| 1 | 1 | | CALIFORNIA LEGISLATURE 20232024 REGULAR SESSION Senate Bill No. 1470Introduced by Senator Glazer(Coauthors: Senators Allen and Cortese)February 16, 2024 An act to amend Sections 895, 896, 897, 916, 921, 926, 927, 933, 934, and 945.5 of the Civil Code, relating to construction defects. LEGISLATIVE COUNSEL'S DIGESTSB 1470, as introduced, Glazer. Construction defect cases.(1) Existing law sets forth standards for determining liability in an action seeking the recovery of damages arising out of, or related to, deficiencies in residential construction, design, and related issues, and specifies the characteristics of those deficiencies.This bill would require a deficiency in the specific standards described above to materially affect the habitability or usefulness of the residential dwelling unit and to be a result of a failure to meet the standard of care in order for the builder to be liable, as specified. The bill would define standard of care as the level of care standard in an industry for similar work performed in the state.(2) Existing law provides for prelitigation procedures for construction defect claims, pursuant to which a claimant and a builder engage in a nonadversarial procedure to resolve deficiencies in construction prior to an adversarial enforcement action. That procedure includes, among other things, an inspection and repair of the alleged defective construction by the builder. Existing law prohibits a builder from obtaining a release or waiver in exchange for such repair work. Existing law authorizes evidence of a repair effort to be admitted as evidence in the event of an enforcement action, and provides that if the claimant contends that repair work was inadequate that the claimant need not shown that the repair work resulted in further damage.This bill would provide for the participation of a special inspector, as defined, in the inspection and approval of repair work performed pursuant to these procedures, and require the builder to obtain and pay for a building permit to perform such work. The bill would instead authorize a builder to obtain a release or waiver upon completion of repair work. This bill would require a local permitting authority to issue a building permit for these purposes within 30 days of receipt of an application for a permit, thereby creating a state-mandated local program. The bill would provide that a claimants rejection of an offer to repair is not inadmissible in an enforcement action. The bill would delete the evidentiary provisions described above and instead authorize the introduction of a building permit and reports from a special inspector as evidence in an enforcement action.(3) Existing law provides for various affirmative defenses for a builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional who is defending an enforcement action for construction deficiencies described above.This will would add a builders compliance with a building permit and approval of repairs from the permitting body, and the builders receipt of approval from a special inspector to these affirmative defenses.The California Constitution requires the state to reimburse local agencies and school districts for certain costs mandated by the state. Statutory provisions establish procedures for making that reimbursement.This bill would provide that, if the Commission on State Mandates determines that the bill contains costs mandated by the state, reimbursement for those costs shall be made pursuant to the statutory provisions noted above.Digest Key Vote: MAJORITY Appropriation: NO Fiscal Committee: YES Local Program: YES Bill TextThe people of the State of California do enact as follows:SECTION 1. Section 895 of the Civil Code is amended to read:895. (a) Structure means any residential dwelling, other building, or improvement located upon a lot or within a common area.(b) Building permit means a permit for the work necessary to remedy or repair a defect. (b)(c) Designed moisture barrier means an installed moisture barrier specified in the plans and specifications, contract documents, or manufacturers recommendations.(c)(d) Actual moisture barrier means any component or material, actually installed, that serves to any degree as a barrier against moisture, whether or not intended as a barrier against moisture.(d)(e) Unintended water means water that passes beyond, around, or through a component or the material that is designed to prevent that passage.(e)(f) Close of escrow means the date of the close of escrow between the builder and the original homeowner. With respect to claims by an association, as defined in Section 4080, close of escrow means the date of substantial completion, as defined in Section 337.15 of the Code of Civil Procedure, or the date the builder relinquishes control over the associations ability to decide whether to initiate a claim under this title, whichever is later.(f)(g) Claimant or homeowner includes the individual owners of single-family homes, individual unit owners of attached dwellings and, in the case of a common interest development, any association as defined in Section 4080.(h) Special Inspector means a private, unbiased third-party quality assurance, quality control, or special inspector.(i) Standard of care means the work was performed with the level of care standard in that industry for similar work performed in this state.SEC. 2. Section 896 of the Civil Code is amended to read:896. In any action seeking recovery of damages arising out of, or related to deficiencies in, the residential construction, design, specifications, surveying, planning, supervision, testing, or observation of construction, a builder, and to the extent set forth in Chapter 4 (commencing with Section 910), a general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, shall, except as specifically set forth in this title, be liable for, and the claimants claims or causes of action shall be limited to violation of, the following standards, except as specifically set forth in this title. This title applies to original construction intended to be sold as an individual dwelling unit. As to condominium conversions, this title does not apply to or does not supersede any other statutory or common law. A deficiency under this section must materially affect the habitability or usefulness of the dwelling unit and be a result of a failure to meet the standard of care. (a) With respect to water issues:(1) A door shall not allow unintended water to pass beyond, around, or through the door or its designed or actual moisture barriers, if any.(2) Windows, patio doors, deck doors, and their systems shall not allow water to pass beyond, around, or through the window, patio door, or deck door or its designed or actual moisture barriers, including, without limitation, internal barriers within the systems themselves. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any.(3) Windows, patio doors, deck doors, and their systems shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any.(4) Roofs, roofing systems, chimney caps, and ventilation components shall not allow water to enter the structure or to pass beyond, around, or through the designed or actual moisture barriers, including, without limitation, internal barriers located within the systems themselves. For purposes of this paragraph, systems include, without limitation, framing, substrate, and sheathing, if any.(5) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow water to pass into the adjacent structure. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any.(6) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow unintended water to pass within the systems themselves and cause damage to the systems. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any.(7) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to cause damage to another building component.(8) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to limit the installation of the type of flooring materials typically used for the particular application.(9) Hardscape, including paths and patios, irrigation systems, landscaping systems, and drainage systems, that are installed as part of the original construction, shall not be installed in such a way as to cause water or soil erosion to enter into or come in contact with the structure so as to cause damage to another building component.(10) Stucco, exterior siding, exterior walls, including, without limitation, exterior framing, and other exterior wall finishes and fixtures and the systems of those components and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall be installed in such a way so as not to allow unintended water to pass into the structure or to pass beyond, around, or through the designed or actual moisture barriers of the system, including any internal barriers located within the system itself. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any.(11) Stucco, exterior siding, and exterior walls shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any.(12) Retaining and site walls and their associated drainage systems shall not allow unintended water to pass beyond, around, or through its designed or actual moisture barriers including, without limitation, any internal barriers, so as to cause damage. This standard does not apply to those portions of any wall or drainage system that are designed to have water flow beyond, around, or through them.(13) Retaining walls and site walls, and their associated drainage systems, shall only allow water to flow beyond, around, or through the areas designated by design.(14) The lines and components of the plumbing system, sewer system, and utility systems shall not leak.(15) Plumbing lines, sewer lines, and utility lines shall not corrode so as to impede the useful life of the systems.(16) Sewer systems shall be installed in such a way as to allow the designated amount of sewage to flow through the system.(17) Showers, baths, and related waterproofing systems shall not leak water into the interior of walls, flooring systems, or the interior of other components.(18) The waterproofing system behind or under ceramic tile and tile countertops shall not allow water into the interior of walls, flooring systems, or other components so as to cause damage. Ceramic tile systems shall be designed and installed so as to deflect intended water to the waterproofing system.(b) With respect to structural issues:(1) Foundations, load bearing components, and slabs, shall not contain significant cracks or significant vertical displacement.(2) Foundations, load bearing components, and slabs shall not cause the structure, in whole or in part, to be structurally unsafe.(3) Foundations, load bearing components, and slabs, and underlying soils shall be constructed so as to materially comply with the design criteria set by applicable government building codes, regulations, and ordinances for chemical deterioration or corrosion resistance in effect at the time of original construction.(4) A structure shall be constructed so as to materially comply with the design criteria for earthquake and wind load resistance, as set forth in the applicable government building codes, regulations, and ordinances in effect at the time of original construction.(c) With respect to soil issues:(1) Soils and engineered retaining walls shall not cause, in whole or in part, damage to the structure built upon the soil or engineered retaining wall.(2) Soils and engineered retaining walls shall not cause, in whole or in part, the structure to be structurally unsafe.(3) Soils shall not cause, in whole or in part, the land upon which no structure is built to become unusable for the purpose represented at the time of original sale by the builder or for the purpose for which that land is commonly used.(d) With respect to fire protection issues:(1) A structure shall be constructed so as to materially comply with the design criteria of the applicable government building codes, regulations, and ordinances for fire protection of the occupants in effect at the time of the original construction.(2) Fireplaces, chimneys, chimney structures, and chimney termination caps shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire outside the fireplace enclosure or chimney.(3) Electrical and mechanical systems shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire.(e) With respect to plumbing and sewer issues:Plumbing and sewer systems shall be installed to operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action may be brought for a violation of this subdivision more than four years after close of escrow.(f) With respect to electrical system issues:Electrical systems shall operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action shall be brought pursuant to this subdivision more than four years from close of escrow.(g) With respect to issues regarding other areas of construction:(1) Exterior pathways, driveways, hardscape, sidewalls, sidewalks, and patios installed by the original builder shall not contain cracks that display significant vertical displacement or that are excessive. However, no action shall be brought upon a violation of this paragraph more than four years from close of escrow.(2) Stucco, exterior siding, and other exterior wall finishes and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall not contain significant cracks or separations.(3) (A) To the extent not otherwise covered by these standards, manufactured products, including, but not limited to, windows, doors, roofs, plumbing products and fixtures, fireplaces, electrical fixtures, HVAC units, countertops, cabinets, paint, and appliances shall be installed so as not to interfere with the products useful life, if any.(B) For purposes of this paragraph, useful life means a representation of how long a product is warranted or represented, through its limited warranty or any written representations, to last by its manufacturer, including recommended or required maintenance. If there is no representation by a manufacturer, a builder shall install manufactured products so as not to interfere with the products utility.(C) For purposes of this paragraph, manufactured product means a product that is completely manufactured offsite.(D) If no useful life representation is made, or if the representation is less than one year, the period shall be no less than one year. If a manufactured product is damaged as a result of a violation of these standards, damage to the product is a recoverable element of damages. This subparagraph does not limit recovery if there has been damage to another building component caused by a manufactured product during the manufactured products useful life. A builder is not strictly liable for damage to a manufactured product if the builder exercised the proper standard of care in the installation and the damage does not materially affect the habitability or usefulness of the dwelling unit.(E) This title does not apply in any action seeking recovery solely for a defect in a manufactured product located within or adjacent to a structure.(4) Heating shall be installed so as to be capable of maintaining a room temperature of 70 degrees Fahrenheit at a point three feet above the floor in any living space if the heating was installed pursuant to a building permit application submitted prior to January 1, 2008, or capable of maintaining a room temperature of 68 degrees Fahrenheit at a point three feet above the floor and two feet from exterior walls in all habitable rooms at the design temperature if the heating was installed pursuant to a building permit application submitted on or before January 1, 2008.(5) Living space air-conditioning, if any, shall be provided in a manner consistent with the size and efficiency design criteria specified in Title 24 of the California Code of Regulations or its successor.(6) Attached structures shall be constructed to comply with interunit noise transmission standards set by the applicable government building codes, ordinances, or regulations in effect at the time of the original construction. If there is no applicable code, ordinance, or regulation, this paragraph does not apply. However, no action shall be brought pursuant to this paragraph more than one year from the original occupancy of the adjacent unit.(7) Irrigation systems and drainage shall operate properly so as not to damage landscaping or other external improvements. However, no action shall be brought pursuant to this paragraph more than one year from close of escrow.(8) Untreated wood posts shall not be installed in contact with soil so as to cause unreasonable decay to the wood based upon the finish grade at the time of original construction. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(9) Untreated steel fences and adjacent components shall be installed so as to prevent unreasonable corrosion. However, no action shall be brought pursuant to this paragraph more than four years from close of escrow.(10) Paint and stains shall be applied in such a manner so as not to cause deterioration of the building surfaces for the length of time specified by the paint or stain manufacturers representations, if any. However, no action shall be brought pursuant to this paragraph more than five years from close of escrow.(11) Roofing materials shall be installed so as to avoid materials falling from the roof.(12) The landscaping systems shall be installed in such a manner so as to survive for not less than one year. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(13) Ceramic tile and tile backing shall be installed in such a manner that the tile does not detach.(14) Dryer ducts shall be installed and terminated pursuant to manufacturer installation requirements. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(15) Structures shall be constructed in such a manner so as not to impair the occupants safety because they contain public health hazards as determined by a duly authorized public health official, health agency, or governmental entity having jurisdiction. This paragraph does not limit recovery for any damages caused by a violation of any other paragraph of this section on the grounds that the damages do not constitute a health hazard.SEC. 3. Section 897 of the Civil Code is amended to read:897. The standards set forth in this chapter are intended to address every function or component of a structure. To the extent that a function or component of a structure is not addressed by these standards, it shall be actionable if the builder fails to meet the standard of care and it causes damage.SEC. 4. Section 916 of the Civil Code is amended to read:916. (a) If a builder elects and special inspector elect to inspect the claimed unmet standards, the builder and special inspector shall complete the initial inspection and testing within 14 days after acknowledgment of receipt of the notice of the claim, at a mutually convenient date and time. If the homeowner has retained legal representation, the inspection shall be scheduled with the legal representatives office at a mutually convenient date and time, unless the legal representative is unavailable during the relevant time periods. All costs of builder inspection inspection, special inspector, building permit, and testing, including any damage caused by the builder inspection, shall be borne by the builder. The builder shall also provide written proof that the builder has liability insurance to cover any damages or injuries occurring during inspection and testing. The builder shall restore the property to its pretesting condition within 48 hours of the testing. The builder shall, upon request, allow the inspections to be observed and electronically recorded, video recorded, or photographed by the claimant or his or her the claimants legal representative.(b) Nothing that occurs during a builders or claimants inspection or testing may be used or introduced as evidence to support a spoliation defense by any potential party in any subsequent litigation.(c) If a builder deems a second inspection or testing reasonably necessary, and specifies the reasons therefor in writing within three days following the initial inspection, the builder and special inspector may conduct a second inspection or testing. A second inspection or testing shall be completed within 40 days of the initial inspection or testing. All requirements concerning the initial inspection or testing shall also apply to the second inspection or testing.(d) If the builder fails to inspect or test the property within the time specified, the claimant is released from the requirements of this section and may proceed with the filing of an action. However, the standards set forth in the other chapters of this title shall continue to apply to the action.(e) If a builder intends to hold a subcontractor, design professional, individual product manufacturer, or material supplier, including an insurance carrier, warranty company, or service company, responsible for its contribution to the unmet standard, the builder shall provide notice to that person or entity sufficiently in advance to allow them to attend the initial, or if requested, second inspection of any alleged unmet standard and to participate in the repair process. The claimant and his or her the claimants legal representative, if any, shall be advised in a reasonable time prior to the inspection as to the identity of all persons or entities entities, including the special inspector, invited to attend. This subdivision does not apply to the builders insurance company. Except with respect to any claims involving a repair actually conducted under this chapter, nothing in this subdivision shall be construed to relieve a subcontractor, design professional, individual product manufacturer, or material supplier of any liability under an action brought by a claimant.SEC. 5. Section 921 of the Civil Code is amended to read:921. (a) In the event that a resolution under this chapter involves a repair by the builder, the builder shall apply for and receive a building permit from the permitting body of the jurisdiction of the home, make an appointment with the claimant, make all appropriate arrangements to effectuate a repair of the claimed unmet standards, and compensate the homeowner for all damages resulting therefrom free of charge to the claimant. The permitting body for the jurisdiction of the claimants dwelling shall issue a building permit within 30 days of the date of submission of an application for a building permit. The repair shall be scheduled through the claimants legal representative, if any, unless he or she the claimants legal representative is unavailable during the relevant time periods. The repair shall be commenced on a mutually convenient date within 14 days of acceptance or, if an alternative contractor is selected by the homeowner, within 14 days of the selection, or, if a mediation occurs, within seven days of the mediation, or within five days after a permit is obtained if one is required. building permit is issued. The builder shall act with reasonable diligence in obtaining any such permit.(b) The builder shall ensure that work done on the repairs is done with the utmost diligence, and that the repairs are completed as soon as reasonably possible, subject to the nature of the repair or some unforeseen event not caused by the builder or the contractor performing the repair. Every effort shall be made to complete the repair within 120 days. During such repairs the special inspector shall review the repairs at least once.SEC. 6. Section 926 of the Civil Code is amended to read:926. The builder may not obtain a release or waiver of any kind in exchange for upon completion of the building permit and completion of the repair work mandated by this chapter. At the conclusion of the repair, the claimant may proceed with filing an action for violation of the applicable standard or for a claim of inadequate repair, or both, including all applicable damages available under Section 944. of care for any work not completed. Should there be a dispute regarding the aesthetic quality of the work, the special inspector shall review the work to ensure the aesthetic quality reasonably matches the finish that was intended prior to beginning repair of the defect.SEC. 7. Section 927 of the Civil Code is amended to read:927. If the applicable statute of limitations has otherwise run during this process, the time period for filing a complaint or other legal remedies for violation of any provision of this title, for failure to complete the building permit to its expiration, or for a claim of inadequate repair, is extended from the time of the original claim by the claimant to 100 days after the repair is completed, whether or not the particular violation is the one being repaired. If the builder fails to acknowledge the claim within the time specified, elects not to go through this statutory process, or fails to request an inspection within the time specified, the time period for filing a complaint or other legal remedies for violation of any provision of this title is extended from the time of the original claim by the claimant to 45 days after the time for responding to the notice of claim has expired. If the builder elects to attempt to enforce its own nonadversarial procedure in lieu of the procedure set forth in this chapter, the time period for filing a complaint or other legal remedies for violation of any provision of this part is extended from the time of the original claim by the claimant to 100 days after either the completion of the builders alternative nonadversarial procedure, or 100 days after the builders alternative nonadversarial procedure is deemed unenforceable, whichever is later.SEC. 8. Section 933 of the Civil Code is amended to read:933. If any enforcement of these standards is commenced, the fact that a repair effort was made may be introduced to the trier of fact. However, the claimant may use the condition of the property prior to the repair as the basis for contending that the repair work was inappropriate, inadequate, or incomplete, or that the violation still exists. The claimant need not show that the repair work resulted in further damage nor that damage has continued to occur as a result of the violation. made, and the associated building permit and reports from the special inspector may be introduced to the trier of fact.SEC. 9. Section 934 of the Civil Code is amended to read:934. Evidence of both parties conduct during this process may be introduced during a subsequent enforcement action, if any, with the exception of any mediation. Any repair efforts undertaken by the builder, shall not be considered settlement communications or offers of settlement and are not inadmissible in evidence on such a basis. Should the claimant reject an offer to repair under Section 918, such rejection is not inadmissible under this section.SEC. 10. Section 945.5 of the Civil Code is amended to read:945.5. A builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, under the principles of comparative fault pertaining to affirmative defenses, may be excused, in whole or in part, from any obligation, damage, loss, or liability if the builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, can demonstrate any of the following affirmative defenses in response to a claimed violation:(a) To the extent it is caused by an unforeseen act of nature which caused the structure not to meet the standard. For purposes of this section an unforeseen act of nature means a weather condition, earthquake, or manmade event such as war, terrorism, or vandalism, in excess of the design criteria expressed by the applicable building codes, regulations, and ordinances in effect at the time of original construction.(b) To the extent it is caused by a homeowners unreasonable failure to minimize or prevent those damages in a timely manner, including the failure of the homeowner to allow reasonable and timely access for inspections and repairs under this title. This includes the failure to give timely notice to the builder after discovery of a violation, but does not include damages due to the untimely or inadequate response of a builder to the homeowners claim.(c) To the extent it is caused by the homeowner or his or her the homeowners agent, employee, general contractor, subcontractor, independent contractor, or consultant by virtue of their failure to follow the builders or manufacturers recommendations, or commonly accepted homeowner maintenance obligations. In order to rely upon this defense as it relates to a builders recommended maintenance schedule, the builder shall show that the homeowner had written notice of these schedules and recommendations and that the recommendations and schedules were reasonable at the time they were issued.(d) To the extent it is caused by the homeowner or his or her the homeowners agents or an independent third partys alterations, ordinary wear and tear, misuse, abuse, or neglect, or by the structures use for something other than its intended purpose.(e) To the extent that the time period for filing actions bars the claimed violation.(f) As to a particular violation for which the builder has obtained a valid release.(g) To the extent that the builders repair was successful in correcting the particular violation of the applicable standard.(h) To the extent that the builder complied with the building permit and gained final sign-off from the permitting body for the repairs.(i) To the extent that the builder received approval from the special inspector on the work completed for the repairs.(h)(j) As to any causes of action to which this statute does not apply, all applicable affirmative defenses are preserved.SEC. 11. If the Commission on State Mandates determines that this act contains costs mandated by the state, reimbursement to local agencies and school districts for those costs shall be made pursuant to Part 7 (commencing with Section 17500) of Division 4 of Title 2 of the Government Code. |
|---|
| 2 | 2 | | |
|---|
| 3 | 3 | | CALIFORNIA LEGISLATURE 20232024 REGULAR SESSION Senate Bill No. 1470Introduced by Senator Glazer(Coauthors: Senators Allen and Cortese)February 16, 2024 An act to amend Sections 895, 896, 897, 916, 921, 926, 927, 933, 934, and 945.5 of the Civil Code, relating to construction defects. LEGISLATIVE COUNSEL'S DIGESTSB 1470, as introduced, Glazer. Construction defect cases.(1) Existing law sets forth standards for determining liability in an action seeking the recovery of damages arising out of, or related to, deficiencies in residential construction, design, and related issues, and specifies the characteristics of those deficiencies.This bill would require a deficiency in the specific standards described above to materially affect the habitability or usefulness of the residential dwelling unit and to be a result of a failure to meet the standard of care in order for the builder to be liable, as specified. The bill would define standard of care as the level of care standard in an industry for similar work performed in the state.(2) Existing law provides for prelitigation procedures for construction defect claims, pursuant to which a claimant and a builder engage in a nonadversarial procedure to resolve deficiencies in construction prior to an adversarial enforcement action. That procedure includes, among other things, an inspection and repair of the alleged defective construction by the builder. Existing law prohibits a builder from obtaining a release or waiver in exchange for such repair work. Existing law authorizes evidence of a repair effort to be admitted as evidence in the event of an enforcement action, and provides that if the claimant contends that repair work was inadequate that the claimant need not shown that the repair work resulted in further damage.This bill would provide for the participation of a special inspector, as defined, in the inspection and approval of repair work performed pursuant to these procedures, and require the builder to obtain and pay for a building permit to perform such work. The bill would instead authorize a builder to obtain a release or waiver upon completion of repair work. This bill would require a local permitting authority to issue a building permit for these purposes within 30 days of receipt of an application for a permit, thereby creating a state-mandated local program. The bill would provide that a claimants rejection of an offer to repair is not inadmissible in an enforcement action. The bill would delete the evidentiary provisions described above and instead authorize the introduction of a building permit and reports from a special inspector as evidence in an enforcement action.(3) Existing law provides for various affirmative defenses for a builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional who is defending an enforcement action for construction deficiencies described above.This will would add a builders compliance with a building permit and approval of repairs from the permitting body, and the builders receipt of approval from a special inspector to these affirmative defenses.The California Constitution requires the state to reimburse local agencies and school districts for certain costs mandated by the state. Statutory provisions establish procedures for making that reimbursement.This bill would provide that, if the Commission on State Mandates determines that the bill contains costs mandated by the state, reimbursement for those costs shall be made pursuant to the statutory provisions noted above.Digest Key Vote: MAJORITY Appropriation: NO Fiscal Committee: YES Local Program: YES |
|---|
| 4 | 4 | | |
|---|
| 5 | 5 | | |
|---|
| 6 | 6 | | |
|---|
| 7 | 7 | | |
|---|
| 8 | 8 | | |
|---|
| 9 | 9 | | CALIFORNIA LEGISLATURE 20232024 REGULAR SESSION |
|---|
| 10 | 10 | | |
|---|
| 11 | 11 | | Senate Bill |
|---|
| 12 | 12 | | |
|---|
| 13 | 13 | | No. 1470 |
|---|
| 14 | 14 | | |
|---|
| 15 | 15 | | Introduced by Senator Glazer(Coauthors: Senators Allen and Cortese)February 16, 2024 |
|---|
| 16 | 16 | | |
|---|
| 17 | 17 | | Introduced by Senator Glazer(Coauthors: Senators Allen and Cortese) |
|---|
| 18 | 18 | | February 16, 2024 |
|---|
| 19 | 19 | | |
|---|
| 20 | 20 | | An act to amend Sections 895, 896, 897, 916, 921, 926, 927, 933, 934, and 945.5 of the Civil Code, relating to construction defects. |
|---|
| 21 | 21 | | |
|---|
| 22 | 22 | | LEGISLATIVE COUNSEL'S DIGEST |
|---|
| 23 | 23 | | |
|---|
| 24 | 24 | | ## LEGISLATIVE COUNSEL'S DIGEST |
|---|
| 25 | 25 | | |
|---|
| 26 | 26 | | SB 1470, as introduced, Glazer. Construction defect cases. |
|---|
| 27 | 27 | | |
|---|
| 28 | 28 | | (1) Existing law sets forth standards for determining liability in an action seeking the recovery of damages arising out of, or related to, deficiencies in residential construction, design, and related issues, and specifies the characteristics of those deficiencies.This bill would require a deficiency in the specific standards described above to materially affect the habitability or usefulness of the residential dwelling unit and to be a result of a failure to meet the standard of care in order for the builder to be liable, as specified. The bill would define standard of care as the level of care standard in an industry for similar work performed in the state.(2) Existing law provides for prelitigation procedures for construction defect claims, pursuant to which a claimant and a builder engage in a nonadversarial procedure to resolve deficiencies in construction prior to an adversarial enforcement action. That procedure includes, among other things, an inspection and repair of the alleged defective construction by the builder. Existing law prohibits a builder from obtaining a release or waiver in exchange for such repair work. Existing law authorizes evidence of a repair effort to be admitted as evidence in the event of an enforcement action, and provides that if the claimant contends that repair work was inadequate that the claimant need not shown that the repair work resulted in further damage.This bill would provide for the participation of a special inspector, as defined, in the inspection and approval of repair work performed pursuant to these procedures, and require the builder to obtain and pay for a building permit to perform such work. The bill would instead authorize a builder to obtain a release or waiver upon completion of repair work. This bill would require a local permitting authority to issue a building permit for these purposes within 30 days of receipt of an application for a permit, thereby creating a state-mandated local program. The bill would provide that a claimants rejection of an offer to repair is not inadmissible in an enforcement action. The bill would delete the evidentiary provisions described above and instead authorize the introduction of a building permit and reports from a special inspector as evidence in an enforcement action.(3) Existing law provides for various affirmative defenses for a builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional who is defending an enforcement action for construction deficiencies described above.This will would add a builders compliance with a building permit and approval of repairs from the permitting body, and the builders receipt of approval from a special inspector to these affirmative defenses.The California Constitution requires the state to reimburse local agencies and school districts for certain costs mandated by the state. Statutory provisions establish procedures for making that reimbursement.This bill would provide that, if the Commission on State Mandates determines that the bill contains costs mandated by the state, reimbursement for those costs shall be made pursuant to the statutory provisions noted above. |
|---|
| 29 | 29 | | |
|---|
| 30 | 30 | | (1) Existing law sets forth standards for determining liability in an action seeking the recovery of damages arising out of, or related to, deficiencies in residential construction, design, and related issues, and specifies the characteristics of those deficiencies. |
|---|
| 31 | 31 | | |
|---|
| 32 | 32 | | This bill would require a deficiency in the specific standards described above to materially affect the habitability or usefulness of the residential dwelling unit and to be a result of a failure to meet the standard of care in order for the builder to be liable, as specified. The bill would define standard of care as the level of care standard in an industry for similar work performed in the state. |
|---|
| 33 | 33 | | |
|---|
| 34 | 34 | | (2) Existing law provides for prelitigation procedures for construction defect claims, pursuant to which a claimant and a builder engage in a nonadversarial procedure to resolve deficiencies in construction prior to an adversarial enforcement action. That procedure includes, among other things, an inspection and repair of the alleged defective construction by the builder. Existing law prohibits a builder from obtaining a release or waiver in exchange for such repair work. Existing law authorizes evidence of a repair effort to be admitted as evidence in the event of an enforcement action, and provides that if the claimant contends that repair work was inadequate that the claimant need not shown that the repair work resulted in further damage. |
|---|
| 35 | 35 | | |
|---|
| 36 | 36 | | This bill would provide for the participation of a special inspector, as defined, in the inspection and approval of repair work performed pursuant to these procedures, and require the builder to obtain and pay for a building permit to perform such work. The bill would instead authorize a builder to obtain a release or waiver upon completion of repair work. This bill would require a local permitting authority to issue a building permit for these purposes within 30 days of receipt of an application for a permit, thereby creating a state-mandated local program. The bill would provide that a claimants rejection of an offer to repair is not inadmissible in an enforcement action. The bill would delete the evidentiary provisions described above and instead authorize the introduction of a building permit and reports from a special inspector as evidence in an enforcement action. |
|---|
| 37 | 37 | | |
|---|
| 38 | 38 | | (3) Existing law provides for various affirmative defenses for a builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional who is defending an enforcement action for construction deficiencies described above. |
|---|
| 39 | 39 | | |
|---|
| 40 | 40 | | This will would add a builders compliance with a building permit and approval of repairs from the permitting body, and the builders receipt of approval from a special inspector to these affirmative defenses. |
|---|
| 41 | 41 | | |
|---|
| 42 | 42 | | The California Constitution requires the state to reimburse local agencies and school districts for certain costs mandated by the state. Statutory provisions establish procedures for making that reimbursement. |
|---|
| 43 | 43 | | |
|---|
| 44 | 44 | | This bill would provide that, if the Commission on State Mandates determines that the bill contains costs mandated by the state, reimbursement for those costs shall be made pursuant to the statutory provisions noted above. |
|---|
| 45 | 45 | | |
|---|
| 46 | 46 | | ## Digest Key |
|---|
| 47 | 47 | | |
|---|
| 48 | 48 | | ## Bill Text |
|---|
| 49 | 49 | | |
|---|
| 50 | 50 | | The people of the State of California do enact as follows:SECTION 1. Section 895 of the Civil Code is amended to read:895. (a) Structure means any residential dwelling, other building, or improvement located upon a lot or within a common area.(b) Building permit means a permit for the work necessary to remedy or repair a defect. (b)(c) Designed moisture barrier means an installed moisture barrier specified in the plans and specifications, contract documents, or manufacturers recommendations.(c)(d) Actual moisture barrier means any component or material, actually installed, that serves to any degree as a barrier against moisture, whether or not intended as a barrier against moisture.(d)(e) Unintended water means water that passes beyond, around, or through a component or the material that is designed to prevent that passage.(e)(f) Close of escrow means the date of the close of escrow between the builder and the original homeowner. With respect to claims by an association, as defined in Section 4080, close of escrow means the date of substantial completion, as defined in Section 337.15 of the Code of Civil Procedure, or the date the builder relinquishes control over the associations ability to decide whether to initiate a claim under this title, whichever is later.(f)(g) Claimant or homeowner includes the individual owners of single-family homes, individual unit owners of attached dwellings and, in the case of a common interest development, any association as defined in Section 4080.(h) Special Inspector means a private, unbiased third-party quality assurance, quality control, or special inspector.(i) Standard of care means the work was performed with the level of care standard in that industry for similar work performed in this state.SEC. 2. Section 896 of the Civil Code is amended to read:896. In any action seeking recovery of damages arising out of, or related to deficiencies in, the residential construction, design, specifications, surveying, planning, supervision, testing, or observation of construction, a builder, and to the extent set forth in Chapter 4 (commencing with Section 910), a general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, shall, except as specifically set forth in this title, be liable for, and the claimants claims or causes of action shall be limited to violation of, the following standards, except as specifically set forth in this title. This title applies to original construction intended to be sold as an individual dwelling unit. As to condominium conversions, this title does not apply to or does not supersede any other statutory or common law. A deficiency under this section must materially affect the habitability or usefulness of the dwelling unit and be a result of a failure to meet the standard of care. (a) With respect to water issues:(1) A door shall not allow unintended water to pass beyond, around, or through the door or its designed or actual moisture barriers, if any.(2) Windows, patio doors, deck doors, and their systems shall not allow water to pass beyond, around, or through the window, patio door, or deck door or its designed or actual moisture barriers, including, without limitation, internal barriers within the systems themselves. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any.(3) Windows, patio doors, deck doors, and their systems shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any.(4) Roofs, roofing systems, chimney caps, and ventilation components shall not allow water to enter the structure or to pass beyond, around, or through the designed or actual moisture barriers, including, without limitation, internal barriers located within the systems themselves. For purposes of this paragraph, systems include, without limitation, framing, substrate, and sheathing, if any.(5) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow water to pass into the adjacent structure. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any.(6) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow unintended water to pass within the systems themselves and cause damage to the systems. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any.(7) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to cause damage to another building component.(8) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to limit the installation of the type of flooring materials typically used for the particular application.(9) Hardscape, including paths and patios, irrigation systems, landscaping systems, and drainage systems, that are installed as part of the original construction, shall not be installed in such a way as to cause water or soil erosion to enter into or come in contact with the structure so as to cause damage to another building component.(10) Stucco, exterior siding, exterior walls, including, without limitation, exterior framing, and other exterior wall finishes and fixtures and the systems of those components and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall be installed in such a way so as not to allow unintended water to pass into the structure or to pass beyond, around, or through the designed or actual moisture barriers of the system, including any internal barriers located within the system itself. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any.(11) Stucco, exterior siding, and exterior walls shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any.(12) Retaining and site walls and their associated drainage systems shall not allow unintended water to pass beyond, around, or through its designed or actual moisture barriers including, without limitation, any internal barriers, so as to cause damage. This standard does not apply to those portions of any wall or drainage system that are designed to have water flow beyond, around, or through them.(13) Retaining walls and site walls, and their associated drainage systems, shall only allow water to flow beyond, around, or through the areas designated by design.(14) The lines and components of the plumbing system, sewer system, and utility systems shall not leak.(15) Plumbing lines, sewer lines, and utility lines shall not corrode so as to impede the useful life of the systems.(16) Sewer systems shall be installed in such a way as to allow the designated amount of sewage to flow through the system.(17) Showers, baths, and related waterproofing systems shall not leak water into the interior of walls, flooring systems, or the interior of other components.(18) The waterproofing system behind or under ceramic tile and tile countertops shall not allow water into the interior of walls, flooring systems, or other components so as to cause damage. Ceramic tile systems shall be designed and installed so as to deflect intended water to the waterproofing system.(b) With respect to structural issues:(1) Foundations, load bearing components, and slabs, shall not contain significant cracks or significant vertical displacement.(2) Foundations, load bearing components, and slabs shall not cause the structure, in whole or in part, to be structurally unsafe.(3) Foundations, load bearing components, and slabs, and underlying soils shall be constructed so as to materially comply with the design criteria set by applicable government building codes, regulations, and ordinances for chemical deterioration or corrosion resistance in effect at the time of original construction.(4) A structure shall be constructed so as to materially comply with the design criteria for earthquake and wind load resistance, as set forth in the applicable government building codes, regulations, and ordinances in effect at the time of original construction.(c) With respect to soil issues:(1) Soils and engineered retaining walls shall not cause, in whole or in part, damage to the structure built upon the soil or engineered retaining wall.(2) Soils and engineered retaining walls shall not cause, in whole or in part, the structure to be structurally unsafe.(3) Soils shall not cause, in whole or in part, the land upon which no structure is built to become unusable for the purpose represented at the time of original sale by the builder or for the purpose for which that land is commonly used.(d) With respect to fire protection issues:(1) A structure shall be constructed so as to materially comply with the design criteria of the applicable government building codes, regulations, and ordinances for fire protection of the occupants in effect at the time of the original construction.(2) Fireplaces, chimneys, chimney structures, and chimney termination caps shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire outside the fireplace enclosure or chimney.(3) Electrical and mechanical systems shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire.(e) With respect to plumbing and sewer issues:Plumbing and sewer systems shall be installed to operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action may be brought for a violation of this subdivision more than four years after close of escrow.(f) With respect to electrical system issues:Electrical systems shall operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action shall be brought pursuant to this subdivision more than four years from close of escrow.(g) With respect to issues regarding other areas of construction:(1) Exterior pathways, driveways, hardscape, sidewalls, sidewalks, and patios installed by the original builder shall not contain cracks that display significant vertical displacement or that are excessive. However, no action shall be brought upon a violation of this paragraph more than four years from close of escrow.(2) Stucco, exterior siding, and other exterior wall finishes and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall not contain significant cracks or separations.(3) (A) To the extent not otherwise covered by these standards, manufactured products, including, but not limited to, windows, doors, roofs, plumbing products and fixtures, fireplaces, electrical fixtures, HVAC units, countertops, cabinets, paint, and appliances shall be installed so as not to interfere with the products useful life, if any.(B) For purposes of this paragraph, useful life means a representation of how long a product is warranted or represented, through its limited warranty or any written representations, to last by its manufacturer, including recommended or required maintenance. If there is no representation by a manufacturer, a builder shall install manufactured products so as not to interfere with the products utility.(C) For purposes of this paragraph, manufactured product means a product that is completely manufactured offsite.(D) If no useful life representation is made, or if the representation is less than one year, the period shall be no less than one year. If a manufactured product is damaged as a result of a violation of these standards, damage to the product is a recoverable element of damages. This subparagraph does not limit recovery if there has been damage to another building component caused by a manufactured product during the manufactured products useful life. A builder is not strictly liable for damage to a manufactured product if the builder exercised the proper standard of care in the installation and the damage does not materially affect the habitability or usefulness of the dwelling unit.(E) This title does not apply in any action seeking recovery solely for a defect in a manufactured product located within or adjacent to a structure.(4) Heating shall be installed so as to be capable of maintaining a room temperature of 70 degrees Fahrenheit at a point three feet above the floor in any living space if the heating was installed pursuant to a building permit application submitted prior to January 1, 2008, or capable of maintaining a room temperature of 68 degrees Fahrenheit at a point three feet above the floor and two feet from exterior walls in all habitable rooms at the design temperature if the heating was installed pursuant to a building permit application submitted on or before January 1, 2008.(5) Living space air-conditioning, if any, shall be provided in a manner consistent with the size and efficiency design criteria specified in Title 24 of the California Code of Regulations or its successor.(6) Attached structures shall be constructed to comply with interunit noise transmission standards set by the applicable government building codes, ordinances, or regulations in effect at the time of the original construction. If there is no applicable code, ordinance, or regulation, this paragraph does not apply. However, no action shall be brought pursuant to this paragraph more than one year from the original occupancy of the adjacent unit.(7) Irrigation systems and drainage shall operate properly so as not to damage landscaping or other external improvements. However, no action shall be brought pursuant to this paragraph more than one year from close of escrow.(8) Untreated wood posts shall not be installed in contact with soil so as to cause unreasonable decay to the wood based upon the finish grade at the time of original construction. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(9) Untreated steel fences and adjacent components shall be installed so as to prevent unreasonable corrosion. However, no action shall be brought pursuant to this paragraph more than four years from close of escrow.(10) Paint and stains shall be applied in such a manner so as not to cause deterioration of the building surfaces for the length of time specified by the paint or stain manufacturers representations, if any. However, no action shall be brought pursuant to this paragraph more than five years from close of escrow.(11) Roofing materials shall be installed so as to avoid materials falling from the roof.(12) The landscaping systems shall be installed in such a manner so as to survive for not less than one year. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(13) Ceramic tile and tile backing shall be installed in such a manner that the tile does not detach.(14) Dryer ducts shall be installed and terminated pursuant to manufacturer installation requirements. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(15) Structures shall be constructed in such a manner so as not to impair the occupants safety because they contain public health hazards as determined by a duly authorized public health official, health agency, or governmental entity having jurisdiction. This paragraph does not limit recovery for any damages caused by a violation of any other paragraph of this section on the grounds that the damages do not constitute a health hazard.SEC. 3. Section 897 of the Civil Code is amended to read:897. The standards set forth in this chapter are intended to address every function or component of a structure. To the extent that a function or component of a structure is not addressed by these standards, it shall be actionable if the builder fails to meet the standard of care and it causes damage.SEC. 4. Section 916 of the Civil Code is amended to read:916. (a) If a builder elects and special inspector elect to inspect the claimed unmet standards, the builder and special inspector shall complete the initial inspection and testing within 14 days after acknowledgment of receipt of the notice of the claim, at a mutually convenient date and time. If the homeowner has retained legal representation, the inspection shall be scheduled with the legal representatives office at a mutually convenient date and time, unless the legal representative is unavailable during the relevant time periods. All costs of builder inspection inspection, special inspector, building permit, and testing, including any damage caused by the builder inspection, shall be borne by the builder. The builder shall also provide written proof that the builder has liability insurance to cover any damages or injuries occurring during inspection and testing. The builder shall restore the property to its pretesting condition within 48 hours of the testing. The builder shall, upon request, allow the inspections to be observed and electronically recorded, video recorded, or photographed by the claimant or his or her the claimants legal representative.(b) Nothing that occurs during a builders or claimants inspection or testing may be used or introduced as evidence to support a spoliation defense by any potential party in any subsequent litigation.(c) If a builder deems a second inspection or testing reasonably necessary, and specifies the reasons therefor in writing within three days following the initial inspection, the builder and special inspector may conduct a second inspection or testing. A second inspection or testing shall be completed within 40 days of the initial inspection or testing. All requirements concerning the initial inspection or testing shall also apply to the second inspection or testing.(d) If the builder fails to inspect or test the property within the time specified, the claimant is released from the requirements of this section and may proceed with the filing of an action. However, the standards set forth in the other chapters of this title shall continue to apply to the action.(e) If a builder intends to hold a subcontractor, design professional, individual product manufacturer, or material supplier, including an insurance carrier, warranty company, or service company, responsible for its contribution to the unmet standard, the builder shall provide notice to that person or entity sufficiently in advance to allow them to attend the initial, or if requested, second inspection of any alleged unmet standard and to participate in the repair process. The claimant and his or her the claimants legal representative, if any, shall be advised in a reasonable time prior to the inspection as to the identity of all persons or entities entities, including the special inspector, invited to attend. This subdivision does not apply to the builders insurance company. Except with respect to any claims involving a repair actually conducted under this chapter, nothing in this subdivision shall be construed to relieve a subcontractor, design professional, individual product manufacturer, or material supplier of any liability under an action brought by a claimant.SEC. 5. Section 921 of the Civil Code is amended to read:921. (a) In the event that a resolution under this chapter involves a repair by the builder, the builder shall apply for and receive a building permit from the permitting body of the jurisdiction of the home, make an appointment with the claimant, make all appropriate arrangements to effectuate a repair of the claimed unmet standards, and compensate the homeowner for all damages resulting therefrom free of charge to the claimant. The permitting body for the jurisdiction of the claimants dwelling shall issue a building permit within 30 days of the date of submission of an application for a building permit. The repair shall be scheduled through the claimants legal representative, if any, unless he or she the claimants legal representative is unavailable during the relevant time periods. The repair shall be commenced on a mutually convenient date within 14 days of acceptance or, if an alternative contractor is selected by the homeowner, within 14 days of the selection, or, if a mediation occurs, within seven days of the mediation, or within five days after a permit is obtained if one is required. building permit is issued. The builder shall act with reasonable diligence in obtaining any such permit.(b) The builder shall ensure that work done on the repairs is done with the utmost diligence, and that the repairs are completed as soon as reasonably possible, subject to the nature of the repair or some unforeseen event not caused by the builder or the contractor performing the repair. Every effort shall be made to complete the repair within 120 days. During such repairs the special inspector shall review the repairs at least once.SEC. 6. Section 926 of the Civil Code is amended to read:926. The builder may not obtain a release or waiver of any kind in exchange for upon completion of the building permit and completion of the repair work mandated by this chapter. At the conclusion of the repair, the claimant may proceed with filing an action for violation of the applicable standard or for a claim of inadequate repair, or both, including all applicable damages available under Section 944. of care for any work not completed. Should there be a dispute regarding the aesthetic quality of the work, the special inspector shall review the work to ensure the aesthetic quality reasonably matches the finish that was intended prior to beginning repair of the defect.SEC. 7. Section 927 of the Civil Code is amended to read:927. If the applicable statute of limitations has otherwise run during this process, the time period for filing a complaint or other legal remedies for violation of any provision of this title, for failure to complete the building permit to its expiration, or for a claim of inadequate repair, is extended from the time of the original claim by the claimant to 100 days after the repair is completed, whether or not the particular violation is the one being repaired. If the builder fails to acknowledge the claim within the time specified, elects not to go through this statutory process, or fails to request an inspection within the time specified, the time period for filing a complaint or other legal remedies for violation of any provision of this title is extended from the time of the original claim by the claimant to 45 days after the time for responding to the notice of claim has expired. If the builder elects to attempt to enforce its own nonadversarial procedure in lieu of the procedure set forth in this chapter, the time period for filing a complaint or other legal remedies for violation of any provision of this part is extended from the time of the original claim by the claimant to 100 days after either the completion of the builders alternative nonadversarial procedure, or 100 days after the builders alternative nonadversarial procedure is deemed unenforceable, whichever is later.SEC. 8. Section 933 of the Civil Code is amended to read:933. If any enforcement of these standards is commenced, the fact that a repair effort was made may be introduced to the trier of fact. However, the claimant may use the condition of the property prior to the repair as the basis for contending that the repair work was inappropriate, inadequate, or incomplete, or that the violation still exists. The claimant need not show that the repair work resulted in further damage nor that damage has continued to occur as a result of the violation. made, and the associated building permit and reports from the special inspector may be introduced to the trier of fact.SEC. 9. Section 934 of the Civil Code is amended to read:934. Evidence of both parties conduct during this process may be introduced during a subsequent enforcement action, if any, with the exception of any mediation. Any repair efforts undertaken by the builder, shall not be considered settlement communications or offers of settlement and are not inadmissible in evidence on such a basis. Should the claimant reject an offer to repair under Section 918, such rejection is not inadmissible under this section.SEC. 10. Section 945.5 of the Civil Code is amended to read:945.5. A builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, under the principles of comparative fault pertaining to affirmative defenses, may be excused, in whole or in part, from any obligation, damage, loss, or liability if the builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, can demonstrate any of the following affirmative defenses in response to a claimed violation:(a) To the extent it is caused by an unforeseen act of nature which caused the structure not to meet the standard. For purposes of this section an unforeseen act of nature means a weather condition, earthquake, or manmade event such as war, terrorism, or vandalism, in excess of the design criteria expressed by the applicable building codes, regulations, and ordinances in effect at the time of original construction.(b) To the extent it is caused by a homeowners unreasonable failure to minimize or prevent those damages in a timely manner, including the failure of the homeowner to allow reasonable and timely access for inspections and repairs under this title. This includes the failure to give timely notice to the builder after discovery of a violation, but does not include damages due to the untimely or inadequate response of a builder to the homeowners claim.(c) To the extent it is caused by the homeowner or his or her the homeowners agent, employee, general contractor, subcontractor, independent contractor, or consultant by virtue of their failure to follow the builders or manufacturers recommendations, or commonly accepted homeowner maintenance obligations. In order to rely upon this defense as it relates to a builders recommended maintenance schedule, the builder shall show that the homeowner had written notice of these schedules and recommendations and that the recommendations and schedules were reasonable at the time they were issued.(d) To the extent it is caused by the homeowner or his or her the homeowners agents or an independent third partys alterations, ordinary wear and tear, misuse, abuse, or neglect, or by the structures use for something other than its intended purpose.(e) To the extent that the time period for filing actions bars the claimed violation.(f) As to a particular violation for which the builder has obtained a valid release.(g) To the extent that the builders repair was successful in correcting the particular violation of the applicable standard.(h) To the extent that the builder complied with the building permit and gained final sign-off from the permitting body for the repairs.(i) To the extent that the builder received approval from the special inspector on the work completed for the repairs.(h)(j) As to any causes of action to which this statute does not apply, all applicable affirmative defenses are preserved.SEC. 11. If the Commission on State Mandates determines that this act contains costs mandated by the state, reimbursement to local agencies and school districts for those costs shall be made pursuant to Part 7 (commencing with Section 17500) of Division 4 of Title 2 of the Government Code. |
|---|
| 51 | 51 | | |
|---|
| 52 | 52 | | The people of the State of California do enact as follows: |
|---|
| 53 | 53 | | |
|---|
| 54 | 54 | | ## The people of the State of California do enact as follows: |
|---|
| 55 | 55 | | |
|---|
| 56 | 56 | | SECTION 1. Section 895 of the Civil Code is amended to read:895. (a) Structure means any residential dwelling, other building, or improvement located upon a lot or within a common area.(b) Building permit means a permit for the work necessary to remedy or repair a defect. (b)(c) Designed moisture barrier means an installed moisture barrier specified in the plans and specifications, contract documents, or manufacturers recommendations.(c)(d) Actual moisture barrier means any component or material, actually installed, that serves to any degree as a barrier against moisture, whether or not intended as a barrier against moisture.(d)(e) Unintended water means water that passes beyond, around, or through a component or the material that is designed to prevent that passage.(e)(f) Close of escrow means the date of the close of escrow between the builder and the original homeowner. With respect to claims by an association, as defined in Section 4080, close of escrow means the date of substantial completion, as defined in Section 337.15 of the Code of Civil Procedure, or the date the builder relinquishes control over the associations ability to decide whether to initiate a claim under this title, whichever is later.(f)(g) Claimant or homeowner includes the individual owners of single-family homes, individual unit owners of attached dwellings and, in the case of a common interest development, any association as defined in Section 4080.(h) Special Inspector means a private, unbiased third-party quality assurance, quality control, or special inspector.(i) Standard of care means the work was performed with the level of care standard in that industry for similar work performed in this state. |
|---|
| 57 | 57 | | |
|---|
| 58 | 58 | | SECTION 1. Section 895 of the Civil Code is amended to read: |
|---|
| 59 | 59 | | |
|---|
| 60 | 60 | | ### SECTION 1. |
|---|
| 61 | 61 | | |
|---|
| 62 | 62 | | 895. (a) Structure means any residential dwelling, other building, or improvement located upon a lot or within a common area.(b) Building permit means a permit for the work necessary to remedy or repair a defect. (b)(c) Designed moisture barrier means an installed moisture barrier specified in the plans and specifications, contract documents, or manufacturers recommendations.(c)(d) Actual moisture barrier means any component or material, actually installed, that serves to any degree as a barrier against moisture, whether or not intended as a barrier against moisture.(d)(e) Unintended water means water that passes beyond, around, or through a component or the material that is designed to prevent that passage.(e)(f) Close of escrow means the date of the close of escrow between the builder and the original homeowner. With respect to claims by an association, as defined in Section 4080, close of escrow means the date of substantial completion, as defined in Section 337.15 of the Code of Civil Procedure, or the date the builder relinquishes control over the associations ability to decide whether to initiate a claim under this title, whichever is later.(f)(g) Claimant or homeowner includes the individual owners of single-family homes, individual unit owners of attached dwellings and, in the case of a common interest development, any association as defined in Section 4080.(h) Special Inspector means a private, unbiased third-party quality assurance, quality control, or special inspector.(i) Standard of care means the work was performed with the level of care standard in that industry for similar work performed in this state. |
|---|
| 63 | 63 | | |
|---|
| 64 | 64 | | 895. (a) Structure means any residential dwelling, other building, or improvement located upon a lot or within a common area.(b) Building permit means a permit for the work necessary to remedy or repair a defect. (b)(c) Designed moisture barrier means an installed moisture barrier specified in the plans and specifications, contract documents, or manufacturers recommendations.(c)(d) Actual moisture barrier means any component or material, actually installed, that serves to any degree as a barrier against moisture, whether or not intended as a barrier against moisture.(d)(e) Unintended water means water that passes beyond, around, or through a component or the material that is designed to prevent that passage.(e)(f) Close of escrow means the date of the close of escrow between the builder and the original homeowner. With respect to claims by an association, as defined in Section 4080, close of escrow means the date of substantial completion, as defined in Section 337.15 of the Code of Civil Procedure, or the date the builder relinquishes control over the associations ability to decide whether to initiate a claim under this title, whichever is later.(f)(g) Claimant or homeowner includes the individual owners of single-family homes, individual unit owners of attached dwellings and, in the case of a common interest development, any association as defined in Section 4080.(h) Special Inspector means a private, unbiased third-party quality assurance, quality control, or special inspector.(i) Standard of care means the work was performed with the level of care standard in that industry for similar work performed in this state. |
|---|
| 65 | 65 | | |
|---|
| 66 | 66 | | 895. (a) Structure means any residential dwelling, other building, or improvement located upon a lot or within a common area.(b) Building permit means a permit for the work necessary to remedy or repair a defect. (b)(c) Designed moisture barrier means an installed moisture barrier specified in the plans and specifications, contract documents, or manufacturers recommendations.(c)(d) Actual moisture barrier means any component or material, actually installed, that serves to any degree as a barrier against moisture, whether or not intended as a barrier against moisture.(d)(e) Unintended water means water that passes beyond, around, or through a component or the material that is designed to prevent that passage.(e)(f) Close of escrow means the date of the close of escrow between the builder and the original homeowner. With respect to claims by an association, as defined in Section 4080, close of escrow means the date of substantial completion, as defined in Section 337.15 of the Code of Civil Procedure, or the date the builder relinquishes control over the associations ability to decide whether to initiate a claim under this title, whichever is later.(f)(g) Claimant or homeowner includes the individual owners of single-family homes, individual unit owners of attached dwellings and, in the case of a common interest development, any association as defined in Section 4080.(h) Special Inspector means a private, unbiased third-party quality assurance, quality control, or special inspector.(i) Standard of care means the work was performed with the level of care standard in that industry for similar work performed in this state. |
|---|
| 67 | 67 | | |
|---|
| 68 | 68 | | |
|---|
| 69 | 69 | | |
|---|
| 70 | 70 | | 895. (a) Structure means any residential dwelling, other building, or improvement located upon a lot or within a common area. |
|---|
| 71 | 71 | | |
|---|
| 72 | 72 | | (b) Building permit means a permit for the work necessary to remedy or repair a defect. |
|---|
| 73 | 73 | | |
|---|
| 74 | 74 | | (b) |
|---|
| 75 | 75 | | |
|---|
| 76 | 76 | | |
|---|
| 77 | 77 | | |
|---|
| 78 | 78 | | (c) Designed moisture barrier means an installed moisture barrier specified in the plans and specifications, contract documents, or manufacturers recommendations. |
|---|
| 79 | 79 | | |
|---|
| 80 | 80 | | (c) |
|---|
| 81 | 81 | | |
|---|
| 82 | 82 | | |
|---|
| 83 | 83 | | |
|---|
| 84 | 84 | | (d) Actual moisture barrier means any component or material, actually installed, that serves to any degree as a barrier against moisture, whether or not intended as a barrier against moisture. |
|---|
| 85 | 85 | | |
|---|
| 86 | 86 | | (d) |
|---|
| 87 | 87 | | |
|---|
| 88 | 88 | | |
|---|
| 89 | 89 | | |
|---|
| 90 | 90 | | (e) Unintended water means water that passes beyond, around, or through a component or the material that is designed to prevent that passage. |
|---|
| 91 | 91 | | |
|---|
| 92 | 92 | | (e) |
|---|
| 93 | 93 | | |
|---|
| 94 | 94 | | |
|---|
| 95 | 95 | | |
|---|
| 96 | 96 | | (f) Close of escrow means the date of the close of escrow between the builder and the original homeowner. With respect to claims by an association, as defined in Section 4080, close of escrow means the date of substantial completion, as defined in Section 337.15 of the Code of Civil Procedure, or the date the builder relinquishes control over the associations ability to decide whether to initiate a claim under this title, whichever is later. |
|---|
| 97 | 97 | | |
|---|
| 98 | 98 | | (f) |
|---|
| 99 | 99 | | |
|---|
| 100 | 100 | | |
|---|
| 101 | 101 | | |
|---|
| 102 | 102 | | (g) Claimant or homeowner includes the individual owners of single-family homes, individual unit owners of attached dwellings and, in the case of a common interest development, any association as defined in Section 4080. |
|---|
| 103 | 103 | | |
|---|
| 104 | 104 | | (h) Special Inspector means a private, unbiased third-party quality assurance, quality control, or special inspector. |
|---|
| 105 | 105 | | |
|---|
| 106 | 106 | | (i) Standard of care means the work was performed with the level of care standard in that industry for similar work performed in this state. |
|---|
| 107 | 107 | | |
|---|
| 108 | 108 | | SEC. 2. Section 896 of the Civil Code is amended to read:896. In any action seeking recovery of damages arising out of, or related to deficiencies in, the residential construction, design, specifications, surveying, planning, supervision, testing, or observation of construction, a builder, and to the extent set forth in Chapter 4 (commencing with Section 910), a general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, shall, except as specifically set forth in this title, be liable for, and the claimants claims or causes of action shall be limited to violation of, the following standards, except as specifically set forth in this title. This title applies to original construction intended to be sold as an individual dwelling unit. As to condominium conversions, this title does not apply to or does not supersede any other statutory or common law. A deficiency under this section must materially affect the habitability or usefulness of the dwelling unit and be a result of a failure to meet the standard of care. (a) With respect to water issues:(1) A door shall not allow unintended water to pass beyond, around, or through the door or its designed or actual moisture barriers, if any.(2) Windows, patio doors, deck doors, and their systems shall not allow water to pass beyond, around, or through the window, patio door, or deck door or its designed or actual moisture barriers, including, without limitation, internal barriers within the systems themselves. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any.(3) Windows, patio doors, deck doors, and their systems shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any.(4) Roofs, roofing systems, chimney caps, and ventilation components shall not allow water to enter the structure or to pass beyond, around, or through the designed or actual moisture barriers, including, without limitation, internal barriers located within the systems themselves. For purposes of this paragraph, systems include, without limitation, framing, substrate, and sheathing, if any.(5) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow water to pass into the adjacent structure. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any.(6) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow unintended water to pass within the systems themselves and cause damage to the systems. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any.(7) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to cause damage to another building component.(8) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to limit the installation of the type of flooring materials typically used for the particular application.(9) Hardscape, including paths and patios, irrigation systems, landscaping systems, and drainage systems, that are installed as part of the original construction, shall not be installed in such a way as to cause water or soil erosion to enter into or come in contact with the structure so as to cause damage to another building component.(10) Stucco, exterior siding, exterior walls, including, without limitation, exterior framing, and other exterior wall finishes and fixtures and the systems of those components and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall be installed in such a way so as not to allow unintended water to pass into the structure or to pass beyond, around, or through the designed or actual moisture barriers of the system, including any internal barriers located within the system itself. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any.(11) Stucco, exterior siding, and exterior walls shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any.(12) Retaining and site walls and their associated drainage systems shall not allow unintended water to pass beyond, around, or through its designed or actual moisture barriers including, without limitation, any internal barriers, so as to cause damage. This standard does not apply to those portions of any wall or drainage system that are designed to have water flow beyond, around, or through them.(13) Retaining walls and site walls, and their associated drainage systems, shall only allow water to flow beyond, around, or through the areas designated by design.(14) The lines and components of the plumbing system, sewer system, and utility systems shall not leak.(15) Plumbing lines, sewer lines, and utility lines shall not corrode so as to impede the useful life of the systems.(16) Sewer systems shall be installed in such a way as to allow the designated amount of sewage to flow through the system.(17) Showers, baths, and related waterproofing systems shall not leak water into the interior of walls, flooring systems, or the interior of other components.(18) The waterproofing system behind or under ceramic tile and tile countertops shall not allow water into the interior of walls, flooring systems, or other components so as to cause damage. Ceramic tile systems shall be designed and installed so as to deflect intended water to the waterproofing system.(b) With respect to structural issues:(1) Foundations, load bearing components, and slabs, shall not contain significant cracks or significant vertical displacement.(2) Foundations, load bearing components, and slabs shall not cause the structure, in whole or in part, to be structurally unsafe.(3) Foundations, load bearing components, and slabs, and underlying soils shall be constructed so as to materially comply with the design criteria set by applicable government building codes, regulations, and ordinances for chemical deterioration or corrosion resistance in effect at the time of original construction.(4) A structure shall be constructed so as to materially comply with the design criteria for earthquake and wind load resistance, as set forth in the applicable government building codes, regulations, and ordinances in effect at the time of original construction.(c) With respect to soil issues:(1) Soils and engineered retaining walls shall not cause, in whole or in part, damage to the structure built upon the soil or engineered retaining wall.(2) Soils and engineered retaining walls shall not cause, in whole or in part, the structure to be structurally unsafe.(3) Soils shall not cause, in whole or in part, the land upon which no structure is built to become unusable for the purpose represented at the time of original sale by the builder or for the purpose for which that land is commonly used.(d) With respect to fire protection issues:(1) A structure shall be constructed so as to materially comply with the design criteria of the applicable government building codes, regulations, and ordinances for fire protection of the occupants in effect at the time of the original construction.(2) Fireplaces, chimneys, chimney structures, and chimney termination caps shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire outside the fireplace enclosure or chimney.(3) Electrical and mechanical systems shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire.(e) With respect to plumbing and sewer issues:Plumbing and sewer systems shall be installed to operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action may be brought for a violation of this subdivision more than four years after close of escrow.(f) With respect to electrical system issues:Electrical systems shall operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action shall be brought pursuant to this subdivision more than four years from close of escrow.(g) With respect to issues regarding other areas of construction:(1) Exterior pathways, driveways, hardscape, sidewalls, sidewalks, and patios installed by the original builder shall not contain cracks that display significant vertical displacement or that are excessive. However, no action shall be brought upon a violation of this paragraph more than four years from close of escrow.(2) Stucco, exterior siding, and other exterior wall finishes and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall not contain significant cracks or separations.(3) (A) To the extent not otherwise covered by these standards, manufactured products, including, but not limited to, windows, doors, roofs, plumbing products and fixtures, fireplaces, electrical fixtures, HVAC units, countertops, cabinets, paint, and appliances shall be installed so as not to interfere with the products useful life, if any.(B) For purposes of this paragraph, useful life means a representation of how long a product is warranted or represented, through its limited warranty or any written representations, to last by its manufacturer, including recommended or required maintenance. If there is no representation by a manufacturer, a builder shall install manufactured products so as not to interfere with the products utility.(C) For purposes of this paragraph, manufactured product means a product that is completely manufactured offsite.(D) If no useful life representation is made, or if the representation is less than one year, the period shall be no less than one year. If a manufactured product is damaged as a result of a violation of these standards, damage to the product is a recoverable element of damages. This subparagraph does not limit recovery if there has been damage to another building component caused by a manufactured product during the manufactured products useful life. A builder is not strictly liable for damage to a manufactured product if the builder exercised the proper standard of care in the installation and the damage does not materially affect the habitability or usefulness of the dwelling unit.(E) This title does not apply in any action seeking recovery solely for a defect in a manufactured product located within or adjacent to a structure.(4) Heating shall be installed so as to be capable of maintaining a room temperature of 70 degrees Fahrenheit at a point three feet above the floor in any living space if the heating was installed pursuant to a building permit application submitted prior to January 1, 2008, or capable of maintaining a room temperature of 68 degrees Fahrenheit at a point three feet above the floor and two feet from exterior walls in all habitable rooms at the design temperature if the heating was installed pursuant to a building permit application submitted on or before January 1, 2008.(5) Living space air-conditioning, if any, shall be provided in a manner consistent with the size and efficiency design criteria specified in Title 24 of the California Code of Regulations or its successor.(6) Attached structures shall be constructed to comply with interunit noise transmission standards set by the applicable government building codes, ordinances, or regulations in effect at the time of the original construction. If there is no applicable code, ordinance, or regulation, this paragraph does not apply. However, no action shall be brought pursuant to this paragraph more than one year from the original occupancy of the adjacent unit.(7) Irrigation systems and drainage shall operate properly so as not to damage landscaping or other external improvements. However, no action shall be brought pursuant to this paragraph more than one year from close of escrow.(8) Untreated wood posts shall not be installed in contact with soil so as to cause unreasonable decay to the wood based upon the finish grade at the time of original construction. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(9) Untreated steel fences and adjacent components shall be installed so as to prevent unreasonable corrosion. However, no action shall be brought pursuant to this paragraph more than four years from close of escrow.(10) Paint and stains shall be applied in such a manner so as not to cause deterioration of the building surfaces for the length of time specified by the paint or stain manufacturers representations, if any. However, no action shall be brought pursuant to this paragraph more than five years from close of escrow.(11) Roofing materials shall be installed so as to avoid materials falling from the roof.(12) The landscaping systems shall be installed in such a manner so as to survive for not less than one year. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(13) Ceramic tile and tile backing shall be installed in such a manner that the tile does not detach.(14) Dryer ducts shall be installed and terminated pursuant to manufacturer installation requirements. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(15) Structures shall be constructed in such a manner so as not to impair the occupants safety because they contain public health hazards as determined by a duly authorized public health official, health agency, or governmental entity having jurisdiction. This paragraph does not limit recovery for any damages caused by a violation of any other paragraph of this section on the grounds that the damages do not constitute a health hazard. |
|---|
| 109 | 109 | | |
|---|
| 110 | 110 | | SEC. 2. Section 896 of the Civil Code is amended to read: |
|---|
| 111 | 111 | | |
|---|
| 112 | 112 | | ### SEC. 2. |
|---|
| 113 | 113 | | |
|---|
| 114 | 114 | | 896. In any action seeking recovery of damages arising out of, or related to deficiencies in, the residential construction, design, specifications, surveying, planning, supervision, testing, or observation of construction, a builder, and to the extent set forth in Chapter 4 (commencing with Section 910), a general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, shall, except as specifically set forth in this title, be liable for, and the claimants claims or causes of action shall be limited to violation of, the following standards, except as specifically set forth in this title. This title applies to original construction intended to be sold as an individual dwelling unit. As to condominium conversions, this title does not apply to or does not supersede any other statutory or common law. A deficiency under this section must materially affect the habitability or usefulness of the dwelling unit and be a result of a failure to meet the standard of care. (a) With respect to water issues:(1) A door shall not allow unintended water to pass beyond, around, or through the door or its designed or actual moisture barriers, if any.(2) Windows, patio doors, deck doors, and their systems shall not allow water to pass beyond, around, or through the window, patio door, or deck door or its designed or actual moisture barriers, including, without limitation, internal barriers within the systems themselves. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any.(3) Windows, patio doors, deck doors, and their systems shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any.(4) Roofs, roofing systems, chimney caps, and ventilation components shall not allow water to enter the structure or to pass beyond, around, or through the designed or actual moisture barriers, including, without limitation, internal barriers located within the systems themselves. For purposes of this paragraph, systems include, without limitation, framing, substrate, and sheathing, if any.(5) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow water to pass into the adjacent structure. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any.(6) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow unintended water to pass within the systems themselves and cause damage to the systems. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any.(7) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to cause damage to another building component.(8) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to limit the installation of the type of flooring materials typically used for the particular application.(9) Hardscape, including paths and patios, irrigation systems, landscaping systems, and drainage systems, that are installed as part of the original construction, shall not be installed in such a way as to cause water or soil erosion to enter into or come in contact with the structure so as to cause damage to another building component.(10) Stucco, exterior siding, exterior walls, including, without limitation, exterior framing, and other exterior wall finishes and fixtures and the systems of those components and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall be installed in such a way so as not to allow unintended water to pass into the structure or to pass beyond, around, or through the designed or actual moisture barriers of the system, including any internal barriers located within the system itself. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any.(11) Stucco, exterior siding, and exterior walls shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any.(12) Retaining and site walls and their associated drainage systems shall not allow unintended water to pass beyond, around, or through its designed or actual moisture barriers including, without limitation, any internal barriers, so as to cause damage. This standard does not apply to those portions of any wall or drainage system that are designed to have water flow beyond, around, or through them.(13) Retaining walls and site walls, and their associated drainage systems, shall only allow water to flow beyond, around, or through the areas designated by design.(14) The lines and components of the plumbing system, sewer system, and utility systems shall not leak.(15) Plumbing lines, sewer lines, and utility lines shall not corrode so as to impede the useful life of the systems.(16) Sewer systems shall be installed in such a way as to allow the designated amount of sewage to flow through the system.(17) Showers, baths, and related waterproofing systems shall not leak water into the interior of walls, flooring systems, or the interior of other components.(18) The waterproofing system behind or under ceramic tile and tile countertops shall not allow water into the interior of walls, flooring systems, or other components so as to cause damage. Ceramic tile systems shall be designed and installed so as to deflect intended water to the waterproofing system.(b) With respect to structural issues:(1) Foundations, load bearing components, and slabs, shall not contain significant cracks or significant vertical displacement.(2) Foundations, load bearing components, and slabs shall not cause the structure, in whole or in part, to be structurally unsafe.(3) Foundations, load bearing components, and slabs, and underlying soils shall be constructed so as to materially comply with the design criteria set by applicable government building codes, regulations, and ordinances for chemical deterioration or corrosion resistance in effect at the time of original construction.(4) A structure shall be constructed so as to materially comply with the design criteria for earthquake and wind load resistance, as set forth in the applicable government building codes, regulations, and ordinances in effect at the time of original construction.(c) With respect to soil issues:(1) Soils and engineered retaining walls shall not cause, in whole or in part, damage to the structure built upon the soil or engineered retaining wall.(2) Soils and engineered retaining walls shall not cause, in whole or in part, the structure to be structurally unsafe.(3) Soils shall not cause, in whole or in part, the land upon which no structure is built to become unusable for the purpose represented at the time of original sale by the builder or for the purpose for which that land is commonly used.(d) With respect to fire protection issues:(1) A structure shall be constructed so as to materially comply with the design criteria of the applicable government building codes, regulations, and ordinances for fire protection of the occupants in effect at the time of the original construction.(2) Fireplaces, chimneys, chimney structures, and chimney termination caps shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire outside the fireplace enclosure or chimney.(3) Electrical and mechanical systems shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire.(e) With respect to plumbing and sewer issues:Plumbing and sewer systems shall be installed to operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action may be brought for a violation of this subdivision more than four years after close of escrow.(f) With respect to electrical system issues:Electrical systems shall operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action shall be brought pursuant to this subdivision more than four years from close of escrow.(g) With respect to issues regarding other areas of construction:(1) Exterior pathways, driveways, hardscape, sidewalls, sidewalks, and patios installed by the original builder shall not contain cracks that display significant vertical displacement or that are excessive. However, no action shall be brought upon a violation of this paragraph more than four years from close of escrow.(2) Stucco, exterior siding, and other exterior wall finishes and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall not contain significant cracks or separations.(3) (A) To the extent not otherwise covered by these standards, manufactured products, including, but not limited to, windows, doors, roofs, plumbing products and fixtures, fireplaces, electrical fixtures, HVAC units, countertops, cabinets, paint, and appliances shall be installed so as not to interfere with the products useful life, if any.(B) For purposes of this paragraph, useful life means a representation of how long a product is warranted or represented, through its limited warranty or any written representations, to last by its manufacturer, including recommended or required maintenance. If there is no representation by a manufacturer, a builder shall install manufactured products so as not to interfere with the products utility.(C) For purposes of this paragraph, manufactured product means a product that is completely manufactured offsite.(D) If no useful life representation is made, or if the representation is less than one year, the period shall be no less than one year. If a manufactured product is damaged as a result of a violation of these standards, damage to the product is a recoverable element of damages. This subparagraph does not limit recovery if there has been damage to another building component caused by a manufactured product during the manufactured products useful life. A builder is not strictly liable for damage to a manufactured product if the builder exercised the proper standard of care in the installation and the damage does not materially affect the habitability or usefulness of the dwelling unit.(E) This title does not apply in any action seeking recovery solely for a defect in a manufactured product located within or adjacent to a structure.(4) Heating shall be installed so as to be capable of maintaining a room temperature of 70 degrees Fahrenheit at a point three feet above the floor in any living space if the heating was installed pursuant to a building permit application submitted prior to January 1, 2008, or capable of maintaining a room temperature of 68 degrees Fahrenheit at a point three feet above the floor and two feet from exterior walls in all habitable rooms at the design temperature if the heating was installed pursuant to a building permit application submitted on or before January 1, 2008.(5) Living space air-conditioning, if any, shall be provided in a manner consistent with the size and efficiency design criteria specified in Title 24 of the California Code of Regulations or its successor.(6) Attached structures shall be constructed to comply with interunit noise transmission standards set by the applicable government building codes, ordinances, or regulations in effect at the time of the original construction. If there is no applicable code, ordinance, or regulation, this paragraph does not apply. However, no action shall be brought pursuant to this paragraph more than one year from the original occupancy of the adjacent unit.(7) Irrigation systems and drainage shall operate properly so as not to damage landscaping or other external improvements. However, no action shall be brought pursuant to this paragraph more than one year from close of escrow.(8) Untreated wood posts shall not be installed in contact with soil so as to cause unreasonable decay to the wood based upon the finish grade at the time of original construction. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(9) Untreated steel fences and adjacent components shall be installed so as to prevent unreasonable corrosion. However, no action shall be brought pursuant to this paragraph more than four years from close of escrow.(10) Paint and stains shall be applied in such a manner so as not to cause deterioration of the building surfaces for the length of time specified by the paint or stain manufacturers representations, if any. However, no action shall be brought pursuant to this paragraph more than five years from close of escrow.(11) Roofing materials shall be installed so as to avoid materials falling from the roof.(12) The landscaping systems shall be installed in such a manner so as to survive for not less than one year. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(13) Ceramic tile and tile backing shall be installed in such a manner that the tile does not detach.(14) Dryer ducts shall be installed and terminated pursuant to manufacturer installation requirements. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(15) Structures shall be constructed in such a manner so as not to impair the occupants safety because they contain public health hazards as determined by a duly authorized public health official, health agency, or governmental entity having jurisdiction. This paragraph does not limit recovery for any damages caused by a violation of any other paragraph of this section on the grounds that the damages do not constitute a health hazard. |
|---|
| 115 | 115 | | |
|---|
| 116 | 116 | | 896. In any action seeking recovery of damages arising out of, or related to deficiencies in, the residential construction, design, specifications, surveying, planning, supervision, testing, or observation of construction, a builder, and to the extent set forth in Chapter 4 (commencing with Section 910), a general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, shall, except as specifically set forth in this title, be liable for, and the claimants claims or causes of action shall be limited to violation of, the following standards, except as specifically set forth in this title. This title applies to original construction intended to be sold as an individual dwelling unit. As to condominium conversions, this title does not apply to or does not supersede any other statutory or common law. A deficiency under this section must materially affect the habitability or usefulness of the dwelling unit and be a result of a failure to meet the standard of care. (a) With respect to water issues:(1) A door shall not allow unintended water to pass beyond, around, or through the door or its designed or actual moisture barriers, if any.(2) Windows, patio doors, deck doors, and their systems shall not allow water to pass beyond, around, or through the window, patio door, or deck door or its designed or actual moisture barriers, including, without limitation, internal barriers within the systems themselves. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any.(3) Windows, patio doors, deck doors, and their systems shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any.(4) Roofs, roofing systems, chimney caps, and ventilation components shall not allow water to enter the structure or to pass beyond, around, or through the designed or actual moisture barriers, including, without limitation, internal barriers located within the systems themselves. For purposes of this paragraph, systems include, without limitation, framing, substrate, and sheathing, if any.(5) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow water to pass into the adjacent structure. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any.(6) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow unintended water to pass within the systems themselves and cause damage to the systems. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any.(7) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to cause damage to another building component.(8) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to limit the installation of the type of flooring materials typically used for the particular application.(9) Hardscape, including paths and patios, irrigation systems, landscaping systems, and drainage systems, that are installed as part of the original construction, shall not be installed in such a way as to cause water or soil erosion to enter into or come in contact with the structure so as to cause damage to another building component.(10) Stucco, exterior siding, exterior walls, including, without limitation, exterior framing, and other exterior wall finishes and fixtures and the systems of those components and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall be installed in such a way so as not to allow unintended water to pass into the structure or to pass beyond, around, or through the designed or actual moisture barriers of the system, including any internal barriers located within the system itself. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any.(11) Stucco, exterior siding, and exterior walls shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any.(12) Retaining and site walls and their associated drainage systems shall not allow unintended water to pass beyond, around, or through its designed or actual moisture barriers including, without limitation, any internal barriers, so as to cause damage. This standard does not apply to those portions of any wall or drainage system that are designed to have water flow beyond, around, or through them.(13) Retaining walls and site walls, and their associated drainage systems, shall only allow water to flow beyond, around, or through the areas designated by design.(14) The lines and components of the plumbing system, sewer system, and utility systems shall not leak.(15) Plumbing lines, sewer lines, and utility lines shall not corrode so as to impede the useful life of the systems.(16) Sewer systems shall be installed in such a way as to allow the designated amount of sewage to flow through the system.(17) Showers, baths, and related waterproofing systems shall not leak water into the interior of walls, flooring systems, or the interior of other components.(18) The waterproofing system behind or under ceramic tile and tile countertops shall not allow water into the interior of walls, flooring systems, or other components so as to cause damage. Ceramic tile systems shall be designed and installed so as to deflect intended water to the waterproofing system.(b) With respect to structural issues:(1) Foundations, load bearing components, and slabs, shall not contain significant cracks or significant vertical displacement.(2) Foundations, load bearing components, and slabs shall not cause the structure, in whole or in part, to be structurally unsafe.(3) Foundations, load bearing components, and slabs, and underlying soils shall be constructed so as to materially comply with the design criteria set by applicable government building codes, regulations, and ordinances for chemical deterioration or corrosion resistance in effect at the time of original construction.(4) A structure shall be constructed so as to materially comply with the design criteria for earthquake and wind load resistance, as set forth in the applicable government building codes, regulations, and ordinances in effect at the time of original construction.(c) With respect to soil issues:(1) Soils and engineered retaining walls shall not cause, in whole or in part, damage to the structure built upon the soil or engineered retaining wall.(2) Soils and engineered retaining walls shall not cause, in whole or in part, the structure to be structurally unsafe.(3) Soils shall not cause, in whole or in part, the land upon which no structure is built to become unusable for the purpose represented at the time of original sale by the builder or for the purpose for which that land is commonly used.(d) With respect to fire protection issues:(1) A structure shall be constructed so as to materially comply with the design criteria of the applicable government building codes, regulations, and ordinances for fire protection of the occupants in effect at the time of the original construction.(2) Fireplaces, chimneys, chimney structures, and chimney termination caps shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire outside the fireplace enclosure or chimney.(3) Electrical and mechanical systems shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire.(e) With respect to plumbing and sewer issues:Plumbing and sewer systems shall be installed to operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action may be brought for a violation of this subdivision more than four years after close of escrow.(f) With respect to electrical system issues:Electrical systems shall operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action shall be brought pursuant to this subdivision more than four years from close of escrow.(g) With respect to issues regarding other areas of construction:(1) Exterior pathways, driveways, hardscape, sidewalls, sidewalks, and patios installed by the original builder shall not contain cracks that display significant vertical displacement or that are excessive. However, no action shall be brought upon a violation of this paragraph more than four years from close of escrow.(2) Stucco, exterior siding, and other exterior wall finishes and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall not contain significant cracks or separations.(3) (A) To the extent not otherwise covered by these standards, manufactured products, including, but not limited to, windows, doors, roofs, plumbing products and fixtures, fireplaces, electrical fixtures, HVAC units, countertops, cabinets, paint, and appliances shall be installed so as not to interfere with the products useful life, if any.(B) For purposes of this paragraph, useful life means a representation of how long a product is warranted or represented, through its limited warranty or any written representations, to last by its manufacturer, including recommended or required maintenance. If there is no representation by a manufacturer, a builder shall install manufactured products so as not to interfere with the products utility.(C) For purposes of this paragraph, manufactured product means a product that is completely manufactured offsite.(D) If no useful life representation is made, or if the representation is less than one year, the period shall be no less than one year. If a manufactured product is damaged as a result of a violation of these standards, damage to the product is a recoverable element of damages. This subparagraph does not limit recovery if there has been damage to another building component caused by a manufactured product during the manufactured products useful life. A builder is not strictly liable for damage to a manufactured product if the builder exercised the proper standard of care in the installation and the damage does not materially affect the habitability or usefulness of the dwelling unit.(E) This title does not apply in any action seeking recovery solely for a defect in a manufactured product located within or adjacent to a structure.(4) Heating shall be installed so as to be capable of maintaining a room temperature of 70 degrees Fahrenheit at a point three feet above the floor in any living space if the heating was installed pursuant to a building permit application submitted prior to January 1, 2008, or capable of maintaining a room temperature of 68 degrees Fahrenheit at a point three feet above the floor and two feet from exterior walls in all habitable rooms at the design temperature if the heating was installed pursuant to a building permit application submitted on or before January 1, 2008.(5) Living space air-conditioning, if any, shall be provided in a manner consistent with the size and efficiency design criteria specified in Title 24 of the California Code of Regulations or its successor.(6) Attached structures shall be constructed to comply with interunit noise transmission standards set by the applicable government building codes, ordinances, or regulations in effect at the time of the original construction. If there is no applicable code, ordinance, or regulation, this paragraph does not apply. However, no action shall be brought pursuant to this paragraph more than one year from the original occupancy of the adjacent unit.(7) Irrigation systems and drainage shall operate properly so as not to damage landscaping or other external improvements. However, no action shall be brought pursuant to this paragraph more than one year from close of escrow.(8) Untreated wood posts shall not be installed in contact with soil so as to cause unreasonable decay to the wood based upon the finish grade at the time of original construction. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(9) Untreated steel fences and adjacent components shall be installed so as to prevent unreasonable corrosion. However, no action shall be brought pursuant to this paragraph more than four years from close of escrow.(10) Paint and stains shall be applied in such a manner so as not to cause deterioration of the building surfaces for the length of time specified by the paint or stain manufacturers representations, if any. However, no action shall be brought pursuant to this paragraph more than five years from close of escrow.(11) Roofing materials shall be installed so as to avoid materials falling from the roof.(12) The landscaping systems shall be installed in such a manner so as to survive for not less than one year. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(13) Ceramic tile and tile backing shall be installed in such a manner that the tile does not detach.(14) Dryer ducts shall be installed and terminated pursuant to manufacturer installation requirements. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(15) Structures shall be constructed in such a manner so as not to impair the occupants safety because they contain public health hazards as determined by a duly authorized public health official, health agency, or governmental entity having jurisdiction. This paragraph does not limit recovery for any damages caused by a violation of any other paragraph of this section on the grounds that the damages do not constitute a health hazard. |
|---|
| 117 | 117 | | |
|---|
| 118 | 118 | | 896. In any action seeking recovery of damages arising out of, or related to deficiencies in, the residential construction, design, specifications, surveying, planning, supervision, testing, or observation of construction, a builder, and to the extent set forth in Chapter 4 (commencing with Section 910), a general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, shall, except as specifically set forth in this title, be liable for, and the claimants claims or causes of action shall be limited to violation of, the following standards, except as specifically set forth in this title. This title applies to original construction intended to be sold as an individual dwelling unit. As to condominium conversions, this title does not apply to or does not supersede any other statutory or common law. A deficiency under this section must materially affect the habitability or usefulness of the dwelling unit and be a result of a failure to meet the standard of care. (a) With respect to water issues:(1) A door shall not allow unintended water to pass beyond, around, or through the door or its designed or actual moisture barriers, if any.(2) Windows, patio doors, deck doors, and their systems shall not allow water to pass beyond, around, or through the window, patio door, or deck door or its designed or actual moisture barriers, including, without limitation, internal barriers within the systems themselves. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any.(3) Windows, patio doors, deck doors, and their systems shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any.(4) Roofs, roofing systems, chimney caps, and ventilation components shall not allow water to enter the structure or to pass beyond, around, or through the designed or actual moisture barriers, including, without limitation, internal barriers located within the systems themselves. For purposes of this paragraph, systems include, without limitation, framing, substrate, and sheathing, if any.(5) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow water to pass into the adjacent structure. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any.(6) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow unintended water to pass within the systems themselves and cause damage to the systems. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any.(7) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to cause damage to another building component.(8) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to limit the installation of the type of flooring materials typically used for the particular application.(9) Hardscape, including paths and patios, irrigation systems, landscaping systems, and drainage systems, that are installed as part of the original construction, shall not be installed in such a way as to cause water or soil erosion to enter into or come in contact with the structure so as to cause damage to another building component.(10) Stucco, exterior siding, exterior walls, including, without limitation, exterior framing, and other exterior wall finishes and fixtures and the systems of those components and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall be installed in such a way so as not to allow unintended water to pass into the structure or to pass beyond, around, or through the designed or actual moisture barriers of the system, including any internal barriers located within the system itself. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any.(11) Stucco, exterior siding, and exterior walls shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any.(12) Retaining and site walls and their associated drainage systems shall not allow unintended water to pass beyond, around, or through its designed or actual moisture barriers including, without limitation, any internal barriers, so as to cause damage. This standard does not apply to those portions of any wall or drainage system that are designed to have water flow beyond, around, or through them.(13) Retaining walls and site walls, and their associated drainage systems, shall only allow water to flow beyond, around, or through the areas designated by design.(14) The lines and components of the plumbing system, sewer system, and utility systems shall not leak.(15) Plumbing lines, sewer lines, and utility lines shall not corrode so as to impede the useful life of the systems.(16) Sewer systems shall be installed in such a way as to allow the designated amount of sewage to flow through the system.(17) Showers, baths, and related waterproofing systems shall not leak water into the interior of walls, flooring systems, or the interior of other components.(18) The waterproofing system behind or under ceramic tile and tile countertops shall not allow water into the interior of walls, flooring systems, or other components so as to cause damage. Ceramic tile systems shall be designed and installed so as to deflect intended water to the waterproofing system.(b) With respect to structural issues:(1) Foundations, load bearing components, and slabs, shall not contain significant cracks or significant vertical displacement.(2) Foundations, load bearing components, and slabs shall not cause the structure, in whole or in part, to be structurally unsafe.(3) Foundations, load bearing components, and slabs, and underlying soils shall be constructed so as to materially comply with the design criteria set by applicable government building codes, regulations, and ordinances for chemical deterioration or corrosion resistance in effect at the time of original construction.(4) A structure shall be constructed so as to materially comply with the design criteria for earthquake and wind load resistance, as set forth in the applicable government building codes, regulations, and ordinances in effect at the time of original construction.(c) With respect to soil issues:(1) Soils and engineered retaining walls shall not cause, in whole or in part, damage to the structure built upon the soil or engineered retaining wall.(2) Soils and engineered retaining walls shall not cause, in whole or in part, the structure to be structurally unsafe.(3) Soils shall not cause, in whole or in part, the land upon which no structure is built to become unusable for the purpose represented at the time of original sale by the builder or for the purpose for which that land is commonly used.(d) With respect to fire protection issues:(1) A structure shall be constructed so as to materially comply with the design criteria of the applicable government building codes, regulations, and ordinances for fire protection of the occupants in effect at the time of the original construction.(2) Fireplaces, chimneys, chimney structures, and chimney termination caps shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire outside the fireplace enclosure or chimney.(3) Electrical and mechanical systems shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire.(e) With respect to plumbing and sewer issues:Plumbing and sewer systems shall be installed to operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action may be brought for a violation of this subdivision more than four years after close of escrow.(f) With respect to electrical system issues:Electrical systems shall operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action shall be brought pursuant to this subdivision more than four years from close of escrow.(g) With respect to issues regarding other areas of construction:(1) Exterior pathways, driveways, hardscape, sidewalls, sidewalks, and patios installed by the original builder shall not contain cracks that display significant vertical displacement or that are excessive. However, no action shall be brought upon a violation of this paragraph more than four years from close of escrow.(2) Stucco, exterior siding, and other exterior wall finishes and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall not contain significant cracks or separations.(3) (A) To the extent not otherwise covered by these standards, manufactured products, including, but not limited to, windows, doors, roofs, plumbing products and fixtures, fireplaces, electrical fixtures, HVAC units, countertops, cabinets, paint, and appliances shall be installed so as not to interfere with the products useful life, if any.(B) For purposes of this paragraph, useful life means a representation of how long a product is warranted or represented, through its limited warranty or any written representations, to last by its manufacturer, including recommended or required maintenance. If there is no representation by a manufacturer, a builder shall install manufactured products so as not to interfere with the products utility.(C) For purposes of this paragraph, manufactured product means a product that is completely manufactured offsite.(D) If no useful life representation is made, or if the representation is less than one year, the period shall be no less than one year. If a manufactured product is damaged as a result of a violation of these standards, damage to the product is a recoverable element of damages. This subparagraph does not limit recovery if there has been damage to another building component caused by a manufactured product during the manufactured products useful life. A builder is not strictly liable for damage to a manufactured product if the builder exercised the proper standard of care in the installation and the damage does not materially affect the habitability or usefulness of the dwelling unit.(E) This title does not apply in any action seeking recovery solely for a defect in a manufactured product located within or adjacent to a structure.(4) Heating shall be installed so as to be capable of maintaining a room temperature of 70 degrees Fahrenheit at a point three feet above the floor in any living space if the heating was installed pursuant to a building permit application submitted prior to January 1, 2008, or capable of maintaining a room temperature of 68 degrees Fahrenheit at a point three feet above the floor and two feet from exterior walls in all habitable rooms at the design temperature if the heating was installed pursuant to a building permit application submitted on or before January 1, 2008.(5) Living space air-conditioning, if any, shall be provided in a manner consistent with the size and efficiency design criteria specified in Title 24 of the California Code of Regulations or its successor.(6) Attached structures shall be constructed to comply with interunit noise transmission standards set by the applicable government building codes, ordinances, or regulations in effect at the time of the original construction. If there is no applicable code, ordinance, or regulation, this paragraph does not apply. However, no action shall be brought pursuant to this paragraph more than one year from the original occupancy of the adjacent unit.(7) Irrigation systems and drainage shall operate properly so as not to damage landscaping or other external improvements. However, no action shall be brought pursuant to this paragraph more than one year from close of escrow.(8) Untreated wood posts shall not be installed in contact with soil so as to cause unreasonable decay to the wood based upon the finish grade at the time of original construction. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(9) Untreated steel fences and adjacent components shall be installed so as to prevent unreasonable corrosion. However, no action shall be brought pursuant to this paragraph more than four years from close of escrow.(10) Paint and stains shall be applied in such a manner so as not to cause deterioration of the building surfaces for the length of time specified by the paint or stain manufacturers representations, if any. However, no action shall be brought pursuant to this paragraph more than five years from close of escrow.(11) Roofing materials shall be installed so as to avoid materials falling from the roof.(12) The landscaping systems shall be installed in such a manner so as to survive for not less than one year. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(13) Ceramic tile and tile backing shall be installed in such a manner that the tile does not detach.(14) Dryer ducts shall be installed and terminated pursuant to manufacturer installation requirements. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow.(15) Structures shall be constructed in such a manner so as not to impair the occupants safety because they contain public health hazards as determined by a duly authorized public health official, health agency, or governmental entity having jurisdiction. This paragraph does not limit recovery for any damages caused by a violation of any other paragraph of this section on the grounds that the damages do not constitute a health hazard. |
|---|
| 119 | 119 | | |
|---|
| 120 | 120 | | |
|---|
| 121 | 121 | | |
|---|
| 122 | 122 | | 896. In any action seeking recovery of damages arising out of, or related to deficiencies in, the residential construction, design, specifications, surveying, planning, supervision, testing, or observation of construction, a builder, and to the extent set forth in Chapter 4 (commencing with Section 910), a general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, shall, except as specifically set forth in this title, be liable for, and the claimants claims or causes of action shall be limited to violation of, the following standards, except as specifically set forth in this title. This title applies to original construction intended to be sold as an individual dwelling unit. As to condominium conversions, this title does not apply to or does not supersede any other statutory or common law. A deficiency under this section must materially affect the habitability or usefulness of the dwelling unit and be a result of a failure to meet the standard of care. |
|---|
| 123 | 123 | | |
|---|
| 124 | 124 | | (a) With respect to water issues: |
|---|
| 125 | 125 | | |
|---|
| 126 | 126 | | (1) A door shall not allow unintended water to pass beyond, around, or through the door or its designed or actual moisture barriers, if any. |
|---|
| 127 | 127 | | |
|---|
| 128 | 128 | | (2) Windows, patio doors, deck doors, and their systems shall not allow water to pass beyond, around, or through the window, patio door, or deck door or its designed or actual moisture barriers, including, without limitation, internal barriers within the systems themselves. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any. |
|---|
| 129 | 129 | | |
|---|
| 130 | 130 | | (3) Windows, patio doors, deck doors, and their systems shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, windows, window assemblies, framing, substrate, flashings, and trim, if any. |
|---|
| 131 | 131 | | |
|---|
| 132 | 132 | | (4) Roofs, roofing systems, chimney caps, and ventilation components shall not allow water to enter the structure or to pass beyond, around, or through the designed or actual moisture barriers, including, without limitation, internal barriers located within the systems themselves. For purposes of this paragraph, systems include, without limitation, framing, substrate, and sheathing, if any. |
|---|
| 133 | 133 | | |
|---|
| 134 | 134 | | (5) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow water to pass into the adjacent structure. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any. |
|---|
| 135 | 135 | | |
|---|
| 136 | 136 | | (6) Decks, deck systems, balconies, balcony systems, exterior stairs, and stair systems shall not allow unintended water to pass within the systems themselves and cause damage to the systems. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashing, and sheathing, if any. |
|---|
| 137 | 137 | | |
|---|
| 138 | 138 | | (7) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to cause damage to another building component. |
|---|
| 139 | 139 | | |
|---|
| 140 | 140 | | (8) Foundation systems and slabs shall not allow water or vapor to enter into the structure so as to limit the installation of the type of flooring materials typically used for the particular application. |
|---|
| 141 | 141 | | |
|---|
| 142 | 142 | | (9) Hardscape, including paths and patios, irrigation systems, landscaping systems, and drainage systems, that are installed as part of the original construction, shall not be installed in such a way as to cause water or soil erosion to enter into or come in contact with the structure so as to cause damage to another building component. |
|---|
| 143 | 143 | | |
|---|
| 144 | 144 | | (10) Stucco, exterior siding, exterior walls, including, without limitation, exterior framing, and other exterior wall finishes and fixtures and the systems of those components and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall be installed in such a way so as not to allow unintended water to pass into the structure or to pass beyond, around, or through the designed or actual moisture barriers of the system, including any internal barriers located within the system itself. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any. |
|---|
| 145 | 145 | | |
|---|
| 146 | 146 | | (11) Stucco, exterior siding, and exterior walls shall not allow excessive condensation to enter the structure and cause damage to another component. For purposes of this paragraph, systems include, without limitation, framing, substrate, flashings, trim, wall assemblies, and internal wall cavities, if any. |
|---|
| 147 | 147 | | |
|---|
| 148 | 148 | | (12) Retaining and site walls and their associated drainage systems shall not allow unintended water to pass beyond, around, or through its designed or actual moisture barriers including, without limitation, any internal barriers, so as to cause damage. This standard does not apply to those portions of any wall or drainage system that are designed to have water flow beyond, around, or through them. |
|---|
| 149 | 149 | | |
|---|
| 150 | 150 | | (13) Retaining walls and site walls, and their associated drainage systems, shall only allow water to flow beyond, around, or through the areas designated by design. |
|---|
| 151 | 151 | | |
|---|
| 152 | 152 | | (14) The lines and components of the plumbing system, sewer system, and utility systems shall not leak. |
|---|
| 153 | 153 | | |
|---|
| 154 | 154 | | (15) Plumbing lines, sewer lines, and utility lines shall not corrode so as to impede the useful life of the systems. |
|---|
| 155 | 155 | | |
|---|
| 156 | 156 | | (16) Sewer systems shall be installed in such a way as to allow the designated amount of sewage to flow through the system. |
|---|
| 157 | 157 | | |
|---|
| 158 | 158 | | (17) Showers, baths, and related waterproofing systems shall not leak water into the interior of walls, flooring systems, or the interior of other components. |
|---|
| 159 | 159 | | |
|---|
| 160 | 160 | | (18) The waterproofing system behind or under ceramic tile and tile countertops shall not allow water into the interior of walls, flooring systems, or other components so as to cause damage. Ceramic tile systems shall be designed and installed so as to deflect intended water to the waterproofing system. |
|---|
| 161 | 161 | | |
|---|
| 162 | 162 | | (b) With respect to structural issues: |
|---|
| 163 | 163 | | |
|---|
| 164 | 164 | | (1) Foundations, load bearing components, and slabs, shall not contain significant cracks or significant vertical displacement. |
|---|
| 165 | 165 | | |
|---|
| 166 | 166 | | (2) Foundations, load bearing components, and slabs shall not cause the structure, in whole or in part, to be structurally unsafe. |
|---|
| 167 | 167 | | |
|---|
| 168 | 168 | | (3) Foundations, load bearing components, and slabs, and underlying soils shall be constructed so as to materially comply with the design criteria set by applicable government building codes, regulations, and ordinances for chemical deterioration or corrosion resistance in effect at the time of original construction. |
|---|
| 169 | 169 | | |
|---|
| 170 | 170 | | (4) A structure shall be constructed so as to materially comply with the design criteria for earthquake and wind load resistance, as set forth in the applicable government building codes, regulations, and ordinances in effect at the time of original construction. |
|---|
| 171 | 171 | | |
|---|
| 172 | 172 | | (c) With respect to soil issues: |
|---|
| 173 | 173 | | |
|---|
| 174 | 174 | | (1) Soils and engineered retaining walls shall not cause, in whole or in part, damage to the structure built upon the soil or engineered retaining wall. |
|---|
| 175 | 175 | | |
|---|
| 176 | 176 | | (2) Soils and engineered retaining walls shall not cause, in whole or in part, the structure to be structurally unsafe. |
|---|
| 177 | 177 | | |
|---|
| 178 | 178 | | (3) Soils shall not cause, in whole or in part, the land upon which no structure is built to become unusable for the purpose represented at the time of original sale by the builder or for the purpose for which that land is commonly used. |
|---|
| 179 | 179 | | |
|---|
| 180 | 180 | | (d) With respect to fire protection issues: |
|---|
| 181 | 181 | | |
|---|
| 182 | 182 | | (1) A structure shall be constructed so as to materially comply with the design criteria of the applicable government building codes, regulations, and ordinances for fire protection of the occupants in effect at the time of the original construction. |
|---|
| 183 | 183 | | |
|---|
| 184 | 184 | | (2) Fireplaces, chimneys, chimney structures, and chimney termination caps shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire outside the fireplace enclosure or chimney. |
|---|
| 185 | 185 | | |
|---|
| 186 | 186 | | (3) Electrical and mechanical systems shall be constructed and installed in such a way so as not to cause an unreasonable risk of fire. |
|---|
| 187 | 187 | | |
|---|
| 188 | 188 | | (e) With respect to plumbing and sewer issues: |
|---|
| 189 | 189 | | |
|---|
| 190 | 190 | | Plumbing and sewer systems shall be installed to operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action may be brought for a violation of this subdivision more than four years after close of escrow. |
|---|
| 191 | 191 | | |
|---|
| 192 | 192 | | (f) With respect to electrical system issues: |
|---|
| 193 | 193 | | |
|---|
| 194 | 194 | | Electrical systems shall operate properly and shall not materially impair the use of the structure by its inhabitants. However, no action shall be brought pursuant to this subdivision more than four years from close of escrow. |
|---|
| 195 | 195 | | |
|---|
| 196 | 196 | | (g) With respect to issues regarding other areas of construction: |
|---|
| 197 | 197 | | |
|---|
| 198 | 198 | | (1) Exterior pathways, driveways, hardscape, sidewalls, sidewalks, and patios installed by the original builder shall not contain cracks that display significant vertical displacement or that are excessive. However, no action shall be brought upon a violation of this paragraph more than four years from close of escrow. |
|---|
| 199 | 199 | | |
|---|
| 200 | 200 | | (2) Stucco, exterior siding, and other exterior wall finishes and fixtures, including, but not limited to, pot shelves, horizontal surfaces, columns, and plant-ons, shall not contain significant cracks or separations. |
|---|
| 201 | 201 | | |
|---|
| 202 | 202 | | (3) (A) To the extent not otherwise covered by these standards, manufactured products, including, but not limited to, windows, doors, roofs, plumbing products and fixtures, fireplaces, electrical fixtures, HVAC units, countertops, cabinets, paint, and appliances shall be installed so as not to interfere with the products useful life, if any. |
|---|
| 203 | 203 | | |
|---|
| 204 | 204 | | (B) For purposes of this paragraph, useful life means a representation of how long a product is warranted or represented, through its limited warranty or any written representations, to last by its manufacturer, including recommended or required maintenance. If there is no representation by a manufacturer, a builder shall install manufactured products so as not to interfere with the products utility. |
|---|
| 205 | 205 | | |
|---|
| 206 | 206 | | (C) For purposes of this paragraph, manufactured product means a product that is completely manufactured offsite. |
|---|
| 207 | 207 | | |
|---|
| 208 | 208 | | (D) If no useful life representation is made, or if the representation is less than one year, the period shall be no less than one year. If a manufactured product is damaged as a result of a violation of these standards, damage to the product is a recoverable element of damages. This subparagraph does not limit recovery if there has been damage to another building component caused by a manufactured product during the manufactured products useful life. A builder is not strictly liable for damage to a manufactured product if the builder exercised the proper standard of care in the installation and the damage does not materially affect the habitability or usefulness of the dwelling unit. |
|---|
| 209 | 209 | | |
|---|
| 210 | 210 | | (E) This title does not apply in any action seeking recovery solely for a defect in a manufactured product located within or adjacent to a structure. |
|---|
| 211 | 211 | | |
|---|
| 212 | 212 | | (4) Heating shall be installed so as to be capable of maintaining a room temperature of 70 degrees Fahrenheit at a point three feet above the floor in any living space if the heating was installed pursuant to a building permit application submitted prior to January 1, 2008, or capable of maintaining a room temperature of 68 degrees Fahrenheit at a point three feet above the floor and two feet from exterior walls in all habitable rooms at the design temperature if the heating was installed pursuant to a building permit application submitted on or before January 1, 2008. |
|---|
| 213 | 213 | | |
|---|
| 214 | 214 | | (5) Living space air-conditioning, if any, shall be provided in a manner consistent with the size and efficiency design criteria specified in Title 24 of the California Code of Regulations or its successor. |
|---|
| 215 | 215 | | |
|---|
| 216 | 216 | | (6) Attached structures shall be constructed to comply with interunit noise transmission standards set by the applicable government building codes, ordinances, or regulations in effect at the time of the original construction. If there is no applicable code, ordinance, or regulation, this paragraph does not apply. However, no action shall be brought pursuant to this paragraph more than one year from the original occupancy of the adjacent unit. |
|---|
| 217 | 217 | | |
|---|
| 218 | 218 | | (7) Irrigation systems and drainage shall operate properly so as not to damage landscaping or other external improvements. However, no action shall be brought pursuant to this paragraph more than one year from close of escrow. |
|---|
| 219 | 219 | | |
|---|
| 220 | 220 | | (8) Untreated wood posts shall not be installed in contact with soil so as to cause unreasonable decay to the wood based upon the finish grade at the time of original construction. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow. |
|---|
| 221 | 221 | | |
|---|
| 222 | 222 | | (9) Untreated steel fences and adjacent components shall be installed so as to prevent unreasonable corrosion. However, no action shall be brought pursuant to this paragraph more than four years from close of escrow. |
|---|
| 223 | 223 | | |
|---|
| 224 | 224 | | (10) Paint and stains shall be applied in such a manner so as not to cause deterioration of the building surfaces for the length of time specified by the paint or stain manufacturers representations, if any. However, no action shall be brought pursuant to this paragraph more than five years from close of escrow. |
|---|
| 225 | 225 | | |
|---|
| 226 | 226 | | (11) Roofing materials shall be installed so as to avoid materials falling from the roof. |
|---|
| 227 | 227 | | |
|---|
| 228 | 228 | | (12) The landscaping systems shall be installed in such a manner so as to survive for not less than one year. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow. |
|---|
| 229 | 229 | | |
|---|
| 230 | 230 | | (13) Ceramic tile and tile backing shall be installed in such a manner that the tile does not detach. |
|---|
| 231 | 231 | | |
|---|
| 232 | 232 | | (14) Dryer ducts shall be installed and terminated pursuant to manufacturer installation requirements. However, no action shall be brought pursuant to this paragraph more than two years from close of escrow. |
|---|
| 233 | 233 | | |
|---|
| 234 | 234 | | (15) Structures shall be constructed in such a manner so as not to impair the occupants safety because they contain public health hazards as determined by a duly authorized public health official, health agency, or governmental entity having jurisdiction. This paragraph does not limit recovery for any damages caused by a violation of any other paragraph of this section on the grounds that the damages do not constitute a health hazard. |
|---|
| 235 | 235 | | |
|---|
| 236 | 236 | | SEC. 3. Section 897 of the Civil Code is amended to read:897. The standards set forth in this chapter are intended to address every function or component of a structure. To the extent that a function or component of a structure is not addressed by these standards, it shall be actionable if the builder fails to meet the standard of care and it causes damage. |
|---|
| 237 | 237 | | |
|---|
| 238 | 238 | | SEC. 3. Section 897 of the Civil Code is amended to read: |
|---|
| 239 | 239 | | |
|---|
| 240 | 240 | | ### SEC. 3. |
|---|
| 241 | 241 | | |
|---|
| 242 | 242 | | 897. The standards set forth in this chapter are intended to address every function or component of a structure. To the extent that a function or component of a structure is not addressed by these standards, it shall be actionable if the builder fails to meet the standard of care and it causes damage. |
|---|
| 243 | 243 | | |
|---|
| 244 | 244 | | 897. The standards set forth in this chapter are intended to address every function or component of a structure. To the extent that a function or component of a structure is not addressed by these standards, it shall be actionable if the builder fails to meet the standard of care and it causes damage. |
|---|
| 245 | 245 | | |
|---|
| 246 | 246 | | 897. The standards set forth in this chapter are intended to address every function or component of a structure. To the extent that a function or component of a structure is not addressed by these standards, it shall be actionable if the builder fails to meet the standard of care and it causes damage. |
|---|
| 247 | 247 | | |
|---|
| 248 | 248 | | |
|---|
| 249 | 249 | | |
|---|
| 250 | 250 | | 897. The standards set forth in this chapter are intended to address every function or component of a structure. To the extent that a function or component of a structure is not addressed by these standards, it shall be actionable if the builder fails to meet the standard of care and it causes damage. |
|---|
| 251 | 251 | | |
|---|
| 252 | 252 | | SEC. 4. Section 916 of the Civil Code is amended to read:916. (a) If a builder elects and special inspector elect to inspect the claimed unmet standards, the builder and special inspector shall complete the initial inspection and testing within 14 days after acknowledgment of receipt of the notice of the claim, at a mutually convenient date and time. If the homeowner has retained legal representation, the inspection shall be scheduled with the legal representatives office at a mutually convenient date and time, unless the legal representative is unavailable during the relevant time periods. All costs of builder inspection inspection, special inspector, building permit, and testing, including any damage caused by the builder inspection, shall be borne by the builder. The builder shall also provide written proof that the builder has liability insurance to cover any damages or injuries occurring during inspection and testing. The builder shall restore the property to its pretesting condition within 48 hours of the testing. The builder shall, upon request, allow the inspections to be observed and electronically recorded, video recorded, or photographed by the claimant or his or her the claimants legal representative.(b) Nothing that occurs during a builders or claimants inspection or testing may be used or introduced as evidence to support a spoliation defense by any potential party in any subsequent litigation.(c) If a builder deems a second inspection or testing reasonably necessary, and specifies the reasons therefor in writing within three days following the initial inspection, the builder and special inspector may conduct a second inspection or testing. A second inspection or testing shall be completed within 40 days of the initial inspection or testing. All requirements concerning the initial inspection or testing shall also apply to the second inspection or testing.(d) If the builder fails to inspect or test the property within the time specified, the claimant is released from the requirements of this section and may proceed with the filing of an action. However, the standards set forth in the other chapters of this title shall continue to apply to the action.(e) If a builder intends to hold a subcontractor, design professional, individual product manufacturer, or material supplier, including an insurance carrier, warranty company, or service company, responsible for its contribution to the unmet standard, the builder shall provide notice to that person or entity sufficiently in advance to allow them to attend the initial, or if requested, second inspection of any alleged unmet standard and to participate in the repair process. The claimant and his or her the claimants legal representative, if any, shall be advised in a reasonable time prior to the inspection as to the identity of all persons or entities entities, including the special inspector, invited to attend. This subdivision does not apply to the builders insurance company. Except with respect to any claims involving a repair actually conducted under this chapter, nothing in this subdivision shall be construed to relieve a subcontractor, design professional, individual product manufacturer, or material supplier of any liability under an action brought by a claimant. |
|---|
| 253 | 253 | | |
|---|
| 254 | 254 | | SEC. 4. Section 916 of the Civil Code is amended to read: |
|---|
| 255 | 255 | | |
|---|
| 256 | 256 | | ### SEC. 4. |
|---|
| 257 | 257 | | |
|---|
| 258 | 258 | | 916. (a) If a builder elects and special inspector elect to inspect the claimed unmet standards, the builder and special inspector shall complete the initial inspection and testing within 14 days after acknowledgment of receipt of the notice of the claim, at a mutually convenient date and time. If the homeowner has retained legal representation, the inspection shall be scheduled with the legal representatives office at a mutually convenient date and time, unless the legal representative is unavailable during the relevant time periods. All costs of builder inspection inspection, special inspector, building permit, and testing, including any damage caused by the builder inspection, shall be borne by the builder. The builder shall also provide written proof that the builder has liability insurance to cover any damages or injuries occurring during inspection and testing. The builder shall restore the property to its pretesting condition within 48 hours of the testing. The builder shall, upon request, allow the inspections to be observed and electronically recorded, video recorded, or photographed by the claimant or his or her the claimants legal representative.(b) Nothing that occurs during a builders or claimants inspection or testing may be used or introduced as evidence to support a spoliation defense by any potential party in any subsequent litigation.(c) If a builder deems a second inspection or testing reasonably necessary, and specifies the reasons therefor in writing within three days following the initial inspection, the builder and special inspector may conduct a second inspection or testing. A second inspection or testing shall be completed within 40 days of the initial inspection or testing. All requirements concerning the initial inspection or testing shall also apply to the second inspection or testing.(d) If the builder fails to inspect or test the property within the time specified, the claimant is released from the requirements of this section and may proceed with the filing of an action. However, the standards set forth in the other chapters of this title shall continue to apply to the action.(e) If a builder intends to hold a subcontractor, design professional, individual product manufacturer, or material supplier, including an insurance carrier, warranty company, or service company, responsible for its contribution to the unmet standard, the builder shall provide notice to that person or entity sufficiently in advance to allow them to attend the initial, or if requested, second inspection of any alleged unmet standard and to participate in the repair process. The claimant and his or her the claimants legal representative, if any, shall be advised in a reasonable time prior to the inspection as to the identity of all persons or entities entities, including the special inspector, invited to attend. This subdivision does not apply to the builders insurance company. Except with respect to any claims involving a repair actually conducted under this chapter, nothing in this subdivision shall be construed to relieve a subcontractor, design professional, individual product manufacturer, or material supplier of any liability under an action brought by a claimant. |
|---|
| 259 | 259 | | |
|---|
| 260 | 260 | | 916. (a) If a builder elects and special inspector elect to inspect the claimed unmet standards, the builder and special inspector shall complete the initial inspection and testing within 14 days after acknowledgment of receipt of the notice of the claim, at a mutually convenient date and time. If the homeowner has retained legal representation, the inspection shall be scheduled with the legal representatives office at a mutually convenient date and time, unless the legal representative is unavailable during the relevant time periods. All costs of builder inspection inspection, special inspector, building permit, and testing, including any damage caused by the builder inspection, shall be borne by the builder. The builder shall also provide written proof that the builder has liability insurance to cover any damages or injuries occurring during inspection and testing. The builder shall restore the property to its pretesting condition within 48 hours of the testing. The builder shall, upon request, allow the inspections to be observed and electronically recorded, video recorded, or photographed by the claimant or his or her the claimants legal representative.(b) Nothing that occurs during a builders or claimants inspection or testing may be used or introduced as evidence to support a spoliation defense by any potential party in any subsequent litigation.(c) If a builder deems a second inspection or testing reasonably necessary, and specifies the reasons therefor in writing within three days following the initial inspection, the builder and special inspector may conduct a second inspection or testing. A second inspection or testing shall be completed within 40 days of the initial inspection or testing. All requirements concerning the initial inspection or testing shall also apply to the second inspection or testing.(d) If the builder fails to inspect or test the property within the time specified, the claimant is released from the requirements of this section and may proceed with the filing of an action. However, the standards set forth in the other chapters of this title shall continue to apply to the action.(e) If a builder intends to hold a subcontractor, design professional, individual product manufacturer, or material supplier, including an insurance carrier, warranty company, or service company, responsible for its contribution to the unmet standard, the builder shall provide notice to that person or entity sufficiently in advance to allow them to attend the initial, or if requested, second inspection of any alleged unmet standard and to participate in the repair process. The claimant and his or her the claimants legal representative, if any, shall be advised in a reasonable time prior to the inspection as to the identity of all persons or entities entities, including the special inspector, invited to attend. This subdivision does not apply to the builders insurance company. Except with respect to any claims involving a repair actually conducted under this chapter, nothing in this subdivision shall be construed to relieve a subcontractor, design professional, individual product manufacturer, or material supplier of any liability under an action brought by a claimant. |
|---|
| 261 | 261 | | |
|---|
| 262 | 262 | | 916. (a) If a builder elects and special inspector elect to inspect the claimed unmet standards, the builder and special inspector shall complete the initial inspection and testing within 14 days after acknowledgment of receipt of the notice of the claim, at a mutually convenient date and time. If the homeowner has retained legal representation, the inspection shall be scheduled with the legal representatives office at a mutually convenient date and time, unless the legal representative is unavailable during the relevant time periods. All costs of builder inspection inspection, special inspector, building permit, and testing, including any damage caused by the builder inspection, shall be borne by the builder. The builder shall also provide written proof that the builder has liability insurance to cover any damages or injuries occurring during inspection and testing. The builder shall restore the property to its pretesting condition within 48 hours of the testing. The builder shall, upon request, allow the inspections to be observed and electronically recorded, video recorded, or photographed by the claimant or his or her the claimants legal representative.(b) Nothing that occurs during a builders or claimants inspection or testing may be used or introduced as evidence to support a spoliation defense by any potential party in any subsequent litigation.(c) If a builder deems a second inspection or testing reasonably necessary, and specifies the reasons therefor in writing within three days following the initial inspection, the builder and special inspector may conduct a second inspection or testing. A second inspection or testing shall be completed within 40 days of the initial inspection or testing. All requirements concerning the initial inspection or testing shall also apply to the second inspection or testing.(d) If the builder fails to inspect or test the property within the time specified, the claimant is released from the requirements of this section and may proceed with the filing of an action. However, the standards set forth in the other chapters of this title shall continue to apply to the action.(e) If a builder intends to hold a subcontractor, design professional, individual product manufacturer, or material supplier, including an insurance carrier, warranty company, or service company, responsible for its contribution to the unmet standard, the builder shall provide notice to that person or entity sufficiently in advance to allow them to attend the initial, or if requested, second inspection of any alleged unmet standard and to participate in the repair process. The claimant and his or her the claimants legal representative, if any, shall be advised in a reasonable time prior to the inspection as to the identity of all persons or entities entities, including the special inspector, invited to attend. This subdivision does not apply to the builders insurance company. Except with respect to any claims involving a repair actually conducted under this chapter, nothing in this subdivision shall be construed to relieve a subcontractor, design professional, individual product manufacturer, or material supplier of any liability under an action brought by a claimant. |
|---|
| 263 | 263 | | |
|---|
| 264 | 264 | | |
|---|
| 265 | 265 | | |
|---|
| 266 | 266 | | 916. (a) If a builder elects and special inspector elect to inspect the claimed unmet standards, the builder and special inspector shall complete the initial inspection and testing within 14 days after acknowledgment of receipt of the notice of the claim, at a mutually convenient date and time. If the homeowner has retained legal representation, the inspection shall be scheduled with the legal representatives office at a mutually convenient date and time, unless the legal representative is unavailable during the relevant time periods. All costs of builder inspection inspection, special inspector, building permit, and testing, including any damage caused by the builder inspection, shall be borne by the builder. The builder shall also provide written proof that the builder has liability insurance to cover any damages or injuries occurring during inspection and testing. The builder shall restore the property to its pretesting condition within 48 hours of the testing. The builder shall, upon request, allow the inspections to be observed and electronically recorded, video recorded, or photographed by the claimant or his or her the claimants legal representative. |
|---|
| 267 | 267 | | |
|---|
| 268 | 268 | | (b) Nothing that occurs during a builders or claimants inspection or testing may be used or introduced as evidence to support a spoliation defense by any potential party in any subsequent litigation. |
|---|
| 269 | 269 | | |
|---|
| 270 | 270 | | (c) If a builder deems a second inspection or testing reasonably necessary, and specifies the reasons therefor in writing within three days following the initial inspection, the builder and special inspector may conduct a second inspection or testing. A second inspection or testing shall be completed within 40 days of the initial inspection or testing. All requirements concerning the initial inspection or testing shall also apply to the second inspection or testing. |
|---|
| 271 | 271 | | |
|---|
| 272 | 272 | | (d) If the builder fails to inspect or test the property within the time specified, the claimant is released from the requirements of this section and may proceed with the filing of an action. However, the standards set forth in the other chapters of this title shall continue to apply to the action. |
|---|
| 273 | 273 | | |
|---|
| 274 | 274 | | (e) If a builder intends to hold a subcontractor, design professional, individual product manufacturer, or material supplier, including an insurance carrier, warranty company, or service company, responsible for its contribution to the unmet standard, the builder shall provide notice to that person or entity sufficiently in advance to allow them to attend the initial, or if requested, second inspection of any alleged unmet standard and to participate in the repair process. The claimant and his or her the claimants legal representative, if any, shall be advised in a reasonable time prior to the inspection as to the identity of all persons or entities entities, including the special inspector, invited to attend. This subdivision does not apply to the builders insurance company. Except with respect to any claims involving a repair actually conducted under this chapter, nothing in this subdivision shall be construed to relieve a subcontractor, design professional, individual product manufacturer, or material supplier of any liability under an action brought by a claimant. |
|---|
| 275 | 275 | | |
|---|
| 276 | 276 | | SEC. 5. Section 921 of the Civil Code is amended to read:921. (a) In the event that a resolution under this chapter involves a repair by the builder, the builder shall apply for and receive a building permit from the permitting body of the jurisdiction of the home, make an appointment with the claimant, make all appropriate arrangements to effectuate a repair of the claimed unmet standards, and compensate the homeowner for all damages resulting therefrom free of charge to the claimant. The permitting body for the jurisdiction of the claimants dwelling shall issue a building permit within 30 days of the date of submission of an application for a building permit. The repair shall be scheduled through the claimants legal representative, if any, unless he or she the claimants legal representative is unavailable during the relevant time periods. The repair shall be commenced on a mutually convenient date within 14 days of acceptance or, if an alternative contractor is selected by the homeowner, within 14 days of the selection, or, if a mediation occurs, within seven days of the mediation, or within five days after a permit is obtained if one is required. building permit is issued. The builder shall act with reasonable diligence in obtaining any such permit.(b) The builder shall ensure that work done on the repairs is done with the utmost diligence, and that the repairs are completed as soon as reasonably possible, subject to the nature of the repair or some unforeseen event not caused by the builder or the contractor performing the repair. Every effort shall be made to complete the repair within 120 days. During such repairs the special inspector shall review the repairs at least once. |
|---|
| 277 | 277 | | |
|---|
| 278 | 278 | | SEC. 5. Section 921 of the Civil Code is amended to read: |
|---|
| 279 | 279 | | |
|---|
| 280 | 280 | | ### SEC. 5. |
|---|
| 281 | 281 | | |
|---|
| 282 | 282 | | 921. (a) In the event that a resolution under this chapter involves a repair by the builder, the builder shall apply for and receive a building permit from the permitting body of the jurisdiction of the home, make an appointment with the claimant, make all appropriate arrangements to effectuate a repair of the claimed unmet standards, and compensate the homeowner for all damages resulting therefrom free of charge to the claimant. The permitting body for the jurisdiction of the claimants dwelling shall issue a building permit within 30 days of the date of submission of an application for a building permit. The repair shall be scheduled through the claimants legal representative, if any, unless he or she the claimants legal representative is unavailable during the relevant time periods. The repair shall be commenced on a mutually convenient date within 14 days of acceptance or, if an alternative contractor is selected by the homeowner, within 14 days of the selection, or, if a mediation occurs, within seven days of the mediation, or within five days after a permit is obtained if one is required. building permit is issued. The builder shall act with reasonable diligence in obtaining any such permit.(b) The builder shall ensure that work done on the repairs is done with the utmost diligence, and that the repairs are completed as soon as reasonably possible, subject to the nature of the repair or some unforeseen event not caused by the builder or the contractor performing the repair. Every effort shall be made to complete the repair within 120 days. During such repairs the special inspector shall review the repairs at least once. |
|---|
| 283 | 283 | | |
|---|
| 284 | 284 | | 921. (a) In the event that a resolution under this chapter involves a repair by the builder, the builder shall apply for and receive a building permit from the permitting body of the jurisdiction of the home, make an appointment with the claimant, make all appropriate arrangements to effectuate a repair of the claimed unmet standards, and compensate the homeowner for all damages resulting therefrom free of charge to the claimant. The permitting body for the jurisdiction of the claimants dwelling shall issue a building permit within 30 days of the date of submission of an application for a building permit. The repair shall be scheduled through the claimants legal representative, if any, unless he or she the claimants legal representative is unavailable during the relevant time periods. The repair shall be commenced on a mutually convenient date within 14 days of acceptance or, if an alternative contractor is selected by the homeowner, within 14 days of the selection, or, if a mediation occurs, within seven days of the mediation, or within five days after a permit is obtained if one is required. building permit is issued. The builder shall act with reasonable diligence in obtaining any such permit.(b) The builder shall ensure that work done on the repairs is done with the utmost diligence, and that the repairs are completed as soon as reasonably possible, subject to the nature of the repair or some unforeseen event not caused by the builder or the contractor performing the repair. Every effort shall be made to complete the repair within 120 days. During such repairs the special inspector shall review the repairs at least once. |
|---|
| 285 | 285 | | |
|---|
| 286 | 286 | | 921. (a) In the event that a resolution under this chapter involves a repair by the builder, the builder shall apply for and receive a building permit from the permitting body of the jurisdiction of the home, make an appointment with the claimant, make all appropriate arrangements to effectuate a repair of the claimed unmet standards, and compensate the homeowner for all damages resulting therefrom free of charge to the claimant. The permitting body for the jurisdiction of the claimants dwelling shall issue a building permit within 30 days of the date of submission of an application for a building permit. The repair shall be scheduled through the claimants legal representative, if any, unless he or she the claimants legal representative is unavailable during the relevant time periods. The repair shall be commenced on a mutually convenient date within 14 days of acceptance or, if an alternative contractor is selected by the homeowner, within 14 days of the selection, or, if a mediation occurs, within seven days of the mediation, or within five days after a permit is obtained if one is required. building permit is issued. The builder shall act with reasonable diligence in obtaining any such permit.(b) The builder shall ensure that work done on the repairs is done with the utmost diligence, and that the repairs are completed as soon as reasonably possible, subject to the nature of the repair or some unforeseen event not caused by the builder or the contractor performing the repair. Every effort shall be made to complete the repair within 120 days. During such repairs the special inspector shall review the repairs at least once. |
|---|
| 287 | 287 | | |
|---|
| 288 | 288 | | |
|---|
| 289 | 289 | | |
|---|
| 290 | 290 | | 921. (a) In the event that a resolution under this chapter involves a repair by the builder, the builder shall apply for and receive a building permit from the permitting body of the jurisdiction of the home, make an appointment with the claimant, make all appropriate arrangements to effectuate a repair of the claimed unmet standards, and compensate the homeowner for all damages resulting therefrom free of charge to the claimant. The permitting body for the jurisdiction of the claimants dwelling shall issue a building permit within 30 days of the date of submission of an application for a building permit. The repair shall be scheduled through the claimants legal representative, if any, unless he or she the claimants legal representative is unavailable during the relevant time periods. The repair shall be commenced on a mutually convenient date within 14 days of acceptance or, if an alternative contractor is selected by the homeowner, within 14 days of the selection, or, if a mediation occurs, within seven days of the mediation, or within five days after a permit is obtained if one is required. building permit is issued. The builder shall act with reasonable diligence in obtaining any such permit. |
|---|
| 291 | 291 | | |
|---|
| 292 | 292 | | (b) The builder shall ensure that work done on the repairs is done with the utmost diligence, and that the repairs are completed as soon as reasonably possible, subject to the nature of the repair or some unforeseen event not caused by the builder or the contractor performing the repair. Every effort shall be made to complete the repair within 120 days. During such repairs the special inspector shall review the repairs at least once. |
|---|
| 293 | 293 | | |
|---|
| 294 | 294 | | SEC. 6. Section 926 of the Civil Code is amended to read:926. The builder may not obtain a release or waiver of any kind in exchange for upon completion of the building permit and completion of the repair work mandated by this chapter. At the conclusion of the repair, the claimant may proceed with filing an action for violation of the applicable standard or for a claim of inadequate repair, or both, including all applicable damages available under Section 944. of care for any work not completed. Should there be a dispute regarding the aesthetic quality of the work, the special inspector shall review the work to ensure the aesthetic quality reasonably matches the finish that was intended prior to beginning repair of the defect. |
|---|
| 295 | 295 | | |
|---|
| 296 | 296 | | SEC. 6. Section 926 of the Civil Code is amended to read: |
|---|
| 297 | 297 | | |
|---|
| 298 | 298 | | ### SEC. 6. |
|---|
| 299 | 299 | | |
|---|
| 300 | 300 | | 926. The builder may not obtain a release or waiver of any kind in exchange for upon completion of the building permit and completion of the repair work mandated by this chapter. At the conclusion of the repair, the claimant may proceed with filing an action for violation of the applicable standard or for a claim of inadequate repair, or both, including all applicable damages available under Section 944. of care for any work not completed. Should there be a dispute regarding the aesthetic quality of the work, the special inspector shall review the work to ensure the aesthetic quality reasonably matches the finish that was intended prior to beginning repair of the defect. |
|---|
| 301 | 301 | | |
|---|
| 302 | 302 | | 926. The builder may not obtain a release or waiver of any kind in exchange for upon completion of the building permit and completion of the repair work mandated by this chapter. At the conclusion of the repair, the claimant may proceed with filing an action for violation of the applicable standard or for a claim of inadequate repair, or both, including all applicable damages available under Section 944. of care for any work not completed. Should there be a dispute regarding the aesthetic quality of the work, the special inspector shall review the work to ensure the aesthetic quality reasonably matches the finish that was intended prior to beginning repair of the defect. |
|---|
| 303 | 303 | | |
|---|
| 304 | 304 | | 926. The builder may not obtain a release or waiver of any kind in exchange for upon completion of the building permit and completion of the repair work mandated by this chapter. At the conclusion of the repair, the claimant may proceed with filing an action for violation of the applicable standard or for a claim of inadequate repair, or both, including all applicable damages available under Section 944. of care for any work not completed. Should there be a dispute regarding the aesthetic quality of the work, the special inspector shall review the work to ensure the aesthetic quality reasonably matches the finish that was intended prior to beginning repair of the defect. |
|---|
| 305 | 305 | | |
|---|
| 306 | 306 | | |
|---|
| 307 | 307 | | |
|---|
| 308 | 308 | | 926. The builder may not obtain a release or waiver of any kind in exchange for upon completion of the building permit and completion of the repair work mandated by this chapter. At the conclusion of the repair, the claimant may proceed with filing an action for violation of the applicable standard or for a claim of inadequate repair, or both, including all applicable damages available under Section 944. of care for any work not completed. Should there be a dispute regarding the aesthetic quality of the work, the special inspector shall review the work to ensure the aesthetic quality reasonably matches the finish that was intended prior to beginning repair of the defect. |
|---|
| 309 | 309 | | |
|---|
| 310 | 310 | | SEC. 7. Section 927 of the Civil Code is amended to read:927. If the applicable statute of limitations has otherwise run during this process, the time period for filing a complaint or other legal remedies for violation of any provision of this title, for failure to complete the building permit to its expiration, or for a claim of inadequate repair, is extended from the time of the original claim by the claimant to 100 days after the repair is completed, whether or not the particular violation is the one being repaired. If the builder fails to acknowledge the claim within the time specified, elects not to go through this statutory process, or fails to request an inspection within the time specified, the time period for filing a complaint or other legal remedies for violation of any provision of this title is extended from the time of the original claim by the claimant to 45 days after the time for responding to the notice of claim has expired. If the builder elects to attempt to enforce its own nonadversarial procedure in lieu of the procedure set forth in this chapter, the time period for filing a complaint or other legal remedies for violation of any provision of this part is extended from the time of the original claim by the claimant to 100 days after either the completion of the builders alternative nonadversarial procedure, or 100 days after the builders alternative nonadversarial procedure is deemed unenforceable, whichever is later. |
|---|
| 311 | 311 | | |
|---|
| 312 | 312 | | SEC. 7. Section 927 of the Civil Code is amended to read: |
|---|
| 313 | 313 | | |
|---|
| 314 | 314 | | ### SEC. 7. |
|---|
| 315 | 315 | | |
|---|
| 316 | 316 | | 927. If the applicable statute of limitations has otherwise run during this process, the time period for filing a complaint or other legal remedies for violation of any provision of this title, for failure to complete the building permit to its expiration, or for a claim of inadequate repair, is extended from the time of the original claim by the claimant to 100 days after the repair is completed, whether or not the particular violation is the one being repaired. If the builder fails to acknowledge the claim within the time specified, elects not to go through this statutory process, or fails to request an inspection within the time specified, the time period for filing a complaint or other legal remedies for violation of any provision of this title is extended from the time of the original claim by the claimant to 45 days after the time for responding to the notice of claim has expired. If the builder elects to attempt to enforce its own nonadversarial procedure in lieu of the procedure set forth in this chapter, the time period for filing a complaint or other legal remedies for violation of any provision of this part is extended from the time of the original claim by the claimant to 100 days after either the completion of the builders alternative nonadversarial procedure, or 100 days after the builders alternative nonadversarial procedure is deemed unenforceable, whichever is later. |
|---|
| 317 | 317 | | |
|---|
| 318 | 318 | | 927. If the applicable statute of limitations has otherwise run during this process, the time period for filing a complaint or other legal remedies for violation of any provision of this title, for failure to complete the building permit to its expiration, or for a claim of inadequate repair, is extended from the time of the original claim by the claimant to 100 days after the repair is completed, whether or not the particular violation is the one being repaired. If the builder fails to acknowledge the claim within the time specified, elects not to go through this statutory process, or fails to request an inspection within the time specified, the time period for filing a complaint or other legal remedies for violation of any provision of this title is extended from the time of the original claim by the claimant to 45 days after the time for responding to the notice of claim has expired. If the builder elects to attempt to enforce its own nonadversarial procedure in lieu of the procedure set forth in this chapter, the time period for filing a complaint or other legal remedies for violation of any provision of this part is extended from the time of the original claim by the claimant to 100 days after either the completion of the builders alternative nonadversarial procedure, or 100 days after the builders alternative nonadversarial procedure is deemed unenforceable, whichever is later. |
|---|
| 319 | 319 | | |
|---|
| 320 | 320 | | 927. If the applicable statute of limitations has otherwise run during this process, the time period for filing a complaint or other legal remedies for violation of any provision of this title, for failure to complete the building permit to its expiration, or for a claim of inadequate repair, is extended from the time of the original claim by the claimant to 100 days after the repair is completed, whether or not the particular violation is the one being repaired. If the builder fails to acknowledge the claim within the time specified, elects not to go through this statutory process, or fails to request an inspection within the time specified, the time period for filing a complaint or other legal remedies for violation of any provision of this title is extended from the time of the original claim by the claimant to 45 days after the time for responding to the notice of claim has expired. If the builder elects to attempt to enforce its own nonadversarial procedure in lieu of the procedure set forth in this chapter, the time period for filing a complaint or other legal remedies for violation of any provision of this part is extended from the time of the original claim by the claimant to 100 days after either the completion of the builders alternative nonadversarial procedure, or 100 days after the builders alternative nonadversarial procedure is deemed unenforceable, whichever is later. |
|---|
| 321 | 321 | | |
|---|
| 322 | 322 | | |
|---|
| 323 | 323 | | |
|---|
| 324 | 324 | | 927. If the applicable statute of limitations has otherwise run during this process, the time period for filing a complaint or other legal remedies for violation of any provision of this title, for failure to complete the building permit to its expiration, or for a claim of inadequate repair, is extended from the time of the original claim by the claimant to 100 days after the repair is completed, whether or not the particular violation is the one being repaired. If the builder fails to acknowledge the claim within the time specified, elects not to go through this statutory process, or fails to request an inspection within the time specified, the time period for filing a complaint or other legal remedies for violation of any provision of this title is extended from the time of the original claim by the claimant to 45 days after the time for responding to the notice of claim has expired. If the builder elects to attempt to enforce its own nonadversarial procedure in lieu of the procedure set forth in this chapter, the time period for filing a complaint or other legal remedies for violation of any provision of this part is extended from the time of the original claim by the claimant to 100 days after either the completion of the builders alternative nonadversarial procedure, or 100 days after the builders alternative nonadversarial procedure is deemed unenforceable, whichever is later. |
|---|
| 325 | 325 | | |
|---|
| 326 | 326 | | SEC. 8. Section 933 of the Civil Code is amended to read:933. If any enforcement of these standards is commenced, the fact that a repair effort was made may be introduced to the trier of fact. However, the claimant may use the condition of the property prior to the repair as the basis for contending that the repair work was inappropriate, inadequate, or incomplete, or that the violation still exists. The claimant need not show that the repair work resulted in further damage nor that damage has continued to occur as a result of the violation. made, and the associated building permit and reports from the special inspector may be introduced to the trier of fact. |
|---|
| 327 | 327 | | |
|---|
| 328 | 328 | | SEC. 8. Section 933 of the Civil Code is amended to read: |
|---|
| 329 | 329 | | |
|---|
| 330 | 330 | | ### SEC. 8. |
|---|
| 331 | 331 | | |
|---|
| 332 | 332 | | 933. If any enforcement of these standards is commenced, the fact that a repair effort was made may be introduced to the trier of fact. However, the claimant may use the condition of the property prior to the repair as the basis for contending that the repair work was inappropriate, inadequate, or incomplete, or that the violation still exists. The claimant need not show that the repair work resulted in further damage nor that damage has continued to occur as a result of the violation. made, and the associated building permit and reports from the special inspector may be introduced to the trier of fact. |
|---|
| 333 | 333 | | |
|---|
| 334 | 334 | | 933. If any enforcement of these standards is commenced, the fact that a repair effort was made may be introduced to the trier of fact. However, the claimant may use the condition of the property prior to the repair as the basis for contending that the repair work was inappropriate, inadequate, or incomplete, or that the violation still exists. The claimant need not show that the repair work resulted in further damage nor that damage has continued to occur as a result of the violation. made, and the associated building permit and reports from the special inspector may be introduced to the trier of fact. |
|---|
| 335 | 335 | | |
|---|
| 336 | 336 | | 933. If any enforcement of these standards is commenced, the fact that a repair effort was made may be introduced to the trier of fact. However, the claimant may use the condition of the property prior to the repair as the basis for contending that the repair work was inappropriate, inadequate, or incomplete, or that the violation still exists. The claimant need not show that the repair work resulted in further damage nor that damage has continued to occur as a result of the violation. made, and the associated building permit and reports from the special inspector may be introduced to the trier of fact. |
|---|
| 337 | 337 | | |
|---|
| 338 | 338 | | |
|---|
| 339 | 339 | | |
|---|
| 340 | 340 | | 933. If any enforcement of these standards is commenced, the fact that a repair effort was made may be introduced to the trier of fact. However, the claimant may use the condition of the property prior to the repair as the basis for contending that the repair work was inappropriate, inadequate, or incomplete, or that the violation still exists. The claimant need not show that the repair work resulted in further damage nor that damage has continued to occur as a result of the violation. made, and the associated building permit and reports from the special inspector may be introduced to the trier of fact. |
|---|
| 341 | 341 | | |
|---|
| 342 | 342 | | SEC. 9. Section 934 of the Civil Code is amended to read:934. Evidence of both parties conduct during this process may be introduced during a subsequent enforcement action, if any, with the exception of any mediation. Any repair efforts undertaken by the builder, shall not be considered settlement communications or offers of settlement and are not inadmissible in evidence on such a basis. Should the claimant reject an offer to repair under Section 918, such rejection is not inadmissible under this section. |
|---|
| 343 | 343 | | |
|---|
| 344 | 344 | | SEC. 9. Section 934 of the Civil Code is amended to read: |
|---|
| 345 | 345 | | |
|---|
| 346 | 346 | | ### SEC. 9. |
|---|
| 347 | 347 | | |
|---|
| 348 | 348 | | 934. Evidence of both parties conduct during this process may be introduced during a subsequent enforcement action, if any, with the exception of any mediation. Any repair efforts undertaken by the builder, shall not be considered settlement communications or offers of settlement and are not inadmissible in evidence on such a basis. Should the claimant reject an offer to repair under Section 918, such rejection is not inadmissible under this section. |
|---|
| 349 | 349 | | |
|---|
| 350 | 350 | | 934. Evidence of both parties conduct during this process may be introduced during a subsequent enforcement action, if any, with the exception of any mediation. Any repair efforts undertaken by the builder, shall not be considered settlement communications or offers of settlement and are not inadmissible in evidence on such a basis. Should the claimant reject an offer to repair under Section 918, such rejection is not inadmissible under this section. |
|---|
| 351 | 351 | | |
|---|
| 352 | 352 | | 934. Evidence of both parties conduct during this process may be introduced during a subsequent enforcement action, if any, with the exception of any mediation. Any repair efforts undertaken by the builder, shall not be considered settlement communications or offers of settlement and are not inadmissible in evidence on such a basis. Should the claimant reject an offer to repair under Section 918, such rejection is not inadmissible under this section. |
|---|
| 353 | 353 | | |
|---|
| 354 | 354 | | |
|---|
| 355 | 355 | | |
|---|
| 356 | 356 | | 934. Evidence of both parties conduct during this process may be introduced during a subsequent enforcement action, if any, with the exception of any mediation. Any repair efforts undertaken by the builder, shall not be considered settlement communications or offers of settlement and are not inadmissible in evidence on such a basis. Should the claimant reject an offer to repair under Section 918, such rejection is not inadmissible under this section. |
|---|
| 357 | 357 | | |
|---|
| 358 | 358 | | SEC. 10. Section 945.5 of the Civil Code is amended to read:945.5. A builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, under the principles of comparative fault pertaining to affirmative defenses, may be excused, in whole or in part, from any obligation, damage, loss, or liability if the builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, can demonstrate any of the following affirmative defenses in response to a claimed violation:(a) To the extent it is caused by an unforeseen act of nature which caused the structure not to meet the standard. For purposes of this section an unforeseen act of nature means a weather condition, earthquake, or manmade event such as war, terrorism, or vandalism, in excess of the design criteria expressed by the applicable building codes, regulations, and ordinances in effect at the time of original construction.(b) To the extent it is caused by a homeowners unreasonable failure to minimize or prevent those damages in a timely manner, including the failure of the homeowner to allow reasonable and timely access for inspections and repairs under this title. This includes the failure to give timely notice to the builder after discovery of a violation, but does not include damages due to the untimely or inadequate response of a builder to the homeowners claim.(c) To the extent it is caused by the homeowner or his or her the homeowners agent, employee, general contractor, subcontractor, independent contractor, or consultant by virtue of their failure to follow the builders or manufacturers recommendations, or commonly accepted homeowner maintenance obligations. In order to rely upon this defense as it relates to a builders recommended maintenance schedule, the builder shall show that the homeowner had written notice of these schedules and recommendations and that the recommendations and schedules were reasonable at the time they were issued.(d) To the extent it is caused by the homeowner or his or her the homeowners agents or an independent third partys alterations, ordinary wear and tear, misuse, abuse, or neglect, or by the structures use for something other than its intended purpose.(e) To the extent that the time period for filing actions bars the claimed violation.(f) As to a particular violation for which the builder has obtained a valid release.(g) To the extent that the builders repair was successful in correcting the particular violation of the applicable standard.(h) To the extent that the builder complied with the building permit and gained final sign-off from the permitting body for the repairs.(i) To the extent that the builder received approval from the special inspector on the work completed for the repairs.(h)(j) As to any causes of action to which this statute does not apply, all applicable affirmative defenses are preserved. |
|---|
| 359 | 359 | | |
|---|
| 360 | 360 | | SEC. 10. Section 945.5 of the Civil Code is amended to read: |
|---|
| 361 | 361 | | |
|---|
| 362 | 362 | | ### SEC. 10. |
|---|
| 363 | 363 | | |
|---|
| 364 | 364 | | 945.5. A builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, under the principles of comparative fault pertaining to affirmative defenses, may be excused, in whole or in part, from any obligation, damage, loss, or liability if the builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, can demonstrate any of the following affirmative defenses in response to a claimed violation:(a) To the extent it is caused by an unforeseen act of nature which caused the structure not to meet the standard. For purposes of this section an unforeseen act of nature means a weather condition, earthquake, or manmade event such as war, terrorism, or vandalism, in excess of the design criteria expressed by the applicable building codes, regulations, and ordinances in effect at the time of original construction.(b) To the extent it is caused by a homeowners unreasonable failure to minimize or prevent those damages in a timely manner, including the failure of the homeowner to allow reasonable and timely access for inspections and repairs under this title. This includes the failure to give timely notice to the builder after discovery of a violation, but does not include damages due to the untimely or inadequate response of a builder to the homeowners claim.(c) To the extent it is caused by the homeowner or his or her the homeowners agent, employee, general contractor, subcontractor, independent contractor, or consultant by virtue of their failure to follow the builders or manufacturers recommendations, or commonly accepted homeowner maintenance obligations. In order to rely upon this defense as it relates to a builders recommended maintenance schedule, the builder shall show that the homeowner had written notice of these schedules and recommendations and that the recommendations and schedules were reasonable at the time they were issued.(d) To the extent it is caused by the homeowner or his or her the homeowners agents or an independent third partys alterations, ordinary wear and tear, misuse, abuse, or neglect, or by the structures use for something other than its intended purpose.(e) To the extent that the time period for filing actions bars the claimed violation.(f) As to a particular violation for which the builder has obtained a valid release.(g) To the extent that the builders repair was successful in correcting the particular violation of the applicable standard.(h) To the extent that the builder complied with the building permit and gained final sign-off from the permitting body for the repairs.(i) To the extent that the builder received approval from the special inspector on the work completed for the repairs.(h)(j) As to any causes of action to which this statute does not apply, all applicable affirmative defenses are preserved. |
|---|
| 365 | 365 | | |
|---|
| 366 | 366 | | 945.5. A builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, under the principles of comparative fault pertaining to affirmative defenses, may be excused, in whole or in part, from any obligation, damage, loss, or liability if the builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, can demonstrate any of the following affirmative defenses in response to a claimed violation:(a) To the extent it is caused by an unforeseen act of nature which caused the structure not to meet the standard. For purposes of this section an unforeseen act of nature means a weather condition, earthquake, or manmade event such as war, terrorism, or vandalism, in excess of the design criteria expressed by the applicable building codes, regulations, and ordinances in effect at the time of original construction.(b) To the extent it is caused by a homeowners unreasonable failure to minimize or prevent those damages in a timely manner, including the failure of the homeowner to allow reasonable and timely access for inspections and repairs under this title. This includes the failure to give timely notice to the builder after discovery of a violation, but does not include damages due to the untimely or inadequate response of a builder to the homeowners claim.(c) To the extent it is caused by the homeowner or his or her the homeowners agent, employee, general contractor, subcontractor, independent contractor, or consultant by virtue of their failure to follow the builders or manufacturers recommendations, or commonly accepted homeowner maintenance obligations. In order to rely upon this defense as it relates to a builders recommended maintenance schedule, the builder shall show that the homeowner had written notice of these schedules and recommendations and that the recommendations and schedules were reasonable at the time they were issued.(d) To the extent it is caused by the homeowner or his or her the homeowners agents or an independent third partys alterations, ordinary wear and tear, misuse, abuse, or neglect, or by the structures use for something other than its intended purpose.(e) To the extent that the time period for filing actions bars the claimed violation.(f) As to a particular violation for which the builder has obtained a valid release.(g) To the extent that the builders repair was successful in correcting the particular violation of the applicable standard.(h) To the extent that the builder complied with the building permit and gained final sign-off from the permitting body for the repairs.(i) To the extent that the builder received approval from the special inspector on the work completed for the repairs.(h)(j) As to any causes of action to which this statute does not apply, all applicable affirmative defenses are preserved. |
|---|
| 367 | 367 | | |
|---|
| 368 | 368 | | 945.5. A builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, under the principles of comparative fault pertaining to affirmative defenses, may be excused, in whole or in part, from any obligation, damage, loss, or liability if the builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, can demonstrate any of the following affirmative defenses in response to a claimed violation:(a) To the extent it is caused by an unforeseen act of nature which caused the structure not to meet the standard. For purposes of this section an unforeseen act of nature means a weather condition, earthquake, or manmade event such as war, terrorism, or vandalism, in excess of the design criteria expressed by the applicable building codes, regulations, and ordinances in effect at the time of original construction.(b) To the extent it is caused by a homeowners unreasonable failure to minimize or prevent those damages in a timely manner, including the failure of the homeowner to allow reasonable and timely access for inspections and repairs under this title. This includes the failure to give timely notice to the builder after discovery of a violation, but does not include damages due to the untimely or inadequate response of a builder to the homeowners claim.(c) To the extent it is caused by the homeowner or his or her the homeowners agent, employee, general contractor, subcontractor, independent contractor, or consultant by virtue of their failure to follow the builders or manufacturers recommendations, or commonly accepted homeowner maintenance obligations. In order to rely upon this defense as it relates to a builders recommended maintenance schedule, the builder shall show that the homeowner had written notice of these schedules and recommendations and that the recommendations and schedules were reasonable at the time they were issued.(d) To the extent it is caused by the homeowner or his or her the homeowners agents or an independent third partys alterations, ordinary wear and tear, misuse, abuse, or neglect, or by the structures use for something other than its intended purpose.(e) To the extent that the time period for filing actions bars the claimed violation.(f) As to a particular violation for which the builder has obtained a valid release.(g) To the extent that the builders repair was successful in correcting the particular violation of the applicable standard.(h) To the extent that the builder complied with the building permit and gained final sign-off from the permitting body for the repairs.(i) To the extent that the builder received approval from the special inspector on the work completed for the repairs.(h)(j) As to any causes of action to which this statute does not apply, all applicable affirmative defenses are preserved. |
|---|
| 369 | 369 | | |
|---|
| 370 | 370 | | |
|---|
| 371 | 371 | | |
|---|
| 372 | 372 | | 945.5. A builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, under the principles of comparative fault pertaining to affirmative defenses, may be excused, in whole or in part, from any obligation, damage, loss, or liability if the builder, general contractor, subcontractor, material supplier, individual product manufacturer, or design professional, can demonstrate any of the following affirmative defenses in response to a claimed violation: |
|---|
| 373 | 373 | | |
|---|
| 374 | 374 | | (a) To the extent it is caused by an unforeseen act of nature which caused the structure not to meet the standard. For purposes of this section an unforeseen act of nature means a weather condition, earthquake, or manmade event such as war, terrorism, or vandalism, in excess of the design criteria expressed by the applicable building codes, regulations, and ordinances in effect at the time of original construction. |
|---|
| 375 | 375 | | |
|---|
| 376 | 376 | | (b) To the extent it is caused by a homeowners unreasonable failure to minimize or prevent those damages in a timely manner, including the failure of the homeowner to allow reasonable and timely access for inspections and repairs under this title. This includes the failure to give timely notice to the builder after discovery of a violation, but does not include damages due to the untimely or inadequate response of a builder to the homeowners claim. |
|---|
| 377 | 377 | | |
|---|
| 378 | 378 | | (c) To the extent it is caused by the homeowner or his or her the homeowners agent, employee, general contractor, subcontractor, independent contractor, or consultant by virtue of their failure to follow the builders or manufacturers recommendations, or commonly accepted homeowner maintenance obligations. In order to rely upon this defense as it relates to a builders recommended maintenance schedule, the builder shall show that the homeowner had written notice of these schedules and recommendations and that the recommendations and schedules were reasonable at the time they were issued. |
|---|
| 379 | 379 | | |
|---|
| 380 | 380 | | (d) To the extent it is caused by the homeowner or his or her the homeowners agents or an independent third partys alterations, ordinary wear and tear, misuse, abuse, or neglect, or by the structures use for something other than its intended purpose. |
|---|
| 381 | 381 | | |
|---|
| 382 | 382 | | (e) To the extent that the time period for filing actions bars the claimed violation. |
|---|
| 383 | 383 | | |
|---|
| 384 | 384 | | (f) As to a particular violation for which the builder has obtained a valid release. |
|---|
| 385 | 385 | | |
|---|
| 386 | 386 | | (g) To the extent that the builders repair was successful in correcting the particular violation of the applicable standard. |
|---|
| 387 | 387 | | |
|---|
| 388 | 388 | | (h) To the extent that the builder complied with the building permit and gained final sign-off from the permitting body for the repairs. |
|---|
| 389 | 389 | | |
|---|
| 390 | 390 | | (i) To the extent that the builder received approval from the special inspector on the work completed for the repairs. |
|---|
| 391 | 391 | | |
|---|
| 392 | 392 | | (h) |
|---|
| 393 | 393 | | |
|---|
| 394 | 394 | | |
|---|
| 395 | 395 | | |
|---|
| 396 | 396 | | (j) As to any causes of action to which this statute does not apply, all applicable affirmative defenses are preserved. |
|---|
| 397 | 397 | | |
|---|
| 398 | 398 | | SEC. 11. If the Commission on State Mandates determines that this act contains costs mandated by the state, reimbursement to local agencies and school districts for those costs shall be made pursuant to Part 7 (commencing with Section 17500) of Division 4 of Title 2 of the Government Code. |
|---|
| 399 | 399 | | |
|---|
| 400 | 400 | | SEC. 11. If the Commission on State Mandates determines that this act contains costs mandated by the state, reimbursement to local agencies and school districts for those costs shall be made pursuant to Part 7 (commencing with Section 17500) of Division 4 of Title 2 of the Government Code. |
|---|
| 401 | 401 | | |
|---|
| 402 | 402 | | SEC. 11. If the Commission on State Mandates determines that this act contains costs mandated by the state, reimbursement to local agencies and school districts for those costs shall be made pursuant to Part 7 (commencing with Section 17500) of Division 4 of Title 2 of the Government Code. |
|---|
| 403 | 403 | | |
|---|
| 404 | 404 | | ### SEC. 11. |
|---|