under the Construction Manager/General Contractor method to be verified under oath.This bill would authorize the use of the Construction Manager/General Contractor method for the construction of the bridge over Bollinger Canyon to extend the Iron Horse Trail. For the purposes only of this authorization, the bill would include the County of Contra Costa and the Contra Costa Transportation Authority within the definition of a regional transportation agency. By expanding the scope of the crime of perjury, the bill would impose a state-mandated local program.This bill would make legislative findings and declarations as to the necessity of a special statute for the County of Contra Costa.The California Constitution requires the state to reimburse local agencies and school districts for certain costs mandated by the state. Statutory provisions establish procedures for making that reimbursement.This bill would provide that no reimbursement is required by this act for a specified reason.Digest Key Vote: MAJORITY Appropriation: NO Fiscal Committee: YES Local Program: YES
CALIFORNIA LEGISLATURE 20192020 REGULAR SESSION
Assembly Bill No. 1475
Introduced by Assembly Member Bauer-Kahan(Coauthor: Senator Glazer)February 22, 2019
Introduced by Assembly Member Bauer-Kahan(Coauthor: Senator Glazer)
February 22, 2019
An act to amend Section 6971 of the Public Contract Code, relating to public contracts.
LEGISLATIVE COUNSEL'S DIGEST
## LEGISLATIVE COUNSEL'S DIGEST
AB 1475, as introduced, Bauer-Kahan. Construction Manager/General Contractor method: transportation planning agencies: bridge over Bollinger Canyon.
Existing law authorizes regional transportation agencies, as defined, to use the Construction Manager/General Contractor project delivery method, as specified, to design and construct projects, including expressways that are not on the state highway system, and specified bridges, railroad grade separations, and a commuter rail project if there is an evaluation of the traditional design-bid-build method of construction and of the Construction Manager/General Contractor method and the board of the regional transportation agency adopts the procurement strategy in a public meeting. Existing law defines the term project for these purposes. Existing law requires specified information submitted under the Construction Manager/General Contractor method to be verified under oath.This bill would authorize the use of the Construction Manager/General Contractor method for the construction of the bridge over Bollinger Canyon to extend the Iron Horse Trail. For the purposes only of this authorization, the bill would include the County of Contra Costa and the Contra Costa Transportation Authority within the definition of a regional transportation agency. By expanding the scope of the crime of perjury, the bill would impose a state-mandated local program.This bill would make legislative findings and declarations as to the necessity of a special statute for the County of Contra Costa.The California Constitution requires the state to reimburse local agencies and school districts for certain costs mandated by the state. Statutory provisions establish procedures for making that reimbursement.This bill would provide that no reimbursement is required by this act for a specified reason.
Existing law authorizes regional transportation agencies, as defined, to use the Construction Manager/General Contractor project delivery method, as specified, to design and construct projects, including expressways that are not on the state highway system, and specified bridges, railroad grade separations, and a commuter rail project if there is an evaluation of the traditional design-bid-build method of construction and of the Construction Manager/General Contractor method and the board of the regional transportation agency adopts the procurement strategy in a public meeting. Existing law defines the term project for these purposes. Existing law requires specified information submitted under the Construction Manager/General Contractor method to be verified under oath.
This bill would authorize the use of the Construction Manager/General Contractor method for the construction of the bridge over Bollinger Canyon to extend the Iron Horse Trail. For the purposes only of this authorization, the bill would include the County of Contra Costa and the Contra Costa Transportation Authority within the definition of a regional transportation agency. By expanding the scope of the crime of perjury, the bill would impose a state-mandated local program.
This bill would make legislative findings and declarations as to the necessity of a special statute for the County of Contra Costa.
The California Constitution requires the state to reimburse local agencies and school districts for certain costs mandated by the state. Statutory provisions establish procedures for making that reimbursement.
This bill would provide that no reimbursement is required by this act for a specified reason.
## Digest Key
## Bill Text
The people of the State of California do enact as follows:SECTION 1. Section 6971 of the Public Contract Code is amended to read:6971. (a) The Legislature finds and declares that the the following:(1) The County of Riverside should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of the railroad grade separations and bridge rehabilitations and replacements specified in subparagraph (C) of paragraph (4) of subdivision (b) using Construction Manager/General Contractor authority. The passage of the Road Repair and Accountability Act of 2017 (Chapter 5 of the Statutes of 2017) provides additional transportation revenue to help close the significant funding shortfalls and address the substantial backlog of infrastructure projects that are in need of repair. The geography, topography, and location of these railroad grade separations and bridge rehabilitations and replacements projects present many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.(2) The County of Contra Costa should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of a bridge over Bollinger Canyon to extend the Iron Horse Trail using the Construction Manager/General Contractor authority. The geography, topography, and location of the bridge presents many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.(b) For purposes of this chapter, the following definitions apply:(1) Construction manager means a partnership, corporation, or other legal entity that is able to provide appropriately licensed contracting and engineering services as needed pursuant to a Construction Manager/General Contractor method contract.(2) Construction Manager/General Contractor method means a project delivery method in which a construction manager is procured to provide preconstruction services during the design phase of the project and construction services during the construction phase of the project. The contract for construction services may be entered into at the same time as the contract for preconstruction services, or at a later time. The execution of the design and the construction of the project may be in sequential phases or concurrent phases.(3) Preconstruction services means advice during the design phase, including, but not limited to, scheduling, pricing, and phasing to assist the regional transportation agency to design a more constructible project.(4) Project means any of the following:(A) The construction of an expressway that is not on the state highway system.(B) The construction of the following bridges that are not on the state highway system:(i) Yerba Buena Island (YBI) West Side Bridges Seismic Retrofit Project.(ii) Yankee Jims Road Bridge Project in the County of Placer (Replacement/Rehabilitation).(iii) Bridge over Bollinger Canyon to extend the Iron Horse Trail.(C) The construction of railroad grade separations and bridge rehabilitations and replacements in the County of Riverside, as specified in Item 2660-110-0042 of Section 2.00 of the Budget Act of 2016, as amended by Chapter 7 of the Statutes of 2017.(D) The construction, alteration, repair, rehabilitation, or improvement of the Golden Gate Bridge, as defined in Section 27502 of the Streets and Highways Code.(E) A Metrolink commuter rail project.(5) Regional transportation agency means any of the following:(A) A transportation planning agency described in Section 29532 or 29532.1 of the Government Code.(B) A county transportation commission established under Section 130050, 130050.1, or 130050.2 of the Public Utilities Code.(C) Any other local or regional transportation entity that is designated by statute as a regional transportation agency.(D) A joint exercise of powers authority established pursuant to Chapter 5 (commencing with Section 6500) of Division 7 of Title 1 of the Government Code, with the consent of a transportation planning agency or a county transportation commission for the jurisdiction in which the transportation project will be developed.(E) A local transportation authority created or designated pursuant to Division 12.5 (commencing with Section 131000) or Division 19 (commencing with Section 180000) of the Public Utilities Code.(F) The Santa Clara Valley Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.(G) The County of Placer.(H) The County of Riverside.(I) The Golden Gate Bridge, Highway and Transportation District established pursuant to Chapter 18 (commencing with Section 27500) of Part 3 of Division 16 of the Streets and Highways Code Code.(J) The Contra Costa Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.(K) The County of Contra Costa.(c) Nothing in this section shall extend any other authority to the County of Riverside Riverside, the County of Contra Costa, or the Golden Gate Bridge, Highway and Transportation District, as a transportation planning agency under any other law.SEC. 2. The Legislature finds and declares that a special statute is necessary and that a general statute cannot be made applicable within the meaning of Section 16 of Article IV of the California Constitution because of the unique circumstances regarding bridge transportation construction projects in the County of Contra Costa.SEC. 3. No reimbursement is required by this act pursuant to Section 6 of Article XIIIB of the California Constitution because the only costs that may be incurred by a local agency or school district will be incurred because this act creates a new crime or infraction, eliminates a crime or infraction, or changes the penalty for a crime or infraction, within the meaning of Section 17556 of the Government Code, or changes the definition of a crime within the meaning of Section 6 of Article XIIIB of the California Constitution.
The people of the State of California do enact as follows:
## The people of the State of California do enact as follows:
SECTION 1. Section 6971 of the Public Contract Code is amended to read:6971. (a) The Legislature finds and declares that the the following:(1) The County of Riverside should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of the railroad grade separations and bridge rehabilitations and replacements specified in subparagraph (C) of paragraph (4) of subdivision (b) using Construction Manager/General Contractor authority. The passage of the Road Repair and Accountability Act of 2017 (Chapter 5 of the Statutes of 2017) provides additional transportation revenue to help close the significant funding shortfalls and address the substantial backlog of infrastructure projects that are in need of repair. The geography, topography, and location of these railroad grade separations and bridge rehabilitations and replacements projects present many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.(2) The County of Contra Costa should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of a bridge over Bollinger Canyon to extend the Iron Horse Trail using the Construction Manager/General Contractor authority. The geography, topography, and location of the bridge presents many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.(b) For purposes of this chapter, the following definitions apply:(1) Construction manager means a partnership, corporation, or other legal entity that is able to provide appropriately licensed contracting and engineering services as needed pursuant to a Construction Manager/General Contractor method contract.(2) Construction Manager/General Contractor method means a project delivery method in which a construction manager is procured to provide preconstruction services during the design phase of the project and construction services during the construction phase of the project. The contract for construction services may be entered into at the same time as the contract for preconstruction services, or at a later time. The execution of the design and the construction of the project may be in sequential phases or concurrent phases.(3) Preconstruction services means advice during the design phase, including, but not limited to, scheduling, pricing, and phasing to assist the regional transportation agency to design a more constructible project.(4) Project means any of the following:(A) The construction of an expressway that is not on the state highway system.(B) The construction of the following bridges that are not on the state highway system:(i) Yerba Buena Island (YBI) West Side Bridges Seismic Retrofit Project.(ii) Yankee Jims Road Bridge Project in the County of Placer (Replacement/Rehabilitation).(iii) Bridge over Bollinger Canyon to extend the Iron Horse Trail.(C) The construction of railroad grade separations and bridge rehabilitations and replacements in the County of Riverside, as specified in Item 2660-110-0042 of Section 2.00 of the Budget Act of 2016, as amended by Chapter 7 of the Statutes of 2017.(D) The construction, alteration, repair, rehabilitation, or improvement of the Golden Gate Bridge, as defined in Section 27502 of the Streets and Highways Code.(E) A Metrolink commuter rail project.(5) Regional transportation agency means any of the following:(A) A transportation planning agency described in Section 29532 or 29532.1 of the Government Code.(B) A county transportation commission established under Section 130050, 130050.1, or 130050.2 of the Public Utilities Code.(C) Any other local or regional transportation entity that is designated by statute as a regional transportation agency.(D) A joint exercise of powers authority established pursuant to Chapter 5 (commencing with Section 6500) of Division 7 of Title 1 of the Government Code, with the consent of a transportation planning agency or a county transportation commission for the jurisdiction in which the transportation project will be developed.(E) A local transportation authority created or designated pursuant to Division 12.5 (commencing with Section 131000) or Division 19 (commencing with Section 180000) of the Public Utilities Code.(F) The Santa Clara Valley Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.(G) The County of Placer.(H) The County of Riverside.(I) The Golden Gate Bridge, Highway and Transportation District established pursuant to Chapter 18 (commencing with Section 27500) of Part 3 of Division 16 of the Streets and Highways Code Code.(J) The Contra Costa Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.(K) The County of Contra Costa.(c) Nothing in this section shall extend any other authority to the County of Riverside Riverside, the County of Contra Costa, or the Golden Gate Bridge, Highway and Transportation District, as a transportation planning agency under any other law.
SECTION 1. Section 6971 of the Public Contract Code is amended to read:
### SECTION 1.
6971. (a) The Legislature finds and declares that the the following:(1) The County of Riverside should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of the railroad grade separations and bridge rehabilitations and replacements specified in subparagraph (C) of paragraph (4) of subdivision (b) using Construction Manager/General Contractor authority. The passage of the Road Repair and Accountability Act of 2017 (Chapter 5 of the Statutes of 2017) provides additional transportation revenue to help close the significant funding shortfalls and address the substantial backlog of infrastructure projects that are in need of repair. The geography, topography, and location of these railroad grade separations and bridge rehabilitations and replacements projects present many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.(2) The County of Contra Costa should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of a bridge over Bollinger Canyon to extend the Iron Horse Trail using the Construction Manager/General Contractor authority. The geography, topography, and location of the bridge presents many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.(b) For purposes of this chapter, the following definitions apply:(1) Construction manager means a partnership, corporation, or other legal entity that is able to provide appropriately licensed contracting and engineering services as needed pursuant to a Construction Manager/General Contractor method contract.(2) Construction Manager/General Contractor method means a project delivery method in which a construction manager is procured to provide preconstruction services during the design phase of the project and construction services during the construction phase of the project. The contract for construction services may be entered into at the same time as the contract for preconstruction services, or at a later time. The execution of the design and the construction of the project may be in sequential phases or concurrent phases.(3) Preconstruction services means advice during the design phase, including, but not limited to, scheduling, pricing, and phasing to assist the regional transportation agency to design a more constructible project.(4) Project means any of the following:(A) The construction of an expressway that is not on the state highway system.(B) The construction of the following bridges that are not on the state highway system:(i) Yerba Buena Island (YBI) West Side Bridges Seismic Retrofit Project.(ii) Yankee Jims Road Bridge Project in the County of Placer (Replacement/Rehabilitation).(iii) Bridge over Bollinger Canyon to extend the Iron Horse Trail.(C) The construction of railroad grade separations and bridge rehabilitations and replacements in the County of Riverside, as specified in Item 2660-110-0042 of Section 2.00 of the Budget Act of 2016, as amended by Chapter 7 of the Statutes of 2017.(D) The construction, alteration, repair, rehabilitation, or improvement of the Golden Gate Bridge, as defined in Section 27502 of the Streets and Highways Code.(E) A Metrolink commuter rail project.(5) Regional transportation agency means any of the following:(A) A transportation planning agency described in Section 29532 or 29532.1 of the Government Code.(B) A county transportation commission established under Section 130050, 130050.1, or 130050.2 of the Public Utilities Code.(C) Any other local or regional transportation entity that is designated by statute as a regional transportation agency.(D) A joint exercise of powers authority established pursuant to Chapter 5 (commencing with Section 6500) of Division 7 of Title 1 of the Government Code, with the consent of a transportation planning agency or a county transportation commission for the jurisdiction in which the transportation project will be developed.(E) A local transportation authority created or designated pursuant to Division 12.5 (commencing with Section 131000) or Division 19 (commencing with Section 180000) of the Public Utilities Code.(F) The Santa Clara Valley Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.(G) The County of Placer.(H) The County of Riverside.(I) The Golden Gate Bridge, Highway and Transportation District established pursuant to Chapter 18 (commencing with Section 27500) of Part 3 of Division 16 of the Streets and Highways Code Code.(J) The Contra Costa Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.(K) The County of Contra Costa.(c) Nothing in this section shall extend any other authority to the County of Riverside Riverside, the County of Contra Costa, or the Golden Gate Bridge, Highway and Transportation District, as a transportation planning agency under any other law.
6971. (a) The Legislature finds and declares that the the following:(1) The County of Riverside should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of the railroad grade separations and bridge rehabilitations and replacements specified in subparagraph (C) of paragraph (4) of subdivision (b) using Construction Manager/General Contractor authority. The passage of the Road Repair and Accountability Act of 2017 (Chapter 5 of the Statutes of 2017) provides additional transportation revenue to help close the significant funding shortfalls and address the substantial backlog of infrastructure projects that are in need of repair. The geography, topography, and location of these railroad grade separations and bridge rehabilitations and replacements projects present many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.(2) The County of Contra Costa should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of a bridge over Bollinger Canyon to extend the Iron Horse Trail using the Construction Manager/General Contractor authority. The geography, topography, and location of the bridge presents many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.(b) For purposes of this chapter, the following definitions apply:(1) Construction manager means a partnership, corporation, or other legal entity that is able to provide appropriately licensed contracting and engineering services as needed pursuant to a Construction Manager/General Contractor method contract.(2) Construction Manager/General Contractor method means a project delivery method in which a construction manager is procured to provide preconstruction services during the design phase of the project and construction services during the construction phase of the project. The contract for construction services may be entered into at the same time as the contract for preconstruction services, or at a later time. The execution of the design and the construction of the project may be in sequential phases or concurrent phases.(3) Preconstruction services means advice during the design phase, including, but not limited to, scheduling, pricing, and phasing to assist the regional transportation agency to design a more constructible project.(4) Project means any of the following:(A) The construction of an expressway that is not on the state highway system.(B) The construction of the following bridges that are not on the state highway system:(i) Yerba Buena Island (YBI) West Side Bridges Seismic Retrofit Project.(ii) Yankee Jims Road Bridge Project in the County of Placer (Replacement/Rehabilitation).(iii) Bridge over Bollinger Canyon to extend the Iron Horse Trail.(C) The construction of railroad grade separations and bridge rehabilitations and replacements in the County of Riverside, as specified in Item 2660-110-0042 of Section 2.00 of the Budget Act of 2016, as amended by Chapter 7 of the Statutes of 2017.(D) The construction, alteration, repair, rehabilitation, or improvement of the Golden Gate Bridge, as defined in Section 27502 of the Streets and Highways Code.(E) A Metrolink commuter rail project.(5) Regional transportation agency means any of the following:(A) A transportation planning agency described in Section 29532 or 29532.1 of the Government Code.(B) A county transportation commission established under Section 130050, 130050.1, or 130050.2 of the Public Utilities Code.(C) Any other local or regional transportation entity that is designated by statute as a regional transportation agency.(D) A joint exercise of powers authority established pursuant to Chapter 5 (commencing with Section 6500) of Division 7 of Title 1 of the Government Code, with the consent of a transportation planning agency or a county transportation commission for the jurisdiction in which the transportation project will be developed.(E) A local transportation authority created or designated pursuant to Division 12.5 (commencing with Section 131000) or Division 19 (commencing with Section 180000) of the Public Utilities Code.(F) The Santa Clara Valley Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.(G) The County of Placer.(H) The County of Riverside.(I) The Golden Gate Bridge, Highway and Transportation District established pursuant to Chapter 18 (commencing with Section 27500) of Part 3 of Division 16 of the Streets and Highways Code Code.(J) The Contra Costa Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.(K) The County of Contra Costa.(c) Nothing in this section shall extend any other authority to the County of Riverside Riverside, the County of Contra Costa, or the Golden Gate Bridge, Highway and Transportation District, as a transportation planning agency under any other law.
6971. (a) The Legislature finds and declares that the the following:(1) The County of Riverside should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of the railroad grade separations and bridge rehabilitations and replacements specified in subparagraph (C) of paragraph (4) of subdivision (b) using Construction Manager/General Contractor authority. The passage of the Road Repair and Accountability Act of 2017 (Chapter 5 of the Statutes of 2017) provides additional transportation revenue to help close the significant funding shortfalls and address the substantial backlog of infrastructure projects that are in need of repair. The geography, topography, and location of these railroad grade separations and bridge rehabilitations and replacements projects present many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.(2) The County of Contra Costa should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of a bridge over Bollinger Canyon to extend the Iron Horse Trail using the Construction Manager/General Contractor authority. The geography, topography, and location of the bridge presents many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.(b) For purposes of this chapter, the following definitions apply:(1) Construction manager means a partnership, corporation, or other legal entity that is able to provide appropriately licensed contracting and engineering services as needed pursuant to a Construction Manager/General Contractor method contract.(2) Construction Manager/General Contractor method means a project delivery method in which a construction manager is procured to provide preconstruction services during the design phase of the project and construction services during the construction phase of the project. The contract for construction services may be entered into at the same time as the contract for preconstruction services, or at a later time. The execution of the design and the construction of the project may be in sequential phases or concurrent phases.(3) Preconstruction services means advice during the design phase, including, but not limited to, scheduling, pricing, and phasing to assist the regional transportation agency to design a more constructible project.(4) Project means any of the following:(A) The construction of an expressway that is not on the state highway system.(B) The construction of the following bridges that are not on the state highway system:(i) Yerba Buena Island (YBI) West Side Bridges Seismic Retrofit Project.(ii) Yankee Jims Road Bridge Project in the County of Placer (Replacement/Rehabilitation).(iii) Bridge over Bollinger Canyon to extend the Iron Horse Trail.(C) The construction of railroad grade separations and bridge rehabilitations and replacements in the County of Riverside, as specified in Item 2660-110-0042 of Section 2.00 of the Budget Act of 2016, as amended by Chapter 7 of the Statutes of 2017.(D) The construction, alteration, repair, rehabilitation, or improvement of the Golden Gate Bridge, as defined in Section 27502 of the Streets and Highways Code.(E) A Metrolink commuter rail project.(5) Regional transportation agency means any of the following:(A) A transportation planning agency described in Section 29532 or 29532.1 of the Government Code.(B) A county transportation commission established under Section 130050, 130050.1, or 130050.2 of the Public Utilities Code.(C) Any other local or regional transportation entity that is designated by statute as a regional transportation agency.(D) A joint exercise of powers authority established pursuant to Chapter 5 (commencing with Section 6500) of Division 7 of Title 1 of the Government Code, with the consent of a transportation planning agency or a county transportation commission for the jurisdiction in which the transportation project will be developed.(E) A local transportation authority created or designated pursuant to Division 12.5 (commencing with Section 131000) or Division 19 (commencing with Section 180000) of the Public Utilities Code.(F) The Santa Clara Valley Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.(G) The County of Placer.(H) The County of Riverside.(I) The Golden Gate Bridge, Highway and Transportation District established pursuant to Chapter 18 (commencing with Section 27500) of Part 3 of Division 16 of the Streets and Highways Code Code.(J) The Contra Costa Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.(K) The County of Contra Costa.(c) Nothing in this section shall extend any other authority to the County of Riverside Riverside, the County of Contra Costa, or the Golden Gate Bridge, Highway and Transportation District, as a transportation planning agency under any other law.
6971. (a) The Legislature finds and declares that the the following:
(1) The County of Riverside should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of the railroad grade separations and bridge rehabilitations and replacements specified in subparagraph (C) of paragraph (4) of subdivision (b) using Construction Manager/General Contractor authority. The passage of the Road Repair and Accountability Act of 2017 (Chapter 5 of the Statutes of 2017) provides additional transportation revenue to help close the significant funding shortfalls and address the substantial backlog of infrastructure projects that are in need of repair. The geography, topography, and location of these railroad grade separations and bridge rehabilitations and replacements projects present many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.
(2) The County of Contra Costa should be considered a transportation planning agency for the purposes of this chapter in order to effectuate the construction of a bridge over Bollinger Canyon to extend the Iron Horse Trail using the Construction Manager/General Contractor authority. The geography, topography, and location of the bridge presents many potential complex challenges, and the Construction Manager/General Contractor method could reduce delays and ensure that those challenges are fully understood at the outset of construction.
(b) For purposes of this chapter, the following definitions apply:
(1) Construction manager means a partnership, corporation, or other legal entity that is able to provide appropriately licensed contracting and engineering services as needed pursuant to a Construction Manager/General Contractor method contract.
(2) Construction Manager/General Contractor method means a project delivery method in which a construction manager is procured to provide preconstruction services during the design phase of the project and construction services during the construction phase of the project. The contract for construction services may be entered into at the same time as the contract for preconstruction services, or at a later time. The execution of the design and the construction of the project may be in sequential phases or concurrent phases.
(3) Preconstruction services means advice during the design phase, including, but not limited to, scheduling, pricing, and phasing to assist the regional transportation agency to design a more constructible project.
(4) Project means any of the following:
(A) The construction of an expressway that is not on the state highway system.
(B) The construction of the following bridges that are not on the state highway system:
(i) Yerba Buena Island (YBI) West Side Bridges Seismic Retrofit Project.
(ii) Yankee Jims Road Bridge Project in the County of Placer (Replacement/Rehabilitation).
(iii) Bridge over Bollinger Canyon to extend the Iron Horse Trail.
(C) The construction of railroad grade separations and bridge rehabilitations and replacements in the County of Riverside, as specified in Item 2660-110-0042 of Section 2.00 of the Budget Act of 2016, as amended by Chapter 7 of the Statutes of 2017.
(D) The construction, alteration, repair, rehabilitation, or improvement of the Golden Gate Bridge, as defined in Section 27502 of the Streets and Highways Code.
(E) A Metrolink commuter rail project.
(5) Regional transportation agency means any of the following:
(A) A transportation planning agency described in Section 29532 or 29532.1 of the Government Code.
(B) A county transportation commission established under Section 130050, 130050.1, or 130050.2 of the Public Utilities Code.
(C) Any other local or regional transportation entity that is designated by statute as a regional transportation agency.
(D) A joint exercise of powers authority established pursuant to Chapter 5 (commencing with Section 6500) of Division 7 of Title 1 of the Government Code, with the consent of a transportation planning agency or a county transportation commission for the jurisdiction in which the transportation project will be developed.
(E) A local transportation authority created or designated pursuant to Division 12.5 (commencing with Section 131000) or Division 19 (commencing with Section 180000) of the Public Utilities Code.
(F) The Santa Clara Valley Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.
(G) The County of Placer.
(H) The County of Riverside.
(I) The Golden Gate Bridge, Highway and Transportation District established pursuant to Chapter 18 (commencing with Section 27500) of Part 3 of Division 16 of the Streets and Highways Code Code.
(J) The Contra Costa Transportation Authority established pursuant to Part 12 (commencing with Section 100000) of Division 10 of the Public Utilities Code.
(K) The County of Contra Costa.
(c) Nothing in this section shall extend any other authority to the County of Riverside Riverside, the County of Contra Costa, or the Golden Gate Bridge, Highway and Transportation District, as a transportation planning agency under any other law.
SEC. 2. The Legislature finds and declares that a special statute is necessary and that a general statute cannot be made applicable within the meaning of Section 16 of Article IV of the California Constitution because of the unique circumstances regarding bridge transportation construction projects in the County of Contra Costa.
SEC. 2. The Legislature finds and declares that a special statute is necessary and that a general statute cannot be made applicable within the meaning of Section 16 of Article IV of the California Constitution because of the unique circumstances regarding bridge transportation construction projects in the County of Contra Costa.
SEC. 2. The Legislature finds and declares that a special statute is necessary and that a general statute cannot be made applicable within the meaning of Section 16 of Article IV of the California Constitution because of the unique circumstances regarding bridge transportation construction projects in the County of Contra Costa.
### SEC. 2.
SEC. 3. No reimbursement is required by this act pursuant to Section 6 of Article XIIIB of the California Constitution because the only costs that may be incurred by a local agency or school district will be incurred because this act creates a new crime or infraction, eliminates a crime or infraction, or changes the penalty for a crime or infraction, within the meaning of Section 17556 of the Government Code, or changes the definition of a crime within the meaning of Section 6 of Article XIIIB of the California Constitution.
SEC. 3. No reimbursement is required by this act pursuant to Section 6 of Article XIIIB of the California Constitution because the only costs that may be incurred by a local agency or school district will be incurred because this act creates a new crime or infraction, eliminates a crime or infraction, or changes the penalty for a crime or infraction, within the meaning of Section 17556 of the Government Code, or changes the definition of a crime within the meaning of Section 6 of Article XIIIB of the California Constitution.
SEC. 3. No reimbursement is required by this act pursuant to Section 6 of Article XIIIB of the California Constitution because the only costs that may be incurred by a local agency or school district will be incurred because this act creates a new crime or infraction, eliminates a crime or infraction, or changes the penalty for a crime or infraction, within the meaning of Section 17556 of the Government Code, or changes the definition of a crime within the meaning of Section 6 of Article XIIIB of the California Constitution.
### SEC. 3.