DC
District Of Columbia Council Bill B25-0886

District Of Columbia 2023-2024 Regular Session

District Of Columbia Council Bill B25-0886 Compare Versions

OldNewDifferences
1- ENROLLED ORIGINAL
2-
3-
4-
5- 1
6-AN ACT
7-
8-________________
9-
10-
11-IN THE COUNCIL OF THE DISTRICT OF COLUMBIA
12-
13-____________________________
14-
15-
16-To approve, on an emergency basis, Modification Nos. 7, 8, and 10 to Contract No. DCAM-20-
17-CS-RFP-0020 with GCS, Inc. to provide construction management at-risk services for
18-Stead Park Recreation Center, and to authorize payment for the goods and services
19-received and to be received under the contract.
20-
21- BE IT ENACTED BY THE COUNCIL OF THE DISTRICT OF COLUMBIA, That this
22-act may be cited as “Modification Nos. 7, 8, and 10 to Contract No. DCAM-20-CS-RFP-0020
23-with GCS, Inc., Approval and Payment Authorization Emergency Act of 2024”.
24-
25- Sec. 2. Pursuant to section 451 of the Home Rule Act (D.C. Official Code § 1-204.51)
26-and notwithstanding the requirements of section 202 of the Procurement Practices Reform Act of
27-2010, effective April 8, 2011 (D.C. Law 18-371; D.C. Official Code § 2-352.02), the Council
28-approves Modification Nos. 7, 8, and 10 to Contract No. DCAM-20-CS-RFP-0020 with GCS,
29-Inc., to provide construction management at-risk services for Stead Park Recreation Center, and
30-authorizes payment in the amount of $15,801,253 for services received and to be received under
31-the contract.
32-
33- Sec. 3. Fiscal impact statement.
34-The Council adopts the fiscal statement of the Chief Financial Officer as the fiscal impact
35-statement required by section 4a of the General Legislative Procedures Act of 1975, approved
36-October 16, 2006 (120 Stat. 2038; D.C. Official Code § 1-301.47a).
37-
38-Sec. 4. Effective date.
39-This act shall take effect following approval by the Mayor (or in the event of veto by the
40-Mayor, action by the Council to override the veto), and shall remain in effect for no longer than
41-90 days, as provided for emergency acts of the Council of the District of Columbia in section
42-
43-
44-
45-
46- ENROLLED ORIGINAL
47-
48-
49-
50- 2
51-412(a) of the District of Columbia Home Rule Act, approved December 24, 1973 (87 Stat. 788;
52-D.C. Official Code § 1-204.12(a)).
53-
54-
55-
56-
57-______________________________
1+
2+
3+
4+
5+
6+
7+
8+MURIEL BOWSER
9+MAYOR
10+
11+
12+July 2, 2024
13+
14+
15+Honorable Phil Mendelson
5816 Chairman
5917 Council of the District of Columbia
60-
61-
18+John A. Wilson Building
19+1350 Pennsylvania Avenue, NW, Suite 504
20+Washington, DC 20004
21+
22+Dear Chairman Mendelson:
23+
24+Enclosed for consideration and enactment by the Council of the District of Columbia is an
25+emergency bill, the “Modification Nos. 7, 8, and 10 to Contract No. DCAM-20-CS-RFP-0020
26+with GCS, Inc., Approval and Payment Authorization Emergency Act of 2024”, and the
27+accompanying emergency declaration resolution.
28+
29+The legislation will approve Modifications No. 7, 8, and 10 to Contract No. DCAM-20-CS-RFP-
30+0020 with GCS, Inc. for the provision of construction management at-risk services for the Stead
31+Park Recreation Center project. The proposed Modification No. 10 is to cover the costs to replace
32+the existing syntactic turf athletic field and the replacement of the running track that surrounds the
33+athletic field. The legislation will approve payment for goods and services received and to be
34+received under the modifications.
35+
36+My administration is available to discuss any questions you may have regarding the proposed
37+contract modifications. In order to facilitate a response to any questions you may have, please
38+contact Delano Hunter, Director, Department of General Services (“DGS”), or have your staff
39+contact George G. Lewis, Chief of Contracts and Procurement, DGS, at (202) 727-2800.
40+
41+I urge the Council to take prompt and favorable action on the enclosed legislation.
42+
43+Sincerely,
44+
45+
46+
47+Muriel Bowser 1
48+2
49+3
50+4
51+5
52+6
53+7 A BILL
54+8
55+9
56+10
57+11
58+#~
59+Chairman Phil Mendelson
60+at the request
61+of the Mayor
62+12 IN THE COUNCIL OF THE DISTRICT OF COLUMBIA
63+13
64+14
65+15
66+16
67+17
68+To approve, on an emergency basis, Modification Nos. 7, 8, and 10 to Contract No. DCAM-20-
69+18 CS-RFP-0020 with GCS, Inc. to provide construction management at-risk services for
70+19 Stead Park Recreation Center, and to authorize payment for the goods and services
71+20 received and to be received under the modifications.
72+21
73+22 BE IT ENACTED BY THE COUNCIL OF THE DISTRICT OF COLUMBIA, That this
74+23 act may be cited as "Modification Nos. 7, 8, and 10 to Contract No. DCAM-20-CS-RFP-0020
75+24 with GCS, Inc., Approval and Payment Authorization Emergency Act
76+of 2024".
77+25 Sec. 2. Pursuant to section 451 of the District of Columbia Home Rule Act, approved
78+26 December 24,
79+1973 (87 Stat. 803; D.C. Official Code§ 1-204.51), and notwithstanding the
80+27 requirements
81+of section 202(a) of the Procurement Practices Reform Act of 2010, effective April
82+28 8, 2011 (D.C. Law 18-371; D. C. Official Code§ 2-352.02(a)), the Council approves
83+29 Modification Nos. 7,
84+8, and 10 to Contract No. DCAM-20-CS-RFP-0020 with GCS, Inc., to
85+30 provide construction management at-risk services for Stead Park Recreation Center, and
86+31 authorizes payment in the amount of $15,801,253 for services received and to be received under
87+32 the modifications. The proposed Modification No.
88+10 is to cover the costs to replace the existing
89+33 syntactic turf athletic field and the replacement of the running track that surrounds the athletic
90+34 field. 2
91+ Sec. 3. Fiscal impact statement. 35
92+The Council adopts the fiscal statement of the Chief Financial Officer as the fiscal impact 36
93+statement required by section 4a of the General Legislative Procedures Act of 1975, approved 37
94+October 16, 2006 (120 Stat. 2038; D.C. Official Code § 1- 301.47a). 38
95+Sec. 4. Effective date. 39
96+This act shall take effect following approval by the Mayor (or in the event of veto by the 40
97+Mayor, action by the Council to override the veto), and shall remain in effect for no longer than 41
98+90 days, as provided for emergency acts of the Council of the District of Columbia in section 42
99+412(a) of the District of Columbia Home Rule Act, approved December 24, 1973 (87 Stat. 788; 43
100+D.C. Official Code § 1- 204.12(a)). 44 GOVERNMENT OF THE DISTRICT OF COLUMBIA
101+DEPARTMENT OF GENERAL SERVICES
102+
103+
104+_______________________________________________________________________________
105+
106+
107+Pursuant to Section 202(c-1) of the Procurement Practices Reform Act of 2010, as amended,
108+D.C. Official Code § 2-352.02(c-1), the following contract summary is provided:
109+
110+COUNCIL CONTRACT SUMMARY
111+(Tipping)
112+
113+Modification Nos. 7 and 8 and Proposed Modification No. 10 to Increase Guaranteed
114+Maximum Price (“GMP”) for Contract No. DCAM-20-CS-RFP-0020 for Construction
115+Management At-Risk Services for Stead Park Recreation Center
116+
117+
118+(A) Contract Number: DCAM-20-CS-RFP-0020 (the “Contract”)
119+
120+Contractor: GCS, Inc. (the “Contractor”)
121+
122+Contractor’s Principal: Gabe Oliver
123+ goliver@gcs-sigal.com
124+
125+
126+Contract Amount: $13,474,000.00 GMP inclusive of the initial
127+NTE amount of $950,000.00 under the Letter
128+Contract
129+
130+Modification Nos. 4 and 5
131+approved by the Council as B25-0301 $1,029,370.00
132+
133+
134+Modification Nos. 7 and 8 and the
135+Proposed Modification No. 10: $1,297,883.00
136+
137+ Proposed Total Contract
138+Amount: $15,801,253.00
139+
140+Unit and Method of Compensation: Progress payments based on GMP
141+
142+Term of Contract: From June 15, 2021, through February 25, 2025
143+(Administrative Term Date) with a Final
144+Completion Date of November 27, 2024.
145+
146+Type of Contract: Cost Plus Fixed Fee with a Guaranteed
147+Maximum Price (“GMP”)
148+
149+Source Selection Method: Competitive Request for Proposals (“RFP”)
150+
151+Page 2 of 10
152+
153+
154+Department of General Services 2000 14
155+th
156+ Street, NW, Washington D.C. 20009
157+
158+
159+(B) For a contract containing option periods, the contract amount for the base period and for
160+each option period. If the contract amount for one or more of the option periods differs
161+from the amount for the base period, provide an explanation of the reason for the
162+difference:
163+
164+Not Applicable.
165+
166+(C) The goods or services to be provided, the methods of delivering goods or services, and any
167+significant program changes reflected in the proposed contract:
168+
169+Under the Contract for construction management at-risk services (DCAM-20-CS-RFP-0020)
170+(the “Contract”), the Contractor provides construction management at-risk services for the
171+renovation and modernization of Stead Park and Recreation Center, located in Ward 2 at 1625
172+P Street NW, Washington, DC 20036 (the “Project”).
173+
174+The Project generally includes but is not limited to the renovation of the existing carriage
175+house building and adding additional space in order to bring the building into compliance with
176+Americans with Disabilities Act (ADA) codes. The Project will require that the new building
177+have Net Zero and LEED Gold certification. The Project also includes renovating the existing
178+playground to the east and south of the building and renovating the spray park to the east of the
179+building. The existing playing field and basketball court are to remain in their current
180+conditions.
181+
182+Modification No. 1 extended the duration of the letter contract from August 31, 2021 to
183+December 31, 2021.
184+
185+Modification No. 2 extended the duration of the letter contract from December 31, 2021 to
186+April 30, 2022.
187+
188+Modification No. 3 extended the duration of the letter contract from April 30, 2022 to
189+September 2022.
190+
191+Modification No. 4 extended the term of the Contract through March 01, 2024, increasing the
192+GMP amount by $700,00.00 from $13,474,000.00 to $14,174,000.00. The amount of
193+Modification No. 4 was less than $1 million, thus the Council’s approval was not required.
194+
195+Modification No. 5 increased the GMP by $ 329,370.00. Since the aggregate amount of
196+Modification Nos. 4 and 5 was approved by the Council as B25- 0301.
197+
198+Modification No. 6 extended the term of the Contract through June 1, 2024.
199+
200+Modification No. 7 increased the GMP amount by $698,313.00 from $14,503,370.00 to
201+$15,201,683.00. The amount of Modification No. 7 was less than $1 million, thus the
202+Council’s approval was not required.
203+
204+Modification No. 8 extended the term of the Contract through July 15, 2024 and increased the
205+GMP amount by $100,000.00 from $15,201,683.00 to $15,301,683.00. The aggregate amount
206+Page 3 of 10
207+
208+
209+Department of General Services 2000 14
210+th
211+ Street, NW, Washington D.C. 20009
212+of Modification Nos . 7 and 8 was less than $1 million, thus the Council’s approval was not
213+required.
214+
215+Modification No. 9 extended the term of the Contract through February 25, 2025.
216+
217+Proposed Modification No. 10, if approved, will increase the GMP amount by $499,570.00
218+from $15,301,683.00 to $15,801,253.00. The aggregate amount of Modification Nos . 7 and 8
219+and the Proposed Modification No. 10 exceeds $1 million ; therefore, Council approval is
220+required for this Contract action.
221+
222+(D) The selection process, including the number of offerors, the evaluation criteria, and the
223+evaluation results, including price, technical or quality, and past performance
224+components:
225+
226+On November 25, 2020, the Department issued the RFP to engage a contractor to provide
227+construction management at-risk services for the renovation and modernization of the Stead
228+Park Recreation Center. Seven (7) addenda were issued to this RFP.
229+
230+Addendum No. 1- Issued on December 8, 2020:
231+
232+- Provided the platform for the Contractor’s pre-proposal conference meeting and revised the
233+ solicitation number.
234+
235+Addendum No. 2- Issued on December 24, 2020:
236+
237+- Corrected the RFP number from DCAM-20-AE-0020 to DCAM-20-CS-RFP-0020.
238+
239+Addendum No. 3- Issued on January 6, 2021:
240+
241+- Provided the questions and answers spreadsheet.
242+- Revised Attachments Nos. B, K, and M in the RFP.
243+- Incorporated Attachments Nos. S, U, O, H, and I.
244+
245+Addendum No. 4- Issued on January 8, 2021:
246+
247+- Provided the revised drawings.
248+
249+Addendum No. 5- Issued on January 12, 2021:
250+
251+- Incorporated The Geotechnical Report, LEED Score Card, Environmental Report and
252+ Drawings.
253+
254+Addendum No. 6- Issued on January 19, 2021:
255+
256+- Extended the proposals due date to January 28, 2021 at 2:00 p.m.
257+- Incorporated the list of attendees to the site visit.
258+- Issued the revised BIM Requirements (Attachment R to the RFP).
259+
260+Addendum No. 7- Issued on January 25, 2021:
261+Page 4 of 10
262+
263+
264+Department of General Services 2000 14
265+th
266+ Street, NW, Washington D.C. 20009
267+
268+- Extended the proposals due date to February 4, 2021 at 2:00 p.m.
269+
270+On the proposals’ due date, February 4, 2021, ten (10) firms (collectively, the “Offerors” and
271+each individually, an “Offeror”) submitted bids in a timely manner.
272+
273+Technical Evaluation:
274+
275+The proposals were evaluated by a technical evaluation panel (“Panel”) in accordance with the
276+criteria set forth in the RFP. Each proposal was independently evaluated utilizing a point scale,
277+certain points of which were for the technical evaluation component as follows: (i) Offeror’s
278+past performance relevant experience and capabilities; (ii) Offeror’s key personnel; and (iii)
279+project management plan and schedule as discussed more fully below. The Panel virtually met
280+on March 12, 2021 to develop a consensus technical score. Prior to convening for the
281+evaluation meeting, each of the Panel members individually completed an evaluation of the
282+proposals. In doing so, each Panel member rated each Offeror with respect to specific
283+subfactors in the five categories. In developing the consensus score, the Panel discussed the
284+details of each of the proposals in light of the evaluation factors. Following the Panel’s
285+discussions and consensus ratings of the Offerors, the ratings were converted to numbers.
286+
287+Pricing Evaluation:
288+
289+As outlined in the RFP, in addition to the technical scoring, certain points were available for
290+price. The RFP required Offerors to submit pricing in the form of: (i) a Preconstruction Fee;
291+(ii) a Construction Management Fee; and (iii) a General Conditions Budget. Offerors were
292+assigned price points on a sliding scale, with the lowest proposed price receiving all of the
293+available points and the remaining proposals receiving a portion of the available points relative
294+to their position in the range established by the highest-price Offeror.
295+
296+Certified Business Enterprise Preference Points:
297+
298+In addition to the price and technical scoring, a certain number of points were available for
299+each Offeror based on its status as a Certified Business Enterprise (“CBE”) as determined by
300+the Department of Small and Local Business Development (“DSLBD”). The Contractor was so
301+certified and received points accordingly.
302+
303+Contracting Officer’s Independent Evaluation:
304+
305+The DGS Contracting Officer, after carefully reviewing the evaluation process followed by the
306+Panel, their notes and scoresheets, and their final consensus technical evaluation, conducted an
307+independent assessment of each of the proposals. In addition, the Contracting Officer also
308+found the proposed pricing to be fair and reasonable. The Contractor was the highest scoring
309+Offeror; thus, the Contracting Officer awarded the Contract to the Contractor. After thorough
310+review of TEP consensus report, the consensus notes and in absence of the original award
311+memo, the current contracting officer believes that the original award to the Contractor was
312+made in good faith and clear judgment based upon criteria presented in the RFP. In addition,
313+the Contracting Officer also found the proposed pricing to be fair and reasonable. The
314+Contractor was the highest scoring Offeror; thus, the Contracting Officer awarded the Contract
315+to the Contractor.
316+Page 5 of 10
317+
318+
319+Department of General Services 2000 14
320+th
321+ Street, NW, Washington D.C. 20009
322+
323+Contract Award:
324+
325+By award memorandum executed on May 18, 2021, the Department awarded Contract No.
326+DCAM-20-CS-RFP-0020 to the Contractor as such award would be most advantageous to the
327+District.
328+
329+(E) A description of any bid protest related to the award of the contract, including whether
330+the protest was resolved through litigation, withdrawal of the protest by the protestor, or
331+voluntary corrective action by the District. Include the identity of the protestor, the
332+grounds alleged in the protest, and any deficiencies identified by the District as a result of
333+the protest:
334+
335+The award of the Contract was not protested.
336+
337+(F) The background and qualifications of the proposed contractor, including its organization,
338+financial stability, personnel, and performance on past or current government or private
339+sector contracts with requirements similar to those of the proposed contract:
340+
341+GCS, Inc. is a CBE and long- time resident- owned business with decades of general contracting
342+and design- build experience in the District of Columbia. The firm has a tremendous portfolio
343+of relevant design- build services experience within the past decade including several projects
344+performed within Washington, DC. The Contractor’s team brings together highly qualified
345+construction professionals with complementary strengths to successfully deliver the Stead Park
346+modernization.
347+
348+The Contractor and its team are fully knowledgeable of the critical need to perform with a high
349+degree of quality and deliver this Project on- schedule, while maintaining operations for the
350+surrounding facilities and minimizing disruptions to the surrounding neighborhood. The
351+Contractor has been determined responsible in accordance with 27 DCMR 4706.1
352+
353+(G) The period of performance associated with the proposed change, including date as of
354+which the proposed change is to be made effective:
355+
356+The period of performance associated with Modification Nos. 7 and 8 is from June 14, 2021,
357+through February 25, 2025. The proposed Modification No. 10 will become effective upon
358+approval by the Council and execution by the Department.
359+
360+(H) The value of any work or services performed pursuant to a proposed change for which
361+the Council has not provided approval, disaggregated by each proposed change if more
362+than one proposed change has been aggregated for Council review:
363+
364+On September 26, 2023, Modification No. 7 was executed for the amount of $698,313.00 and
365+increased the GMP amount to $15,201,683.00 ($14,503,370.00 + $698,313.00).
366+
367+On November 3, 2023, Modification No. 8 was executed for the amount of $100,000.00 which
368+increased the GMP amount to $15,301,683.00 ($15,201,683.00 + $100,000.00) and extended
369+the term of the Contract from June 01, 2024 to July 15, 2024.
370+Page 6 of 10
371+
372+
373+Department of General Services 2000 14
374+th
375+ Street, NW, Washington D.C. 20009
376+The aggregate amount of both Modifications No. 7 and 8 was less than $1 million; thus,
377+Council approval was not required.
378+
379+(I) The aggregate dollar value of the proposed changes as compared with the amount of the
380+contract as awarded:
381+
382+CA24-0575 was Deemed Approved on Jul 07, 2022. On August 11, 2022, the Department
383+executed the Definitive Contract for the amount of 13,474.000.00.
384+
385+Modifications No. 4 and 5 increased the GMP price from $13,474,000.00 to $14,503,370.00
386+($13,474,000.00 + $700,000.00 + $329,370.00), and extended the term of the Contract from
387+December 01, 2023 through March 01, 2024, approved by the Council on June 2, 2023 as B25-
388+0301.
389+
390+On September 26, 2023, Modification No. 7 was executed for the amount of $698,313.00 and
391+increased the GMP amount to $15,201,683.00 ($14,503,370.00 + $698,313.00). On November
392+3, 2023, Modification No. 8 was executed for the amount of $100,000.00 which increased the
393+GMP amount to $15,301,683.00 ($15,201,683.00 + $100,000.00) and extended the term of the
394+Contract from June 01, 2024 to July 15, 2024. The aggregate amount of both Modifications
395+No. 7 and 8 was less than $1 million; thus, Council approval was not required. The proposed
396+Modification No. 10 for the amount of $499,570.00, if approved, will increase the GMP to
397+$15,801,253.00 ($15,301,683.00 + $499,570.00). The aggregate amount of Modification Nos.
398+7 and 8 and the Proposed Modification No. 10 exceeds $1 million; therefore, Council approval
399+is required for this Contract action.
400+
401+
402+(J) Date on which the contracting officer was notified of the proposed change:
403+
404+March 26, 2024.
405+
406+(K) The reason why the proposed change was sent to Council for approval after it is intended
407+to take effect:
408+
409+On September 26, 2023, Modification No. 7 was executed for the amount of $698,313.00 and
410+increased the GMP amount to $15,201,683.00 ($14,503,370.00 + $698,313.00). On November
411+3, 2023, Modification No. 8 was executed for the amount of $100,000.00 which increased the
412+GMP amount to $15,301,683.00 ($15,201,683.00 + $100,000.00) and extended the term of the
413+Contract from June 01, 2024 to July 15, 2024. The aggregate amount of both Modifications
414+No. 7 and 8 was less than $1 million; thus, Council approval was not required.
415+
416+However, proposed Modification No. 10 would tip the amount of the modifications over $1
417+million; thus, Council approval of these modifications is required.
418+
419+(L) The reason for the proposed change:
420+
421+The proposed Modification No. 10 in the amount of $499,570.00, if approved, would cover
422+Costs for modernization of the existing recreation facility with an addition and to bring it up to
423+ADA standards As the aggregate amount of Modification Nos. 7 and 8, and Proposed
424+Page 7 of 10
425+
426+
427+Department of General Services 2000 14
428+th
429+ Street, NW, Washington D.C. 20009
430+Modification No. 10 is $1,297,883.00, an amount over $1 million; therefore, Council approval
431+of the Contract and these modifications is required.
432+
433+(M) The legal, regulatory, or contractual authority for the proposed change:
434+
435+Articles 3 and 4 of the Department’s Standard Contract Provision (Construction Contracts)
436+provide authority for the issuance of modifications. Additionally, as Modification Nos. 7, 8,
437+and 10 would increase the total Contract value over $1 million, this contract action is subject to
438+the requirements of the District of Columbia Home Rule Act, codified at D. C. Official Code §
439+1-204.51(b). Thus, Council review and approval of the proposed contract action are required
440+under the District of Columbia Home Rule Act, and the proposed contract action would be
441+authorized by Council’s enactment of “Modification Nos. 7, 8, and 10 to Contract No. DCAM -
442+20-CS-RFP-0020 with GCS, Inc. Approval and Payment Authorization Emergency Act of
443+2024” pursuant to D.C. Official Code § 2- 352.02(c-1).
444+
445+(N) A summary of the subcontracting plan required under section 2346 of the Small, Local,
446+and Disadvantaged Business Enterprise Development and Assistance Act of 2005, as
447+amended, D.C. Official Code § 2- 218.01 et seq. (“Act”), including a certification that the
448+subcontracting plan meets the minimum requirements of the Act and the dollar volume
449+of the portion of the Contract to be subcontracted, expressed both in total dollars and as
450+a percentage of the total Contract amount:
451+
452+The Contractor is a certified business enterprise in accordance with the Act (CBE Number:
453+LZXR28836012025). Notwithstanding the foregoing, the Contractor has submitted its
454+subcontracting plan as required by law.
455+
456+Total Contract Value: $15,801,253.00
457+Minimum SBE Sub-Contracting Requirement: $5,530,439.00 - 35%
458+Actual SBE Subcontracting Amount/Percentage: $5,781,031.00 - 37%
459+
460+
461+(O) Performance standards and the expected outcome of the proposed contract:
462+
463+The Department is implementing the Project through a CMAR approach. The Contractor will
464+collaborate and work in unison with the Architect/Engineer to review the design documents
465+and advise on whether they are consistent with the Department’s budget and schedule for the
466+Project. The Project’s scope of work is divided into two phases: (i) Preconstruction Phase and
467+(ii) the Construction Phase. During the Preconstruction Phase, the Contractor is required to
468+work with the Architect/Engineer to develop a schedule, budget and design that accomplishes
469+the Department’s goals and objectives. The Contractor is required to participate in the
470+development of the construction documents by providing cost estimating, scheduling,
471+identifying long- lead purchasing items and performing constructability reviews. The
472+Department will continue to monitor the Contractor’s performance to ensure consistency with
473+the Contract’s terms and conditions.
474+
475+(P) The amount and date of any expenditure of funds by the District pursuant to the contract
476+prior to its submission to the Council for approval:
477+
478+Page 8 of 10
479+
480+
481+Department of General Services 2000 14
482+th
483+ Street, NW, Washington D.C. 20009
484+On September 26, 2023, Modification No. 7 was executed for the amount of $698,313.00 and
485+increased the GMP amount to $15,201,683.00 ($14,503,370.00 + $698,313.00). On November
486+3, 2023, Modification No. 8 was executed for the amount of $100,000.00 which increased the
487+GMP amount to $15,301,683.00 ($15,201,683.00 + $100,000.00) and extended the term of the
488+Contract from June 01, 2024 to July 15, 2024. The aggregate amount of both Modifications
489+No. 7 and 8 was less than $1 million; thus, Council approval was not required.
490+
491+(Q) A certification that the proposed contract is within the appropriated budget authority for
492+the agency for the fiscal year and is consistent with the financial plan and budget adopted
493+in accordance with D.C. Official Code §§ 47- 392.01 and 47- 392.02:
494+
495+The aggregate amount of Modification Nos. 7 and 8 and the Proposed Modification No. 10 is
496+within the appropriated budget authority for the agency, for the fiscal year. The Agency Fiscal
497+Officer has certified that the aggregate GMP amount of Modification Nos . 7, 8 and the
498+proposed Modification No. 10 is consistent with the financial plan and budget adopted in
499+accordance with D.C. Official Code §§ 47- 392.01 and 47- 392.02. The relevant Fiscal
500+Sufficiency certification accompanies this Council Package.
501+
502+(R) A certification that the contract is legally sufficient, including whether the proposed
503+contractor has any pending legal claims against the District:
504+
505+Modification Nos. 7 and 8 and the proposed Modification No. 10 have been deemed legally
506+sufficient by the District’s Office of the Attorney General . The Contractor does not appear to
507+have any currently pending legal claims against the District.
508+
509+(S) A certification that Citywide Clean Hands database indicates that the proposed
510+contractor is current with its District taxes. If the Citywide Clean Hands Database
511+indicates that the proposed contractor is not current with its District taxes, either: (1) a
512+certification that the contractor has worked out and is current with a payment schedule
513+approved by the District; or (2) a certification that the contractor will be current with its
514+District taxes after the District recovers any outstanding debt as provided under D.C.
515+Official Code § 2-353.01(b):
516+
517+The Citywide Clean Hands database indicates that the Contractor is current with its District
518+taxes. The applicable Clean Hands certification for the Contractor accompanies this Council
519+Package.
520+
521+(T) A certification from the proposed contractor that it is current with its federal taxes, or
522+has worked out and is current with a payment schedule approved by the federal
523+government:
524+
525+The Contractor has certified that it is in compliance with federal tax laws.
526+
527+(U) The status of the proposed contractor as a certified local, small, or disadvantaged
528+business enterprise as defined in the Small, Local, and Disadvantaged Business
529+Enterprise Development and Assistance Act of 2005, as amended; D.C. Official Code § 2-
530+218.01 et seq .:
531+
532+Page 9 of 10
533+
534+
535+Department of General Services 2000 14
536+th
537+ Street, NW, Washington D.C. 20009
538+According to the DSLBD’s website, the Contractor is a certified Local Business Enterprise.
539+The Contractor’s CBE Number is LZXR28836012025 with an expiration date of January 19,
540+2025.
541+
542+(V) Other aspects of the proposed contract that the Chief Procurement Officer considers
543+significant:
544+
545+Not Applicable.
546+
547+(W) A statement indicating whether the proposed contractor is currently debarred from
548+providing services or goods to the District or federal government, the dates of the
549+debarment, and the reasons for debarment:
550+
551+The Contractor is not debarred from providing services to the Government of the District of
552+Columbia or the Federal Government according to the Office of Contracts and Procurement’s
553+Excluded Parties List and the Federal Government’s Excluded Parties List.
554+
555+(X) Any determination and findings issues relating to the contract’s formation, including any
556+determination and findings made under D.C. Official Code § 2 -352.05 (privatization
557+contracts):
558+
559+Not Applicable.
560+
561+(Y) Where the contract, and any amendments or modifications, if executed, will be made
562+available online:
563+
564+Contract award information, Contract and Modification Nos. 4, 5, 7, and 8 are available on the
565+Department’s website. A copy of the proposed Modification No. 10 (if approved) will be made
566+available.
567+
568+(Z) Where the original solicitation, and any amendments or modifications, will be made
569+available online:
570+
571+The original solicitation and any amendments were posted on the Department’s website.
572+
573+(AA) A notation identifying: (i) whether the Contractor is a covered contractor, as that term is
574+defined in D.C. Official Code § 1-1161.01; and (ii) to which prohibited recipients, as that
575+term is defined in D.C. Official Code § 1-1161.01(45D), the Contractor is prohibited from
576+making campaign contributions and during what prohibited period, as that term is
577+defined in § 1-1161.01(45C).
578+
579+Not Applicable. This Contract was executed prior to the November 9, 2022, effective date of
580+D.C. Law 22- 250.
581+
582+(BB) List of contracts that the Contractor holds and/or is currently seeking with the D istrict of
583+Columbia agencies.
584+
585+List of Contracts the GCS Inc. holds with the District agencies:
586+
587+Page 10 of 10
588+
589+
590+Department of General Services 2000 14
591+th
592+ Street, NW, Washington D.C. 20009
593+S/NO Contract Number Contract Caption Value of the Contract
594+1 DCAM-20-CS-RFP-0020 CMAR for Stead Park Recreation Center $15,301,683.00
595+2 DCAM-20-CS-RFQ-0002B CMAR for Texas Avenue Dog Park $962,286.00
596+3 DCAM-23-CS-RFP-0004 CMAR for Congress Heights Recreation Center $990,000.00
597+4 DCAM-20-CS-RFQ-0002B Design-Build Services for DOC Temporary Boiler $2,568,100.00
598+5 DCAM-23-CS-RFP-0005 Design-Build Services for Malcolm X at Green
599+Elementary School Modernization
600+$5,995,180.00
601+6 DCAM-20-CS-RFQ-0002B
602+/ RFTOP-CS-0035
603+Design-Build Services for Deanwood Recreation center
604+IT Room Upgrade
605+$60,000.00
606+7 DCAM-22-CS-RFP-0020 Design Bulder for DOC Central Boiler Plant $21,450,090.00
607+8 DCAM-24-CS-RFP-0003 CMAR for Southeast Tennis and Learning Center $990,000.00
608+
609+List of the Contracts that GCS Inc. is seeking with the District:
610+
611+S/NO Contract Number Contract Caption Value of the Contract
612+1 DCAM-24-CS-RFP-0014 Design-Build Services for Langdon Park Community
613+Center
614+29,000,000
615+ 1101 4
616+th
617+Street, SW
618+Washington, DC 20024
619+Date of Notice:April 3, 2024 L0011586783Notice Number:
620+FEIN: **-***8921
621+Case ID: 2542283
622+ 
623+Government of the District of Columbia
624+Office of the Chief Financial Officer
625+Office of Tax and Revenue
626+GCS INC
627+1140 3RD ST NE STE 320
628+WASHINGTON DC 20002-7899
629+
630+Branch Chief, Collection and Enforcement Administration
631+Authorized By Melinda Jenkins
632+To validate this certificate, please visit MyTax.DC.gov. On the MyTax DC homepage, click the
633+“Validate a Certificate of Clean Hands” hyperlink under the Clean Hands section.
634+CERTIFICATE OF CLEAN HANDS
635+As reported in the Clean Hands system, the above referenced individual/entity has no outstanding
636+liability with the District of Columbia Office of Tax and Revenue or the Department of Employment
637+Services. As of the date above, the individual/entity has complied with DC Code § 47-2862, therefore
638+this Certificate of Clean Hands is issued.
639+TITLE 47. TAXATION, LICENSING, PERMITS, ASSESSMENTS, AND FEES
640+CHAPTER 28 GENERAL LICENSE
641+SUBCHAPTER II. CLEAN HANDS BEFORE RECEIVING A LICENSE OR PERMIT
642+D.C. CODE § 47-2862 (2006)
643+§ 47-2862 PROHIBITION AGAINST ISSUANCE OF LICENSE OR PERMIT
644+1101 4th Street SW, Suite W270, Washington, DC 20024/Phone: (202) 724-5045/MyTax.DC.gov
645+  GOVERNMENT OF THE DISTRICT OF COLUMBIA
646+DEPARTMENT OF GENERAL SERVICES
647+
648+
649+
650+
651+
652+
653+Memorandum
654+
655+To: Delano Hunter
656+Director
657+
658+From: Antoinette Hudson Beckham
659+Agency Fiscal Officer
660+Department of General Services
661+
662+Reference: Contract No. DCAM-20-CS-RFP-0020
663+ Construction Management At-Risk Services for Stead Park Recreation Center
664+
665+ Date: May 22, 2024
666+
667+Subject: Fiscal Sufficiency Certification
668+
669+
670+
671+
672+In my capacity as the Agency Fiscal Officer of the Department of General Services (the
673+“Department”), I hereby certify that the Construction Management At-Risk Services for Stead
674+Park Recreation Center (DCAM-20-CS-RFP-0020) (the “Contract”), with GCS, Inc. (the
675+“Contractor”), in the amount of $1,297,883.00 is consistent with the Department’s current budget
676+and that adequate funds are available in the budget for the expenditure.
677+
678+Per the Department’s Contracts & Procurement team, on June 15, 2021, the Letter Contract was
679+executed by the Department, with an initial Not-to-Exceed amount of $950,000.00. On August 11,
680+2022, the Definitized Contract was executed and established a Guaranteed Maximum Price
681+(“GMP”) of $13,474,000.00 ($950,000.00 + $12,524,000.00). Modifications No. 4 and 5 increased
682+the GMP price to $14,503,370.00 ($13,474,000.00 + $700,000.00 + $329,370.00).
683+
684+On September 26, 2023, Modification No. 7 was executed for the amount of $698,313.00. The
685+GMP amount increased to $15,201,683.00 ($14,503,370.00 + $698,313.00). On November 3, 2023,
686+Modification No. 8 was executed for the amount of $100,000.00. The GMP amount increased to
687+$15,301,683.00 ($15,201,683.00 + $100,000.00). The aggregate amount of both Modifications No.
688+7 and 8 was less than $1m; thus, Council approval was not required. On February 28, 2024,
689+Modification No. 9 was executed and extended the Contract’s term from July 15, 2024 to February
690+25, 2025 with no impact on the GMP amount. The proposed Modification No. 10 for the amount
691+of $499,570.00 will increase the GMP amount to $15,801,253.00 ($15,301,683.00 + $499,570.00). Fiscal Sufficiency Review
692+Contract No. DCAM-20-CS-RFP-0020
693+Construction Management At-Risk Services for Stead Park Recreation Center
694+
695+
696+Page 2 of 10
697+
698+The aggregate total sum of Modifications No. 7 and 8 and the Proposed Modification No. 10 is
699+$1,297,883.00; therefore, Council approval is required.
700+
701+Per C&P, the proposed Contract increase of $499,570.00 is for modernization of the existing recreation
702+facility with an addition and to bring it up to ADA standards.
703+
704+The Department of General Services (DGS – Implementing AGY) has $1,192.323.00 in the
705+Department of Parks & Recreation (DPR – Owner AGY) cumulative budget authority balance.
706+There was $5,560.00 funded in the DGS FY23 operating budget, via an approved reverse capital
707+paygo to operating reprogramming from DPR implemented capital projects. Lastly, there is
708+$100,000.00 funded from the capital inter -agency project, where DPR is the buyer and DGS is
709+the seller. The total is $1,297,883.00 ($1,192,323.00 + $5,560.00 + $100,000.00).
710+
711+The PASS/DIFS information is attached/ below.
712+
713+Project Name Project
714+Number
715+AY Fund
716+Detail
717+Imp.
718+AGY
719+Owner
720+AGY
721+RK/PO Amount Comments
722+AM0.STDDPC.ST
723+EAD PARK REC
724+CENTER
725+IMPROVEMENTS
726+100243 N/A 3030300 AM0 HA0 PO695251 $692,753.00 Modification
727+No. 7
728+CCD Reverse
729+Capital Paygo to
730+Operating Funding
731+201552 N/A 1010001 AM0 AM0 PO695238 $5,560.00 Modification
732+No. 7
733+(FY2023
734+Ineligible
735+Costs)
736+HA0.AM0_Stead
737+Park_IA_DGS
738+300208 N/A 3034345 AM0 HA0 PO700661 $100,000.00 Modification
739+No. 8 – Inter
740+agency funds
741+AM0.QN702C.AT
742+HLETIC FIELD
743+AND PARK
744+IMPROVEMENTS
745+100182 N/A 3030300 AM0 AM0 RK266072 $499,570.00 Proposed
746+Modification
747+No. 10
748+Total $1,297,883.00
749+
750+\
751+
752+
753+
754+ _____________________________
755+ Antoinette Hudson Beckham
756+ Agency Fiscal Officer
757+Department of General Services
758+
759+
760+
761+
762+1350 Pennsylvania Avenue, N.W., Suite 409, Washington, D.C. 20004 Phone (202) 724-5524 Email: megan.browder@dc.gov
763+
764+GOVERNMENT OF THE DISTRICT OF COLUMBIA
765+OFFICE OF THE ATTORNEY GENERAL
766+
767+
768+
769+
770+
771+
772+
773+Legal Counsel Division
774+
775+
776+
777+MEMORANDUM
778+ TO: Tomás Talamante
779+Director
780+Office of Policy and Legislative Affairs
781+ FROM: Megan D. Browder
782+ Deputy Attorney General
783+ Legal Counsel Division
784+ DATE: June 14, 2024
785+ SUBJECT: Legal Sufficiency Review of the “Modification Nos. 7, 8, and 10 to Contract No. DCAM-20-CS-RFP-0020 with GCS, Inc. Approval and Payment Authorization
786+Emergency Act of 2024” and Accompanying Emergency Declaration Resolution
787+
788+(AE-24-301)
789+________________________________________________________________________
790+This is to Certify that this Office has reviewed the above- referenced
791+legislation and that we have found it to be legally sufficient. If you have any questions in this regard, please do not hesitate to call me at (202) 724- 5524.
62792
63793
64794
65795 _________________________________
66-Mayor
67-District of Columbia
68-
69-
70-
71-
796+Megan D. Browder
797+
798+
799+
800+ MODIFICATION OF CONTRACT
801+1. Contract Number Page of Pages
802+DCAM-20-CS-RFP-0020 1 I 2
803+2. Modification Number 3. Effective Date 4. Requisition/Purchase Request No. 5. Caption
804+Construction Management At-Risk Services for
805+Modification No. 7 See Block 16C RK255281& RK256204 Stead Park Recreation Center
806+6. Issued By: 7. Administered By (If other than line 6)
807+Department of General Services Department of General Services
808+Contracting and Procurement Division Capital Construction Division
809+3924 Minnesota Ave NE, 5th Floor 3924 Minnesota Ave NE, 5th Floor
810+Washington, DC 20019 Washington, DC 20019
811+8. Name and Address of Contractor (No. Street, city, country, state and ZIP Code) 9A. Amendment of Solicitation No.
812+Gabe Oliver 9B. Dated (See Item 11)
813+GCS, Inc.
814+3020 Yost Place, NE 10A. Modification of Contract/Order No.
815+Washington, DC 20018
816+x
817+DCAM-20-CS-RFP-0020
818+Email: msigal@gcs-sigal.com 10B. Dated (See Item 13)
819+gloiver@gcs-sigal.com Auqust 11, 2022
820+11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS
821+_jThe above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers LJis extended. LJ is not extended.
822+Olfers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the
823+following methods: (a) By completing Items 8 and 15, and returning 1 copies of the amendment: (b) By acknowledging receipt of this
824+---
825+amendment on each copy of the ofter submitted; or (c) By separate letter or fax which includes a reference to the solicitation and
826+amendment number. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS
827+PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change
828+an ofter already submitted, such change may be made by letter or fax, provided each letter or telegram makes reference to the
829+solicitation and this amendment, and is received prior to the opening hour and date specified.
830+12. Accounting and Appropriation Data (If Required)
831+13. TH IS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,
832+IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14
833+A. This change order is issued pursuant to: (Specify Authority)
834+The changes set forth in Item 14 are made in the contract/order no. in item 10A.
835+B. The above numbered contract/order is modified to reflect the administrative changes (such as changes in paying office, appropriation
836+date, etc.) set forth in item 14.
837+C. This supplemental agreement is entered into pursuant to authority of:
838+x
839+D. Other (Specify type of modification and authority) Title 27 DCMR Sections 4728 and Contract No. DCAM-20-CS-RFP-0020
840+E. IMPORTANT: Contractor LJis not, L!J is required to sign this document and return 1 copy to the issuing office.
841+---
842+14. Description of amendment/modification (Organized by UCF Section headings, including solicitation/contract subject matter where feasible.)
843+Contract No. DCAM-20-CS-RFP-0020 for Construction Manager at Risk ("CMAR") Services for Stead Park Recreation Center {the "Project") is
844+hereby modified as follows:
845+1. Section 6.i Guaranteed Maximum Price ("GMP"): The contractor's GMP is hereby increased by $698,313.00 from $14,503,370.00 to
846+$15,201,683.00 to incorporate added Costs for Unforeseen Conditions, re-design and unsuitable soils for the Stead Park Recreation Center
847+2. Terms & Conditions. All other terms and conditions remain unchanged.
848+3. Release. It is mutually agreed that in exchange for this Change Order and other consideration, the Contractor hereby releases, waives, settles
849+and holds the Department harmless from any and all actual or potential claims or demands for delays, disruptions, additional work, additional time,
850+additional cost, contract extensions, compensations or liability under any theory, whether known or unknown, that the Contractor may have now or
851+in the future against the Department arising from or out of, as consequences or result of, relating to or in any manner connected with this
852+Modification, the above-referenced Project, and the Contract work.
853+15A. Name and Title of Signer 16A. Name of Contracting Officer
854+Gabe Oliver, Vice Pres ident ~ Obaidullah Ranjbar
855+'5B GCS, loo d
856+;~;;;:
857+16B. District of Columbia 16C. Date Signed
858+:l-3 r? (Sig~ure of person authorized to sign) (Sianature of Contractina Officer) (Continuation)
859+Contract Number
860+DCAM-20-CS-RFP-0020
861+4. Contract Recap:
862+Letter Contract
863+Modification No. 1
864+Modification No. 2
865+Modification No. 3
866+Definitive Contract
867+Modification No. 4
868+Modification No. 5
869+Modification No. 6
870+Modification No. 7
871+Guaranteed Maximum Price:
872+Modification No.
873+Modification No. 7
874+Letter Contract Executed on June 14, 2021
875+Administrative -Time Extension
876+Administrative -Time Extension
877+Administrative -Time Extension
878+Definitive Contract Executed on August 11, 2022
879+Incorporating ADA Impact Cost and Time Extension
880+Incorporates Added Cost for unforseen condition
881+Administrative -Time Extension
882+Incorporates Added Cost for unforseen condition, re-design and
883+unsuitable soils for the Stead Park Recreation Center
884+Page of Pages
885+2 of 2
886+$950 000 00
887+$0.00
888+$0.00
889+$0.00
890+$13,474,000.00
891+$700,000.00
892+$329,370.00
893+$0.00
894+$698,313.00
895+$15 201 683 00
896+
897+
898+
899+
900+
901+
902+
903+
904+
905+
906+
907+ContNaror PageoPanes
908+MODIFICATIONOFCONTRACT eneronee20 + i>
909+f=WoaieatonNaber freociveDate[iReaustionPurchaseRequestNo.Caplon
910+ConstructionManagementAt-RiskServicesfr
911+ModificationNo.8 SeeBlock160 4263566 SteadParkRecreationCenter
912+sued. FRararsteredby(ohare6)
913+DepartmentofGeneralServices DepartmentofGeneralServices
914+ContractingandProcurementDivision CapitalCnstrucionDivision
915+3924MinnesotaAveNE,SthFloor 3924MinnesotaAveNE,SthFloor
916+Washington,OC20018 Washington,DC20019
917+TaeandharesofContec(Ne.Setiy,cour,sateandiCode)—]—[BAArnenamentofSaicatonNo
918+GabeOlver [5Dated(SeeemTy
919+GCS,ne.
920+3020YostPlace,NE HoxWeaiicatonofConracvOrsorNo
921+Washington,DC20018 x|OCAM.20.08-RFP.0020
922+Ema:msigal@gce-sigalcom 08.Date(Seetem13)
923+sioner@geragalcon Jaugust11,2022
924+TLTHISTEMONLYAPPLIESTOAMENDMENTSOFSOLICITATIONS:
925+|TravenorberedsottatnisamendedasseoiRe4.TheDouranditespecigxrecebofOfer]_Jead Lifrratoaenaea
926+tersmustacknowedgereceiptofthisamendmentprothehouanddatespiedinhesationosamended,byoneofthe
927+{allowingmethods:(8)Bycompletingtems8and15,andreturing_1_coplesfheamendment(2)Byacknowledgingreceiptofthis
928+‘amendmentoneachcopyoftheoffersubmitedor(c)Bysoparatletrafaxwhichincludesareterencetotheeolaionand
929+amendmentnumber.FAILUREOFYOURACKNOWLEDGEMENTTOBERECEIVEDATTHEPLACEDESIGNATEDFORTHERECEIPTOFOFFERS
930+PRIORTOTHEHOURANDDATESPECIFIEDMAYRESULTINREJECTIONOFYOUROFFER.ibyvitueofhisamendmentyousietochange
931+{anofferalreadysubmited,suchchangemaybemadebylterofax,providedeachletterortlegrammakesreferencetothe
932+solictationandthisamendment,andsreceivedpirtotheopeninghouranddatespecie,
933+2:AccountingandAppropriationDaa(fRequired)
934+
935+ 13:THISITEMAPPLIESONLYTOMODIFICATIONSOFCONTRACTSIORDERS,
936+FTMODIFIESTHECONTRACTIORDERNO.ASDESCRIBEDINITEM14
937+[&Thischangeorder esuedpursuant:(SpectyAuthority)
938+[Thechangessetforthintem14aremadeinthecontractorno.intem108.
939+B.Theabovenumberedcontractorderismodifiedtorefiecttheadminitraivechanges(euchachangeshpayingSco,appropriation
940+date,etc.)setforthintem14
941+[cThissupplementalagreementenierediopursuantoaonof
942+
943+
944+
945+ "X_|®-Otierpecttypeofmoaiicaionandachoriy)Tie27DOMRSections4728andGoniractNo.DCAM-Z0-CS-RFP-O0ZO
946+JE-WPORTANT.——Contracor]|[snot[Xerequredtospntsdocumentandrum
947+ apytoeasingaoe,
948+
949+ [74Descriptioncfamendmentimodication(OrganizedbyUCFSealionheadings,includingsolGtation/contractsubjeckmatterwhereTeasley)
950+{ContractNo.DCAM-20-CS-RFP-0020forConstructionManageratRisk(‘CMAR’)ServicesforSteadParkRecreationCenter(the"Projectis
951+herebymodifiedasfollows:
952+1.ValueofAgreementTheadditionalcostisduetotheRedesignofPlaygroundEquipment.TheContractValueIncreasedtror18,201,683.00.
953+Joy$100,000.00to$15,301,683.00.ThisincreaseistoauthorizeGCS,Inc."TheContractor’)toperformadditonalservicesasdescribedinthe
954+Jpotentalchangeorder(AttachmentA).Innoeventshallthecontractorbepaidmorethan$15,301,683.00unlesstheContractor,isauthorizedto
955+JexceedthislimitinadvanceandinwritingbyDGSContractingOfficer.
956+2.SubstantialCompletionDate.TheSubstantialCompletionDateisherebytoextendfromNovember03,2023,toDecember
957+/18,2023.ContracttimeextensionduetoDOEEreviewandapprovalofthereviseddrawingsforBioretention#5re-designdueto
958+lunforeseenexistingconditionsandsiteutilities.
959+3.FinalCompletionDate.TheFinalCompletionDateisherebytoextendfromMarch01,2024toApril15,2024,
960+4.AdministrativeTermDate:TheAdminisvatveTermDateisherebyToextendFomJune01,2024toJuly162024,
961+
962+
963+
964+ -Terms&Conditions.Allothertermsandconditionsremainunchanged.
965+[s.Release.itismutuallyagreedthatinexchangeforthisCostModificationandotherconsideration,theContractorherebyreleases,waives,settles
966+[andholdstheDepartmentharmlessfromanyandallactualorpotentialclaimsordemandsfordelays,disruptions,additionalwork,adionaltime,
967+Jadaitionalcost,contractextensions,compensationsorlabilityunderanytheory,whetherknownorunknown,thattheContractormayhavenoworin]
968+thefutureagainsttheDepartmentarisingfromoroutof,asconsequencesorresultof,relatingtoorinanymannerconnectedwiththisModification,
969+tneabove-referencedProject,andtheContractwork.
970+
971+
972+
973+RTE TEDTLabd 6ANameofConacingOct
974+cawwotaveePresentMavicWa ‘ObaidutlhRanjbar
975+Fs8.GCS.he. FSCDaeSed[168DstofCokin [6GbaeSigned
976+l/s[23|obeRanjbar 1103/2023
977+sonata seenofContetngone
978+
979+
980+
981+(Continationy
982+
983+ContractNumber ModificationNo. PageofPages
984+
985+DCAM-20-CS-RFP.0020
986+
987+ModificationNo.8 2of2
988+
989+
990+7.ContractRecap:
991+LetterContract
992+ModificationNo.1
993+ModictionNo.2
994+‘ModificationNo.3
995+DefinitiveContract
996+ModificationNo.4
997+ModificationNo.5
998+ModificationNo.6
999+ModificationNo,7
1000+ModificationNo.8
1001+GuaranteedMaximumPrice
1002+LetterContractExecutedonJune14,2021
1003+‘Administrative-TimeExtension
1004+‘Administrative-TimeExtension
1005+Administrative-TimeExtension
1006+DefinitiveContractExecutedonAugust11,2022
1007+IncorporatingADAImpactCostandTimeExtension
1008+IncorporatesAddedCostforunforseencondition
1009+‘Administrative-TimeExtension
1010+IncorporatesAddedCosforunforseencondtion,re-designand
1011+UnsuitablesoilsfortheSteadParkRecreationCenter
1012+CurrentContractValueincreased
1013+$0.00
1014+$0.00
1015+0.00
1016+
1017+a
1018+$700,000.00
1019+$329,370.00
1020+$0.00
1021+$698,313.00
1022+‘s1g0.000.09
1023+
1024+
1025+
1026+
1027+
1028+
1029+
1030+
1031+
1032+
1033+
1034+
1035+FCanvactNumber PageofPages
1036+MODIFICATIONOFCONTRACT scauabexeenacnsi ii
1037+FattNonber iEfeciveDateJzReauisionPurchaseRequestNo.[5Caption
1038+[ConstructionManagementAt-RiskServicesfo
1039+ModificationNo.10 ‘SeeBlock16¢ Rk266072 elonMenaconnentMekoon
1040+eaeBY [F-AaistoredByWaferthante6)
1041+DepartmentofGeneralServices DepartmentofGeneralServices
1042+ContractingandProcurementDivision CapitalConstructionDivision
1043+3924MinnesotaAveNE,SthFloor 3824MinnesotaAveNE,5thFloor
1044+Washington,OC20019 Washington,DC20019
1045+6:NameandAdressofContractor(No.Steel,ly,countyaleandZIPCode)|_aAAmendientofSobcatonNo
1046+GabeOlver [98Dated(SeeNem17)
1047+GCS,ine.
1048+3020YostPiace,NE HOAModificationofConvacVOrderNo,
1049+Washington,DC20018 x|DCAN-20-cs-RFP.0020
1050+matt:msigal@ges-sigalcom 108.Dated(Seetem13)
1051+loiver@gessigacom Jaugust11,2022
1052+TTLTHISITEMONLYAPPLIESTOANENDMENTSOFSOUGTTATIONS
1053+|Theabovenberedsocaonarenessetforthnem16.Thehouranddtspecieforrecatoffers|_JisextendedLilieonencea
1054+‘Oflersmustacknowledgereceiptofthisamendmentpriortothehouranddatespectinthesokctationorasamended,byoneofthe
1055+folowingmethods:(a)Bycompletinglems8and15,andreuming_11_copiesoftheamendment:(b)Byacknowedingreceiptofhis
1056+amendmentoneachcopyoftheoffersubmited;(c)Byseparatelatofaxwhichincludesareferencetothesalctationand
1057+‘amendmentnumber.FAILUREOFYOURACKNOWLEDGEMENTTOBERECEIVEDATTHEPLACEDESIGNATEDFORTHERECEIPTOFOFFERS
1058+PRIORTOTHEHOURANDDATESPECIFIEDMAYRESULTINREJECTIONOFYOUROFFER.ibyveofthisamendmentyoudesirtochange
1059+‘anofferaroadysubmitted,suchchangemaybemadebyateroffax,providedeachleteortelegrammakesreferencetothe
1060+soitatonandthisamendment,andsreceivedpriorotheopeninghouranddatespeciied
1061+Z-AccouriingandAppropriationData(fRequred)
1062+
1063+
1064+
1065+75:THISITEMAPPLIESONLYTOMODIFICATIONSOFCONTRACTSIORDERS,
1066+ITMODIFIESTHECONTRACTIORDERNO.ASDESCRIBEDINTEM14
1067+[AThschangeordoriissuedpursuantto:SpecityAuthory)
1068+Thechangessetforthinom14aremadinthecontracvordernoinitr10A..
1069+B.Theabovenumberedcontraclorderismoeoreflecttheadmintralivechanges(auchaschangesihpayingfee,apprepraton
1070+[ato,ot.)sotforthintom14
1071+
1072+
1073+
1074+I.ThissupplementalagreementenioredTiopursuantToaorOF
1075+
1076+X_[®OtterSpeckyypeofmoaticatonandautor)Tila27DCMSections4728andContractNo,DCAN-20-CS-RFP-O020
1077+
1078+
1079+JEmPORTANT:——Contractor[_Jienet,—[X]isroquredtosgntisdocumentandrum1copyothesuingfon.
1080+
1081+
1082+[=DasenpionofamenarmenUrnoaTicalion(OrganedbyUCFSecTonheadings,WadingSoVCTaUonIConIraclwIDjOeTmaterwhereTease]
1083+contractNo,DCAM-20-CS-RFP.0020forConstructionManageratRisk"CMAR")ServicesforSteadParkRecreationCentr(he“Projectis
1084+herebymodifiedasfolows
1085+1.ValueofAgreement:ValueofAgreementisherebyincreasedfrom$15,201,683.00to$15,801,253.00by$499,570.00.Theincreaseof
1086+{$499,570.00isforthemodernizationoftheexistingrecreationfaciltywithanadltonandtobringituptoADAstandards.Innoeventshallthe
1087+contractorbepaidmorethan$15;80',253.00unlesstheContractorsauhorizedtoexceedthislimitadvanceandinwringbyDGSContracting
1088+oticr.Contractor'sProposalconsistingofhefolowingitemsisherebyprovidedasExhibitA:
1089+
1090+1.CostSummary 4.FirstSourceEmploymentAgreementandPlan
1091+2.Drawings 5.CertificateofCleanHands
1092+3.SBESubcontractingPlan 6.BondRider
1093+2.Terms&Conditions.Allothertermsandconditionsremainunchanged,
1094+3.Release.It'smutuallyagreedthatinexchangeforthisChangeOrderandotherconsideration,theContractorherebyreleases,waives,settles
1095+JandholdstheDepartmentharmlessfromanyandallactualorpotentialclaimsordemandsfordelays,disruptions,additionalwork,additonalime,
1096+addtionalcost,contractextensions,compensationsorliabilityunderanytheory,whetherknownorunknown,thattheContractormayhavenowor
1097+inthefutureagainsttheDepartmentarisingfromoroutof,asconsequencesorresullof,relatingtoorinanymannerconnectedwiththis,
1098+|Modiicaton,theabove-referencedProject,andtheContractwork.
1099+
1100+
1101+
1102+SK.NameandTiteofSigner [6ANameofContractingOficor
1103+GabeOliver,VicePresident ObsiduilahRanjbar
1104+5B:GCs,ne TSG.DateSigned|768.DistrictofColumbia Fe.DateSigned
1105+0,Mh
1106+Aa 4 ee
1107+ (Continuation)
1108+Page of Pages
1109+4. Contract Recap:
1110+Letter Contract $950,000.00
1111+Modification No. 1 $0.00
1112+Modification No. 2 $0.00
1113+Modification No. 3 $0.00
1114+Definitive Contract $13,474,000.00
1115+Modification No. 4 $700,000.00
1116+Modification No. 5 $329,370.00
1117+Modification No. 6 $0.00
1118+Modification No. 7 $698,313.00
1119+Modification No. 8 $100,000.00
1120+Modification No. 9 $0.00
1121+Modification No. 10 $499,570.00
1122+Guaranteed Maximum Price: $15,801,253.00
1123+Contract Value Increased
1124+Current Contract Value Increased
1125+Administrative - Time Extension
1126+Incorporating ADA Impact Cost and Time Extension
1127+Incorporates Added Cost for unforeseen condition
1128+Administrative - Time Extension
1129+Administrative - Time Extension
1130+Definitive Contract Executed on August 11, 2022
1131+Administrative - Time Extension
1132+Administrative - Time Extension
1133+Incorporates Added Cost for unforeseen condition, re-design and
1134+unsuitable soils for the Stead Park Recreation Center
1135+2 of 2
1136+Contract Number Modification No.
1137+DCAM-20-CS-RFP-0020 Modification No. 10
1138+Letter Contract Executed on June 14, 2021 GOVERNMENT OF THE DISTRICT OF COLUMBIA
1139+DEPARTMENT OF GENERAL SERVICES
1140+
1141+
1142+
1143+
1144+
1145+
1146+EXHIBIT A – CONTRACTOR’S PROPOSAL
1147+
1148+(EXHIBIT WILL APPEAR ON THE FOLLOWING PAGES)
1149+
1150+GCS, INC. DBA GCS-SIGAL 202.944.6600
1151+1140 3
1152+rd
1153+ St NE, Suite 320 www.GCS-SIGAL.com
1154+Washington, DC 20002
1155+
1156+November 9,2023
1157+
1158+Sent via email to:
1159+Michael Etherton
1160+Senior Project Manager - Capital Construction Services
1161+Contractor with Department of General Services
1162+3924 Minnesota Avenue, NE - 5th Floor
1163+Washington, DC 20019
1164+
1165+
1166+RE: Stead Park Recreation Center
1167+ Field Turf Replacement
1168+
1169+Dear Mike:
1170+
1171+We hereby submit our bid proposal in the amount of Four Hundred Ninety-Nine
1172+Thousand Five Hundred Seventy Dollars ($499,570.00 ) to remove and
1173+replace the existing field turf field and running track .
1174+
1175+Our cost breakdown is as follows:
1176+Description Itemized Cost Total
1177+Field Turf Removal/Replacement $281,385
1178+New Turf – SYNAugustine X47 $141,712
1179+Envirofill Ballast 41,590
1180+Perimeter Board 2,700
1181+Adhesive 4,200
1182+Freight 9,273
1183+Labor – Remove Existing Turf Field 36,500
1184+Labor – Install New Turf 45,410
1185+Running Track $88,925
1186+Material – New Poured in Place Rubber Surface $59,335
1187+Labor – Removal of Existing Track 11,558
1188+Labor – Installation of New Track 19,032
1189+Project Requirements $15,600
1190+Temporary Toilets $2,400
1191+Temporary Fencing 4,200
1192+Tree Protection 5,000
1193+Dumpsters 4,000
1194+Root Pruning Allowance 11,172
1195+Direct Cost Subtotal $397,082
1196+General Conditions – Please see breakout below 72,972
1197+Insurance 5,200
1198+Performance and Payment Bonds 5,560
1199+Fee 18,756
1200+TOTAL $499,570
1201+
1202+GCS, INC. DBA GCS-SIGAL 202.944.6600
1203+1140 3
1204+rd
1205+ St NE, Suite 320 www.GCS-SIGAL.com
1206+Washington, DC 20002
1207+General Conditions Breakdown
1208+
1209+Project Executive $ 4,676
1210+Project Manager 10,604
1211+Assistant Project Manager 8,252
1212+Superintendent 41,200
1213+Project Accountant 3,200
1214+Field Office Supplies 420
1215+Postage/Messenger 500
1216+Safety Officer 2,120
1217+Project Safety Signage 2,000
1218+Total General Conditions $72,972
1219+
1220+Our proposal is based upon the following clarifications:
1221+1. All work will be performed during normal working hours, Monday through Friday.
1222+No overtime, premium time, or differential time is included unless otherwise noted.
1223+2. Building department filing or permits are by owner if required.
1224+3. We will need the field shut down for ten (10) weeks in order to complete the turf
1225+and track replacement.
1226+4. No CBE participation is included in this proposal.
1227+5. New first source excluded from this proposal.
1228+6. Wage scale is included per General Wage Decision Number DC20200002 dated
1229+September 18, 2020.
1230+7. No underdrain or modification to existing drainage system is included.
1231+8. Turf does not include pad.
1232+9. We assume that the existing subbase material is acceptable for reuse. We include
1233+new sand to level field only.
1234+10. Concrete curb along running track is existing to remain.
1235+11. We assume concrete/stone base at track is existing to remain.
1236+12. Striping of track is not included in this proposal.
1237+13. New track to be 1 to 1 ½” of base with ½” top layer of EPDM.
1238+14. Proposal is based on an in- kind replacement of the turf field and running track. No
1239+work related to concrete planters, site specialties, landscaping, fencing etc. is
1240+included in this proposal.
1241+15. The PIP Surface for the track requires 48 - 72 hours to cure. We will need a
1242+weather forecast with temperatures above 40 degrees for 3 days /nights in order to
1243+start this work.
1244+We appreciate the opportunity to work with you on this project. Please do not hesitate to
1245+contact me should you have any questions.
1246+
1247+Sincerely,
1248+
1249+Paul Vayo
1250+Project Executive
1251+202.359.4459
1252+pvayo@gcs-sigal.com
1253+CC: Dan Waldo (via email)
1254+ Ryan Walsh (via email)
1255+ Sean Frazier (via email)
1256+
1257+
1258+
1259+
1260+
1261+paivaavais40SONaR
1262+‘Visnumi00go13n81SIa‘NOLONTHSYM,
1263+mivddvals
1264+Srupi039
1265+
1266+
1267+
1268+
1269+
1270+
1271+
1272+
1273+
1274+
1275+
1276+
1277+
1278+
1279+Srupio39)
1280+
1281+
1282+
1283+
1284+
1285+
1286+
1287+
1288+
1289+
1290+
1291+ DSLBDY
1292+SBESUBCONTRACTINGPLAN
1293+INSTRUCTIONS:Allconstruction&non-constructioncontractsforgovernment-assistedprojects(agency
1294+contracts&privateprojectwithDistrictsubsidy)over$250,000,shallrequireatleast35%oftheamountofthe
1295+contract(totalamountofagencycontractortotalprivateprojectdevelopmentcosts)besubcontractedtoSmall
1296+BusinessEnterprises(SBE),ifinsufficientqualifiedSBEstoCertifiedBusinessEnterprises(CBE).TheSBE
1297+‘SubcontractingPlanmustlistallSBEandCBEsubcontractsateverytier.OncetheSBESubcontractingPlanis
1298+submittedforagencycontracts,options&extensions,itcanonlybeamendedwithDSLBD’sconsent.
1299+SUBMISSIONOFSBESUBCONTRACTINGPLAN:
1300+4Foragencysolicitations-submittoagencywithbid/proposal.
1301+4Foragencyoptions&extensions-submittoagencybeforeoptionorextensionexercised.
1302+Forprivateprojects-submittoDSLBD,agencyprojectmanagerandDistrictofColumbiaAuditor,witheach
1303+quarterlyreport.AsprivateprojectsmaynothaveawardedallcontractsatthetimetheDistrictsubsidyisgranted,the
1304+SBESubcontractingPlanmaybesubmittedsimultaneouslywitheachquarterlyreportandlistallSBE/CBE
1305+subcontractsexecutedbythetimeofsubmission.
1306+CREDIT:ForeachsubcontractlistedontheSBESubcontractingPlan,creditwillonlybegivenfortheportionofthe
1307+subcontractperformed,ateverytier,byaSBE/CBEusingitsownorganizationandresources.COPIESOFEACH
1308+FULLYEXECUTEDSUBCONIRACTWITHSBEsandCBEs(ATEVERYTIER)MUSTBEPROVIDEDTORECEIVE
1309+CREDIT.
1310+EXEMPTION:IftheBeneficiary(PrimeContractororDeveloper)isaCBEandwillperformtheENTIRE
1311+government-assistedprojectwithitsownorganizationandresourcesandwillNOTsubcontractanyportionofthe
1312+servicesandgoods,thentheCBEisnotrequiredtosubcontract35%toSBEs.
1313+
1314+BENEFICIARY(7whichappliesF]PrimeContractoror[|Developer)INFORMATION:
1315+
1316+‘GOS,_Tae—DBR
1317+‘Company:ccs--sGAL.Contact#(202)944-6600Emailaddress:GOLIVER®GCS-STGALCOM
1318+StreetAddress;11403rdStNE,Suite320,Washington,DC20002
1319+“allthatapplies,Companyis:
1320+(1aSBeGB}aCBE[JCBECertificationNumber:£24828836012025
1321+WILLperformtheENTIREagencycontractorprivateprojectwithitsownorganizationandresources
1322+_WILLsubcontractaportionoftheagencycontractorprivateproject
1323+‘Company'spointofcontactforagencycontractorprivateproject:
1324+
1325+PointofContact:GABEOLIVER Title:PartnerandS.V.P
1326+
1327+Contact#(202)944-6600 Emailaddress:COLIVER@GCS-STGAL.cOM
1328+‘StreetAddress:11493rdStNE,Suite320,Washington,Dc20002
1329+
1330+
1331+
1332+GOVERNMENT-ASSISTEDPROJECT(7whichapplies"|AgencyContractor[]PrivateProject)INFORMATION:
1333+
1334+
1335+
1336+"AGENCYSOLICITATION PRIVATEPROJECT
1337+SolicitationNumberDCAM-20-CS~REP-0020 DistrictSubsidy:
1338+SolicitationDueDatarsanuary20,2021 ‘AgencyProvidingSubsidy
1339+Agency:26: “AmountofDistrictSubsidy
1340+TotalDollarAmountofContract:$15,801,253 DateDistrictSubsidyProvided:
1341+
1342+“Design-Buildmustincludetotalcontractamountforbothdesignand|ProjectName:
1343+buildphaseofproject.
1344+ProjectAddress:
1345+35%ofTotalDollarAmountofContract:§5.530,439 “TotalDevalopmaandProjectBlgot'§
1346+(includepre-constructionandconstructioncosts)
1347+
1348+TotalAmountofAllSBE/CBEsubcontracts:$5,781,032
1349+(includeeverylowertier) 35%ofTotalDevelopmentProjectBudget:§
1350+TotalAmountofAlSBE/CBEsubcontracts:$_
1351+(includeeverylowertier)
1352+
1353+SBESubcontractingPlan—RevisedOctober2014 DSLBDY
1354+‘SBE/CBESUBCONTRACTORS(FOREACHTIER):
1355+
1356+‘SBE/CBESUBCONTRACTORINFORMATION:(Fordesign-buildprojects,theSBESubcontractingPlanIsnotrequiredtobe
1357+‘submittedforpreconstructionservices;however,afullSBESubcontractingPlan(35%ofthecontractamountincludingtotaldesign
1358+
1359+
1360+
1361+andbuildcosts)is‘0besubmittedbeforeenteringintoaguaranteedmaximumpriceorcontractauthorizingconstruction.)
1362+‘SBE/CBECompany‘Address/TelephoneNoJ|SubcontractorTier|DescriptionofSubcontractscopeofworktobePERFORMED
1363+Email (.2%,3%ete)|WITHSBE/CBEsOWNORGANIZATION&RESOURCES,
1364+SelectTier
1365+TronFabrication306FloridaaveWH,ist
1366+Services,Lic WashingtonDc,20001
1367+
1368+
1369+StructuralandMiscMetals
1370+
1371+Periodofsubcontract:June,2022~July,2023
1372+PricetobepaidtotheSBE/CBESubcontractor:$1,478,065
1373+allthatapplies,Subcontractoris:
1374+@asBe(acseCOCBECertification#:_1.363879092024
1375+[JSBE/CBEwillperformtheENTIREsubcontractwithitsown
1376+organizationandresource
1377+(_SBE/CBEwillsubcontractaportionofthé
1378+EACHLOWERTIERSBE/CBESUBCONTRACTS)
1379+
1380+ Jubcontract(MUSTLIST
1381+‘SBE/CBEPointofContact
1382+Name:ALiAzad
1383+Title:DixectorofEstimatingandProcurement
1384+TelephoneNumber:(410)712-7070
1385+EmailAddress:naliironfs.com
1386+
1387+
1388+‘SBECBESUBCONTRACTORINFORMATION:(Fordesign-buildprojects,theSBESubcontractingPlanisnotrequiredtobe
1389+‘submittedforpreconstructionservices;however,afullSBESubcontractingPlan(35%ofthecontractamountincludingtotaldesign
1390+andbuildcosts)isrequiredbetosubmittedbeforeenteringintoaguaranteedmaximumpriceorcontractauthorizingconstruction.)
1391+
1392+
1393+
1394+"SBE/CBECompany‘Address/TelephoneNoJ|SubcontractorTier|DescriptionofSubcontractscopeofworktobePERFORMED
1395+Email (08.2%,3%ote)WITHSBE/CBEsOWNORGANIZATION&RESOURCES
1396+SelectTier
1397+33Prime 1421KeniiworthAve
1398+Services,Lc NE,WashingtonDC,
1399+20019
1400+
1401+et
1402+
1403+Sitework,SiteUtilities
1404+
1405+Sane, 202:2022-duly,
1406+Periodofsubcontract:
1407+PricetobepaidtotheSBE/CBESubcontractor:$1,740,990
1408+allthatapplies,Subcontractoris:
1409+3
1410+
1411+Basse
1412+o
1413+a
1414+ace1]CBECertification#usp64283022025
1415+'SBE/CBEwillperformtheENTIREsubcontractwithitsown
1416+organizationandresource:
1417+'SBEICBEwillsubcontractaportionofthesubcontract(MUSTLIST
1418+EACHLOWERTIERSBE/CBESUBCONTRACTS)
1419+
1420+‘SBE/CBEPointofContact
1421+Name:JuanAguirre
1422+Tie:
1423+TelephoneNumber:(202)399-0060
1424+EmailAddress:contact@)jprimeservices.com
1425+
1426+1&
1427+DBAGCS-SIGAL
1428+(Nama)ida)(PiimeContractor!Developer)
1429+S/13/24
1430+(Signature)¢ (Date)
1431+Completeadditionalcopiesasneeded.
1432+‘Swearoraffirmtheaboveistrueandaccurate
1433+SBESubcontractingPlan—RevisedOctober2014 DSLBDY
1434+SBE/CBESUBCONTRACTORS(FOREACHTIER):
1435+
1436+‘SBE/CBESUBCONTRACTORINFORMATION:(Fordesign-buildprojects,theSBESubcontractingPlanisnotrequiredtobe
1437+fullSBESubcontractingPlan(35%ofthecontractamountincludingtotaldesign‘submittedforpreconstructionservices;however,
1438+
1439+
1440+
1441+andbuildcosts)is tobesubmittedbeforeintoa ‘maximumpriceorcontractauthorizingconstruction.)
1442+‘SBE/CBECompany‘Address/TelephoneNoJ|SubcontractorTier]DescriptionofSubcontractscopeofworktobePERFORMED
1443+Email 18,24,9,ote)WITHSBE/CBEsOWNORGANIZATION&RESOURCES
1444+SelectTier
1445+Dynamic 2806DouglasStNE,ist DrywallandCeilings
1446+Contracting,Inc.Washington,DC20018
1447+
1448+
1449+
1450+Periodofsubcontract:June,2022-July,2023
1451+PricetobepaidtotheSBE/CBESubcontractor:$1054,170,
1452+allthatapplies,Subcontractoris:
1453+@asee()acBe—(]CBECertification#:1:50233855062025
1454+[JSBE/CBEwillperformtheENTIREsubcontractwithitsown
1455+‘organizationandresources
1456+(C1SBE/CBEwillsubcontractaportionofthesubcontract(MUSTLIST
1457+EACHLOWERTIERSBE/CBESUBCONTRACTS)
1458+‘SBE/CBEPointofContact,
1459+Name:MariaCartagena
1460+
1461+Tite:
1462+‘TelephoneNumber.(202)408-5009
1463+EmailAddress:mariactdynanic-contracting.com
1464+
1465+
1466+‘SBE/CBESUBCONTRACTORINFORMATION:(Fordesign-buildprojects,theSBESubcontractingPlanisnotrequiredtobe
1467+fullSBESubcontractingPlan(35%ofthecontractamountincludingtotaldesign
1468+andbuildcosts)isrequiredbetosubmittedbeforeenteringintoaguaranteedmaximumpriceorcontractauthorizingconstruction.)
1469+‘submittedforpreconstructionservices;however,
1470+
1471+
1472+
1473+
1474+"SBE/CBECompany‘Address/TelephoneNoJ|SubcontractorTier|DescriptionofSubcontractscopeofworktobePERFORMED
1475+Email (9.2%,34,ote)WITHSBE/CBEsOWNORGANIZATION&RESOURCES
1476+SelectTier
1477+PrecisionWall 605RaleighPlSE,ist Painting
1478+Tech,Ine Washington,Dc20032
1479+
1480+
1481+
1482+
1483+Periodofsubcontract:June,2022-July,2023
1484+PricetobepaidtotheSBE/CBESubcontractor:$92,680
1485+allthatapplies,Subcontractoris
1486+ asse (acse []CBECertification#10264725122024
1487+TE)SBEICBEwillperformtheENTIREsubcontractwithfsown
1488+‘organizationandresources
1489+C_SBE/CBEwillsubcontractaportionofthesubcontract(MUSTLIST
1490+EACHLOWERTIERSBE!CBESUBCONTRACTS)
1491+
1492+
1493+‘SBE/CBEPointofContact,
1494+Name:CindyAthey
1495+
1496+Title:President
1497+TelephoneNumber:_(202)330-0955
1498+EmailAddress:cathey@precisionwall.com
1499+
1500+Paulvayo, DBAGCS-SIGAL
1501+(Name)(Titi)
1502+En
1503+Completeadditionalcopiesasneeded.
1504+ProjectBnec,05,Ine
1505+(PrimeContractor!Developer)
1506+_S/131204
1507+(Date)
1508+ ‘Swearoraffirmtheaboveistrueandaccurate
1509+SBESubcontractingPlan—RevisedOctober2014 DSLBDY
1510+SBE/CBESUBCONTRACTORS(FOREACHTIER):
1511+
1512+‘SBE/CBESUBCONTRACTORINFORMATION:(Fordesign-buildprojects,theSBESubcontractingPlanisnotrequiredtobe
1513+‘submittedforpreconstructionservices;however,afullSBESubcontractingPlan(35%ofthecontractamountincludingtotaldesign
1514+andbuildcosts)isrequiredtobesubmittedbeforeenteringintoaquaranteedmaximumpriceorcontractauthorizingconstruction.)
1515+
1516+
1517+
1518+
1519+‘SBE/CBECompany‘Address/TelephoneNoJ|SubcontractorTier|DesoriptionofSubcontractscopeofworktobePERFORMED
1520+Email (9,24.9%,ote)WITHSBE/CBEsOWNORGANIZATION&RESOURCES
1521+SelectTier
1522+PotomacFire 70012thstXW, Ist FireProtection/Sprinklers
1523+ProtectionCompany
1524+ine
1525+Washington,DC’20005
1526+
1527+
1528+
1529+Periodofsubcontract:June,2022~July,2023
1530+PricetobepaidtotheSBE/CBESubcontractor:$98,985
1531+“allthatapplies,Subcontractoris:
1532+@asBe(acBe ()CBECertification#:
1533+_SBE/CBEwillperformtheENTIREsubcontractwithitsown
1534+‘organizationandresources:
1535+(_SBEICBEwillsubcontractaportionofthesubcontract(MUSTLIST
1536+EACHLOWERTIERSBE/CBESUBCONTRACTS)
1537+
1538+‘SBE/CBEPointofContact
1539+Name:TonyButler
1540+Tie:
1541+
1542+TelephoneNumber;(202)543-2590
1543+butLer@potonacfireprotection.com
1544+EmailAddress:
1545+
1546+
1547+'SBE/CBESUBCONTRACTORINFORMATION:(Fordesign-buildprojects,theSBESubcontractingPlanIsnotrequiredtobe
1548+‘submittedforpreconstructionservices;however,afullSBESubcontractingPlan(35%ofthecontractamountincludingtotaldesign
1549+
1550+
1551+
1552+andbuildcosts)is‘betosubmittedbeforeenteringintoaguaranteedmaximumpriceorcontractauthorizingconstruction.)
1553+‘SBE/CBECompany‘AddressiTelephoneNo/|SubcontractorTier|DescriptionofSubcontractscopeofworktobePERFORMED
1554+Email (1.2%,3%ote)WITHSBE/CBEsOWNORGANIZATION&RESOURCES
1555+‘SelectTier
1556+DistrictElectrical|1100NewJerseyave|ist ElectricalWork
1557+Services,Inc.SE,Washington,Dc
1558+20003
1559+
1560+
1561+
1562+
1563+Periodofsubcontract:Zune,2022-July,2023
1564+
1565+PricetobepaidtotheSBE/CBESubcontractor:$8
1566+“allthatapplies,Subcontractoris:
1567+ assefi)acBe—()_cBECertification#1.211428102025
1568+C_SBE/CBEwillperformtheENTIREsubcontractwithitsown
1569+‘organizationandresources
1570+1SBE/CBEwillsubcontractaportionofthesubcontract(MUSTLIST
1571+EACHLOWERTIERSBE/CBESUBCONTRACTS)
1572+‘SBE/CBEPointofContact,
1573+Name:TerryBeauford
1574+Tile
1575+TelephoneNumber,(202)465-7020
1576+EmailAddress:tbeauford-des@wcamith.com
1577+
1578+PaulVayo,ProjectExec,GCS,Inc.DBAGCS-SIGAL
1579+ae
1580+(Name)(fitiey—(PrimeContractor!Developer)
1581+Quer si2y
1582+(Signature)¢ (Date)
1583+Completeadditionalcopiesasneeded.
1584+swearoraffirmtheaboveistrueandaccurate
1585+SBESubcontractingPlan—RevisedOctober2014 DSLBDY
1586+
1587+‘SBE/CBESUBCONTRACTORS (FOREACHTIER):
1588+
1589+‘SBE/CBESUBCONTRACTORINFORMATION:(Fordesign-buildprojects,theSBESubcontractingPlanisnotrequiredtobe
1590+submittedforpreconstructionservices;however,afullSBESubcontractingPlan(35%ofthecontractamountincludingtotaldesign
1591+andbuildcosts)isrequiredtobesubmittedbeforeenteringintoaguaranteedmaximumpriceorcontractauthorizingconstruction.)
1592+
1593+
1594+
1595+
1596+‘SBE/CBECompany‘Address/TelephoneNo/|SubcontractorTier|DescriptionofSubcontractscopeofworktobePERFORMED
1597+Email (5.24.99,ote)WITHSBE/CBEsOWNORGANIZATION&RESOURCES
1598+SelectTier
1599+‘GCAFloors,LLC3221MstWH, let FlooringandTiling
1600+Washington,DC20007
1601+
1602+
1603+Periodofsubcontract:June,2022-July,2023
1604+PricetobepaidtotheSBE/CBESubcontractor:$112,441
1605+allthatapplies,Subcontractoris:
1606+ asse(ace(1)CBECertification#:is783954022024
1607+[4SBE/CBEwillperformtheENTIREsubcontractwithitsown
1608+‘organizationandresource:
1609+_SBE/CBEwillsubcontractaportionofthesubcontract(MUSTLIST
1610+EACHLOWERTIERSBE/CBESUBCONTRACTS)
1611+‘SBE/CBEPointofContact
1612+Name:LacyWalston
1613+Tite:
1614+TelephoneNumber.(202)735-0766
1615+ EmailAddress:lualston@gcsfloors.com
1616+
1617+
1618+‘SBE/CBESUBCONTRACTORINFORMATION:(Fordesign-buildprojects,theSBESubcontractingPlanIsnotrequiredtobe
1619+‘submittedforpreconstructionservices;however,
1620+
1621+fullSBESubcontractingPlan(35%ofthecontractamountincludingtotaldesign
1622+andbuildcosts)isrequiredbetosubmittedbeforeenteringintoaguaranteedmaximumpriceorcontractauthorizingconstruction.)
1623+
1624+
1625+
1626+
1627+‘SBE/CBECompany‘Address/TelephoneNo/|SubcontractorTier|DescriptionofSubcontractscopeofworktobePERFORMED.
1628+Email (12%3"otc)_|WITHSBE/CBEsOWNORGANIZATION&RESOURCES,
1629+SelectTier
1630+GECSupplyCompany,|1105stateRoute2nd Mechanical/PlumbingEquipmentSupply
1631+Ine 77,Atwood,IN
1632+38220
1633+
1634+
1635+
1636+Periodofsubcontract:_tune,2022-July,2023
1637+PricetobepaidtotheSBE/CBESubcontractor:$3251000
1638+allthatapplies,Subcontractoris
1639+SBEL]acBEL]_CBECertification#z5v07447012023,
1640+SBE/CBEwillperformtheENTIREsubcontractwithtsown
1641+‘organizationandresources
1642+G]_SBEICBEwillsubcontractaportionofthesubcontract(MUSTLIST
1643+EACHLOWERTIERSBE/CBESUBCONTRACTS)
1644+
1645+‘SBE/CBEPointofContact
1646+Name:__GeneHale
1647+Tite
1648+TelephoneNumber:(202)248-5070
1649+EmailAddress:gene@gandecorp.com
1650+
1651+PaulVayo,ProjectExec,GCS,Inc.DBAGCS-SIGAL
1652+
1653+(Name)(Title)(PrimeContractor!Developer)
1654+_S1B/24
1655+(Signature)¢ (Date)
1656+Completeadditionalcopiesasneeded.
1657+‘Swearoraffirmtheaboveistrueandaccurate
1658+SBESubcontractingPlan—RevisedOctober2014
1659+ DSLBDY
1660+[AGENCYCONTRACTINGOFFICER'SUSEONLYOR[]AGENCYPROJECTMANAGER'SUSEONLY
1661+(¥whichapplies.Onlyoneoptionshouldbeselected.)
1662+
1663+"AGENCYCONTRACTAWARD
1664+‘Agency:
1665+PrimeContractor:__
1666+ContractNumber:
1667+DateSBESubcontractingPlanAccepted:
1668+Dateagencycontractsigned:
1669+
1670+AnticipatedStartDateofContract:
1671+‘AnticipatedEndDaleofContract:
1672+TotalDollarAmountofContract.
1673+
1674+“Design-Buildmustincludetotalcontractamountforbothdesignand
1675+buildphaseofproject.
1676+35%ofTotalContractAmount:§
1677+otalAmountofAllSBE/CBEsubcontracts:§
1678+{includeeveryter)
1679+(5fats)
1680+BasePeriodContract~Option/ExtensionPeriod:
1681+CiMutt-yearContract
1682+Firstyear(period)ofContract:
1683+Currentyear(period)ofContract.
1684+{U1Design-Buld-DateofGuaranteedConiract
1685+checkiprimecontractorisaCBEandwillperformtheENTIRE
1686+overnment-asistedproject(agencycontract)wititsown
1687+‘organizationandresourcesandNOTsubcontractanypationof
1688+servicesorgoods
1689+
1690+PRIVATEPROJECTSUBSIDYAWARD
1691+‘AgencyProvidingSubsidy:_
1692+DistrictSubsidy
1693+Developer:
1694+‘AmountofDistrictSubsidy:
1695+DateDistrictSubsidyProvided!contractsigned:
1696+AnticipatedStartDateofProject:
1697+AnticipatedEndDateofProject:
1698+ProjectName:
1699+ProjectAddress:
1700+TotalDevelopmentProjectBudget:$
1701+(includepre-constructionandconstructioncosts)
1702+
1703+
1704+35%ofTotalDevelopmentProjectBudget:$
1705+TotalAmountofAllSBE/CBEsubcontracts:$
1706+(includeeverylowertier)
1707+[checkifdeveloperisaCBEandwillperformtheENTIREgovernment-assisted
1708+Project(privateproject)withitsownorganizationandresourcesandNOT
1709+‘subcontractanyportionofservicesorgoods.
1710+
1711+
1712+
1713+[CIAGENCYCONTRACTINGOFFICER'SAFFIRMATIONOR[]AGENCYPROJECTMANAGER'SAFFIRMATION
1714+(7whichapplies)
1715+‘TheBelowAgencyContractingOfficerorAgencyProjectManagerAffirmsthefollowing(vtoaffirm):
1716+iftheBeneficiaryisaCBE,DSLBDwascontactedtoconfirmBeneficiary'sCBEcertification;
1717+1ThefullyexecutedContract(BaseorOptionorExtensionorMulti-Year)orsubsidydocument,betweentheBeneficiaryandAgency,was
1718+‘emailedtoDSLBD@Compliance.Enforcement@dc.govwithinfive(5)daysofsigning;
1719+CIFORAGENCYCONTRACTtheSBESubcontractingPlan,submittedbyBeneficiary,wasemailedtoDSLBD@
1720+‘Compliance.Enforcement@dc.govwithinfive(5)daysofsigningthecontractbetweentheBeneficiaryandAgency.
1721+NameofAgencyContractingOfficerorAgencyProjectManager
1722+
1723+TileofAgencyContractingOfficerorAgencyProjectManager
1724+
1725+
1726+SBESubcontractingPlan—RevisedOctober2014 ***
1727+GOVERNMENT OF THE DISTRICT OF COLUMBIA
1728+FIRST SOURCE EMPLOYMENT AGREEMENT (2) FOR
1729+CONSTRUCTION PROJECTS ONLY
1730+GOVERNMENT-ASSISTED PROJECT/CONTRACT INFORMATION
1731+CONTRACT/SOLICITATION NUMBER: DCAM-20-CS-RFP-0020
1732+***
1733+------- -
1734+--------- ---
1735+DIST Rl CT CONTRACTING AGENCY: Deoartment of General Services
1736+C
1737+ONTRACTING OFFICER:
1738+-:----------a-----;-:;;.;:----:------ -------- ----
1739+TELEPHONE NUMBER:
1740+TOT AL CONTRACT AMOUNT:
1741+.,._$�15_,,....8-0�1 .... , 2_5-3 ____________ ____ _
1742+THIS SECTION TO BE COMPLETED BY THE BENEFICIARY ONLY:
1743+TOT AL GOVERNMENT ASSISTED FUNDED AMOUNT:
1744+$
1745+15,
1746+801,
1747+253 DATE ____ _
1748+E] CONTRACT □ GRANT O LOAN OT AX ABATEMENT OR EXEMPTION □ LAND TRANSFER
1749+0 LAND DISPOSITION AND DEVELOPMENT AGREEMENT □ TAX INCREMENT FINANCING
1750+OANY ADDITIONAL LEGISLATION, IF YES _________________ _
1751+D.C. CODE#
1752+GENERAL CONTRACTOR WILL MEET THE HIRING OR HOURS WORKED PERCENT AGES
1753+REQUIREMENTS FOR ENTIRE PROJECT □ OR PER EACH SUBCONTRACTOR0
1754+PROJECT NAME: SteadParkRecreatlonCente,
1755+--------------- --------------
1756+PROJECT ADDRESS: 1625PStreetNW ---------------------- -----
1757+CITY: Washington
1758+ST ATE: D.C.
1759+ZIP CODE: 20036 --------- -- ---- --- --------
1760+PROJECT START DATE: August9•2022 PROJECT END DATE: October4,2o2• ---------
1761+EMPLOYER START DATE: AuguSl9,2022 EMPLOYER END DATE: October4,2o24 --- ----
1762+EMPLOYER INFORMATION
1763+EMPLOYER NAME: _G_cs_, 1n_cd_ba_G_cs_-s_1GA_L ________ ____ _____ ___ __ _
1764+EMPLOYERADDRESS:_1,_4
1765+0
1766+_
1767+3
1768+,_ds_
1769+tN_E_s1
1770+e
1771+_32_0 ________ _______ ______ _
1772+CITY: Washington ST ATE: D.C.
1773+ZIP CODE: _20_
1774+00_2
1775+------
1776+TELEPHONE NUMBER:_1
1777+2_
1778+02
1779+_l99_4-_66_
1780+00
1781+____ _ FEDERAL IDENTIFICATION N0.:_52
1782+_
1783+-14_
1784+88
1785+_
1786+92_
1787+1 ___ _
1788+CONTACT PERSON: GabeOiiver
1789+----------- ------ ---------
1790+TITLE: Partner and Senior Vice President
1791+E-MAIL: goliver@gcs-sigal.com TELEPHONE NUMBER: (202) 437-6771
1792+CERTIFIED BUSINESS ENTERPRISES CERTIFICATION NUMBER:_Lz_xR_
1793+2
1794+e_a3_60_12_02_s _____ _ _
1795+D.C. APPRENTICESHIP COUNCIL REGISTRATION NUMBER: _NI_A
1796+---- -----
1797+­
1798+ARE YOU A SUBCONTRACTOR □YES 0 NO IF YES, NAME OF PRIME CONTRACTOR:
1799+This First Source Employment Agreement (Agreement), in accordance with Workforce Intem1ediary
1800+Establishment and Reform of the First Source Amendment Act of 2011 (D.C. Official Code §§ 2-219.01
1801+-2.219.05), and relevant provisions of the Apprenticeship Requirements Amendment Act of2004 (D_C.
1802+Official Code § 2-219.03 and § 32-1431) is a required agreement between the District of Columbia
1803+Department of Employment Services (DOES) and EMPLOYER.
1804+EMPLOYER, which includes the Beneficiary and all contractors and subcontractors, is working on a
1805+contract or project that has received:
1806+D D.C. Government assistance valued between $300,000 and $5 million dollars, required to make a
1807+good faith effort to ensure that 51 % of all new hires are District residents. (D.C. Official Code § 2-
1808+219(e)(1 )(A))
1809+0 D.C. Government assistance valued at $5 million or more, required to have the following percentage
1810+of hours worked in each classification by DC residents; 20% of journey worker hours; 60% of apprentice
1811+hours; 51 % of skilled laborer hours; 70% of common laborer hours for all jobs created by the Project.
1812+(D.C. Official Code §2-219.03 (lA)(A))
1813+Page l of 11
1814+First Source Employment Agreement, Revised Feb111a1y 15, 2 018 Obaidullah Ranjbar 202-359 3362 Page 2 of 11
1815+First Source Employment Agreement, Revised February 15, 2 018
1816+
1817+
1818+
1819+
1820+DOES is the first source for recruitment, referral, and placement of new hires or employees for all jobs
1821+created by the Government Assisted Project or Contract (Project).
1822+
1823+EMPLOYER began work on the Project, prior to receipt of an accepted First Source Employment
1824+Agreement (Agreement) from DOES, in violation of D.C. Code §2-219.03. In order to continue to work
1825+on the Project, Employer shall adhere to the Agreement requirements retroactive to the date that work
1826+began and continuing until Project completion.
1827+
1828+The Parties agree to the terms and conditions of the Agreement as follows:
1829+
1830+I. DEFINITIONS
1831+
1832+The following definitions shall govern the terms used in this Agreement.
1833+A. Apprentice means a worker who is employed to learn an apprenticeable occupation under the
1834+terms and conditions of approved apprenticeship standards.
1835+B. Beneficiary means:
1836+1. The signatory to a contract executed by the Mayor which involves any District of
1837+Columbia government funds, or funds which, in accordance with a federal grant or
1838+otherwise, the District government administers and which details the number and
1839+description of all jobs created by a government-assisted Project for which the
1840+beneficiary is required to use the First Source Register;
1841+
1842+2. A recipient of a District government economic development action including
1843+contracts, grants, loans, tax abatements, land transfers for redevelopment, or tax
1844+increment financing that results in a financial benefit of $300,000 or more from an
1845+agency, commission, instrumentality, or other entity of the District government,
1846+including a financial or banking institution which serves as the repository for $1
1847+million or more of District of Columbia funds.
1848+
1849+C. Contracting Agency means any District of Columbia agency that awarded a government
1850+assisted Project totaling $300,000 or more.
1851+
1852+D. Direct labor costs means all costs, including wages and benefits, associated with the hiring
1853+and employment of personnel assigned to a process in which payroll expenses are traced to
1854+the units of output and are included in the cost of goods sold.
1855+
1856+E. EMPLOYER means any entity awarded a government assisted Project totaling $300,000 or
1857+more, including all individual contractor and subcontractor entities at any tier who work
1858+on the Project.
1859+
1860+F. First Source Employer Portal is a website consisting of a connected group of static and
1861+dynamic web pages with the ability for Employers to enter data using the internet. The
1862+website is accessible by a Uniform Resource Locator (URL) and is maintained by DOES.
1863+The website provides reporting information to First Source EMPLOYERS.
1864+
1865+G. First Source Register means the DOES Automated Applicant Files, which consists of the
1866+names of DC residents registered with DOES.
1867+
1868+H. Good faith effort means an EMPLOYER has exhausted all reasonable means to comply with
1869+any affirmative action, hiring, or contractual goal(s) pursuant to the First Source law and
1870+Agreement.
1871+
1872+ Page 3 of 11
1873+First Source Employment Agreement, Revised February 15, 2 018
1874+
1875+
1876+
1877+
1878+I. Government-assisted project or contract (Project) means any construction or non-
1879+construction Project that receives funds or resources, valued at $300,000 or more, from the
1880+District of Columbia, or funds or resources which, in accordance with a federal grant or
1881+otherwise, the District of Columbia government administers, including contracts, grants,
1882+loans, tax abatements or exemptions, land transfers, land disposition and development
1883+agreements, tax increment financing, or any combination of the aforementioned.
1884+
1885+J. Hard to employ means a District of Columbia resident who is confirmed by DOES as:
1886+1. An ex-offender who has been released from prison within the last 10 years;
1887+2. A participant of the Temporary Assistance for Needy Families program;
1888+3. A participant of the Supplemental Nutrition Assistance Program;
1889+4. Living with a permanent disability verified by the Social Security Administration or
1890+District vocational rehabilitation program;
1891+5. Unemployed for 6 months or more in the last 12-month period;
1892+6. Homeless;
1893+7. A participant or graduate of the Transitional Employment Program established by §
1894+32-1331; or
1895+8. An individual who qualified for inclusion in the Work Opportunity Tax Credit
1896+Program as certified by the Department of Employment Services.
1897+
1898+K. Indirect labor costs means all costs, including wages and benefits, that are part of operating
1899+expenses and are associated with the hiring and employment of personnel assigned to tasks
1900+other than producing products.
1901+
1902+L. Jobs means any union and non-union managerial, non-managerial, professional,
1903+nonprofessional, technical or nontechnical position including: clerical and sales occupations,
1904+service occupations, processing occupations, machine trade occupations, bench work
1905+occupations, structural work occupations, agricultural, fishery, forestry, and related
1906+occupations, and any other occupations as the Department of Employment Services may
1907+identify in the Dictionary of Occupational Titles, United States Department of Labor.
1908+
1909+M. New Hire: Individual(s) newly hired by the EMPLOYER to perform work on a government
1910+assisted Project.
1911+
1912+N. Transfer: Existing EMPLOYER employee who has been moved from one Project to another
1913+Project.
1914+
1915+O. Journeyman means a worker who has attained a level of skill, abilities and competencies
1916+recognized within an industry as having mastered the skills and competencies required for the
1917+occupation.
1918+
1919+P. Revised Employment Plan means a document prepared and submitted by the EMPLOYER
1920+that includes the following:
1921+
1922+1. A projection of the total number of hours to be worked on the Project by trade;
1923+
1924+2. A projection of the total number of journey worker hours, by trade, to be worked on
1925+the Project and the total number of journey worker hours, by trade, to be worked by
1926+DC residents;
1927+
1928+3. A projection of the total number of apprentice hours, by trade, to be worked on the
1929+Project and the total number of apprentice hours, by trade, to be worked by DC
1930+residents; Page 4 of 11
1931+First Source Employment Agreement, Revised February 15, 2 018
1932+
1933+
1934+
1935+
1936+4. A projection of the total number of skilled laborer hours, by trade, to be worked on
1937+the Project and the total number of skilled laborer hours, by trade, to be worked by
1938+DC residents;
1939+
1940+5. A projection of the total number of common laborer hours to be worked on the
1941+Project and the total number of common laborer hours to be worked by DC residents;
1942+
1943+6. A timetable outlining the total hours worked by trade over the life of the Project and
1944+an associated hiring schedule;
1945+
1946+7. Descriptions of the skill requirements by job title or position, including industry-
1947+recognized certifications required for the different positions;
1948+
1949+8. A strategy to fill the hours required to be worked by DC residents pursuant to this
1950+paragraph, including a component on communicating these requirements to
1951+contractors and subcontractors and a component on potential community outreach
1952+partnerships with the University of the District of Columbia, the University of the
1953+District of Columbia Community College, the Department of Employment Services,
1954+Jointly Funded Apprenticeship Programs, the District of Columbia Workforce
1955+Intermediary, or other government-approved, community-based job training
1956+providers;
1957+
1958+9. A remediation strategy to ameliorate any problems associated with meeting these
1959+hiring requirements, including any problems encountered with contractors and
1960+subcontractors;
1961+
1962+10. The designation of a senior official from the EMPLOYER(S) or general contractor
1963+who will be responsible for implementing the hiring and reporting requirements;
1964+
1965+11. Descriptions of the health and retirement benefits that will be provided to DC
1966+residents working on the Project;
1967+
1968+12. A strategy to ensure that District residents who work on the Project receive ongoing
1969+employment and training opportunities after they complete work on the job for which
1970+they were initially hired and a review of past practices in continuing to employ DC
1971+residents from one Project to the next;
1972+
1973+13. A strategy to hire graduates of District of Columbia Public Schools, District of
1974+Columbia public charter schools, and community-based job training providers, and
1975+hard-to-employ residents; and
1976+
1977+14. A disclosure of past compliance with the Workforce Act and the Davis-Bacon Act,
1978+where applicable, and the bidder or offeror's general DC resident hiring practices on
1979+projects or contracts completed within the last 2 years.
1980+
1981+Q. Tier Subcontractor means any subcontractor selected by the primary contractor to perform
1982+portion(s) or all work related to the trade or occupation area(s) on a Project subject to this
1983+First Source Agreement.
1984+
1985+R. Washington Metropolitan Statistical Area means the District of Columbia; Virginia Cities
1986+of Alexandria, Fairfax, Falls Church, Fredericksburg, Manassas, and Manassas Park; the
1987+Virginia Counties of Arlington, Clarke, Fairfax, Fauquier, Loudon, Prince William,
1988+Spotsylvania, Stafford, and Warren; the Maryland Counties of Calvert, Charles, Frederick, Page 5 of 11
1989+First Source Employment Agreement, Revised February 15, 2 018
1990+
1991+
1992+
1993+Montgomery and Prince Georges; and the West Virginia County of Jefferson.
1994+
1995+S. Workforce Intermediary Pilot Program means the intermediary between employers and
1996+training providers to provide employers with qualified DC resident job applicants. See DC
1997+Official Code § 2-219.04b.
1998+
1999+II. GENERAL TERMS
2000+
2001+A. Subject to the terms and conditions set forth herein, DOES will receive the Agreement from
2002+the Contracting Agency no less than 7 calendar days in advance of the Project start date. No
2003+work associated with the relevant Project can begin until the Agreement has been accepted by
2004+DOES.
2005+
2006+B. The Beneficiary and/or EMPLOYER shall require all Project contractors and subcontractors,
2007+under a Project receiving government assistance or benefits valued at $300,000 or more, to
2008+enter into an Agreement with DOES.
2009+
2010+C. Agreement will take affect once beneficiary/Employer awarded contract and start work on
2011+the government assisted Project and no work can begin prior to execution of the Agreement
2012+and will be fully effective through the duration, any extension or modifications of the Project
2013+and until such time as construction is complete and a certificate of occupancy is issued.
2014+
2015+D. If an EMPLOYER began work prior to the execution of a First Source Employment
2016+Agreement, the EMPLOYER shall cease work on the Project and sign a First Source
2017+Employment Agreement to be bound by the applicable First Source Employment Agreement
2018+requirements, retroactively, from the start of work throughout the duration of the contract.
2019+
2020+E. DOES will provide recruitment, referral, and placement services to the EMPLOYER, subject
2021+to the limitations in this Agreement.
2022+
2023+F. DOES and the EMPLOYER agree that, for purposes of this Agreement, new hires and jobs
2024+created for the Project (both union and nonunion) include all of EMPLOYER'S job openings
2025+and vacancies in the Washington Metropolitan Statistical Area created for the Project as a
2026+result of internal promotions, terminations, and expansions of the EMPLOYER'S workforce,
2027+as a result of this Project.
2028+
2029+G. This Agreement includes apprentices as defined in D.C. Official Code §§ 32-1401- 1431.
2030+
2031+DOES will make every effort to work within the terms of all collective bargaining
2032+agreements to which the EMPLOYER is a party. The EMPLOYER will provide DOES with
2033+written documentation that the EMPLOYER has provided the representative of any collective
2034+bargaining unit involved with this Project a copy of this Agreement and has requested
2035+comments or objections. If the representative has any comments or objections, the
2036+EMPLOYER will promptly provide them to DOES.
2037+
2038+The EMPLOYER who contracts with the District of Columbia government to perform
2039+construction, renovation work, or information technology work with a single contract, or
2040+cumulative contracts, of at least $500,000, within a 12-month period will be required to
2041+register an apprenticeship program with the District of Columbia Apprenticeship Council as
2042+required by DC Code 32-1431.
2043+
2044+H. If, during the term of this Agreement, the EMPLOYER should transfer possession of all or a
2045+portion of its business concerns affected by this Agreement to any other party by lease, sale,
2046+assignment, merger, or otherwise this First Source Agreement shall remain in full force and
2047+effect and transferee shall remain subject to all provisions herein. In addition, the Page 6 of 11
2048+First Source Employment Agreement, Revised February 15, 2 018
2049+
2050+
2051+
2052+EMPLOYER as a condition of transfer shall:
2053+
2054+1. Notify the party taking possession of the existence of this EMPLOYER'S First
2055+Source Employment Agreement.
2056+2. Notify DOES within 7 business days of the transfer. This notice will include the
2057+name of the party taking possession and the name and telephone of that party's
2058+representative.
2059+
2060+I. The EMPLOYER and DOES may mutually agree to modify this Agreement. Any
2061+modification shall be in writing, signed by the EMPLOYER and DOES and attached to the
2062+original Agreement.
2063+
2064+J. To the extent that this Agreement is in conflict with any federal labor laws or governmental
2065+regulations, the federal laws or regulations shall prevail.
2066+
2067+III. TRAINING
2068+
2069+A. DOES and the EMPLOYER may agree to develop skills training and on-the-job training
2070+programs as approved by DOES; the training specifications and cost for such training will be
2071+mutually agreed upon by the EMPLOYER and DOES and will be set forth in a separate
2072+Training Agreement.
2073+
2074+IV. RECRUITMENT
2075+
2076+A. The EMPLOYER shall complete the attached Revised Employment Plan that will include the
2077+information outlined in Section I.P.
2078+
2079+B. The EMPLOYER shall register and post all job vacancies with the Job Bank Services of
2080+DOES at www.dcnetworks.org for a minimum of 10 days. Should you need assistance
2081+posting job vacancies, please contact Job Bank Services at (202) 698-6001.
2082+
2083+C. The EMPLOYER shall notify DOES of all new jobs created for the Project within at least 7
2084+business days (Monday - Friday) of the EMPLOYERS’ identification/creation of the new
2085+jobs. The Notice of New Job Creation shall include the number of employees needed by job
2086+title, qualifications and specific skills required to perform the job, hiring date, rate of pay,
2087+hours of work, duration of employment, and a description of the work to be performed. This
2088+must be done before using any other referral source.
2089+
2090+D. Job openings to be filled by internal promotion from the EMPLOYER'S current workforce
2091+shall be reported to DOES for placement and referral, if the job is newly created.
2092+EMPLOYER shall provide DOES a Notice of New Job Creation that details such promotions
2093+in accordance with Section IV.C.
2094+
2095+E. The EMPLOYER will submit to DOES, prior to commencing work on the Project, a list of
2096+Current Employees that includes the name, social security number, and residency status of all
2097+current employees, including apprentices, trainees, and laid-off workers who will be employed
2098+on the Project. All EMPLOYER information reviewed or gathered, including social security
2099+numbers, as a result of DOES’ monitoring and enforcement activities will be held confidential
2100+in accordance with all District and federal confidentiality and privacy laws and used only for
2101+the purposes that it was reviewed or gathered.
2102+
2103+
2104+
2105+ Page 7 of 11
2106+First Source Employment Agreement, Revised February 15, 2 018
2107+
2108+
2109+
2110+
2111+V. REFERRAL
2112+
2113+A. DOES will screen applicants through carefully planned recruitment and training events and
2114+provide the EMPLOYER with a list of qualified applicants according to the number of
2115+employees needed by job title, qualifications and specific skills required to perform the job,
2116+hiring date, rate of pay, hours of work, duration of employment, and a description of the work
2117+to be performed as supplied by the EMPLOYER in its Notice of New Job Creation set forth
2118+above in Section IV.C.
2119+
2120+B. DOES will notify the EMPLOYER of the number of applicants DOES will refer, prior to the
2121+anticipated hiring dates.
2122+
2123+VI. PLACEMENT
2124+
2125+A. EMPLOYER shall in good faith, use reasonable efforts to select its new hires or employees
2126+from among the qualified applicants referred by DOES. All hiring decisions are made by the
2127+EMPLOYER.
2128+
2129+B. In the event that DOES is unable to refer qualified applicants meeting the EMPLOYER’S
2130+established qualifications, within 7 business days (Monday - Friday) from the date of
2131+notification from the EMPLOYER, the EMPLOYER will be free to directly fill remaining
2132+positions for which no qualified applicants have been referred. However, the EMPLOYER shall
2133+still be required to meet the First Source hiring requirements or hours worked percentages for
2134+all jobs created by the Project.
2135+
2136+C. After the EMPLOYER has selected its employees, DOES is not responsible for the employees'
2137+actions and the EMPLOYER hereby releases DOES, and the Government of the District of
2138+Columbia, the District of Columbia Municipal Corporation, and the officers and employees of
2139+the District of Columbia from any liability for employees' actions.
2140+
2141+VII. REPORTING REQUIREMENTS
2142+
2143+A. EMPLOYER with a single contract valued at $300,000 or more on a Project that received
2144+government assistance totaling between $300,000 and $5,000,000, a provision that at least 51% of
2145+the new employees hired to work on the Project shall be District residents.
2146+
2147+B. EMPLOYER shall register in the First Source Online Registration and Reporting System for
2148+electronic submission of all monthly Contract Compliance data, weekly certified payrolls and
2149+any other documents required by DOES for reporting and monitoring.
2150+
2151+C. EMPLOYER shall submit to the Department of Employment Services each month following the
2152+start of the Project a hiring compliance report for the Project that includes the:
2153+1. Number of new job openings created/available;
2154+2. Number of new job openings listed with DOES, or any other District Agency;
2155+3. Number of DC residents hired for new jobs;
2156+4. Number of employees transferred to the Project;
2157+5. Number of DC residents transferred to the Project;
2158+6. Direct or indirect labor cost associated with the project;
2159+7. Each employee’s name, job title, social security number, hire date, residence,
2160+and referral source; and
2161+8. Workforce statistics throughout the entire project tenure.
2162+
2163+ Page 8 of 11
2164+First Source Employment Agreement, Revised February 15, 2 018
2165+
2166+
2167+
2168+D. EMPLOYER with a single contract valued at $300,000 or more on a Project that received
2169+government assistance totaling $5 million or more shall meet the following hours worked
2170+percentages for all jobs created by the Project:
2171+1. At least 20% of journey worker hours by trade shall be performed by DC residents;
2172+2. At least 60% of apprentice hours by trade shall be performed by DC residents;
2173+3. At least 51% of the skilled laborer hours by trade shall be performed by DC
2174+residents; and
2175+4. At least 70% of common laborer hours shall be performed by DC residents.
2176+
2177+E. EMPLOYERS shall provide the following cumulative statistics, that will be used to create
2178+the monthly report, by uploading certified payrolls or payroll data into the LCPtracker
2179+reporting system:
2180+
2181+1. Total Number of journey worker hours worked by DC residents by trade;
2182+2. Number of hours worked by all journey workers by trade;
2183+3. Number of apprentice hours worked by DC residents by trade;
2184+4. Number of hours worked by all apprentices by trade;
2185+5. Number of skilled laborer worker hours worked by DC residents by trade;
2186+6. Number of hours worked by all skilled laborers by trade;
2187+7. Number of common laborer hours worked by DC residents by trade; and
2188+8. Number of hours worked by all common laborers by trade.
2189+
2190+F. EMPLOYER may “double count” hours for the “hard to employ” up to 15% of total hours
2191+worked by DC Residents; however, a collective bargaining agreement shall not be a basis for
2192+waiver of this requirement.
2193+
2194+G. For construction Projects that are not subject to Davis-Bacon law in which certified payroll
2195+records do not exist, EMPLOYER shall submit monthly documents of workers employed on
2196+the Project to DOES, including DC residents and all employment classifications of hours
2197+worked.
2198+
2199+H. EMPLOYER may also be required to provide verification of hours worked or hiring
2200+percentages of DC residents, such as internal payroll records for construction Projects that are
2201+not subject to Davis-Bacon.
2202+
2203+I. Monthly, EMPLOYER shall submit weekly certified payrolls from all subcontractors at any tier
2204+working on the Project to the Contracting Agency. EMPLOYER is also required to make
2205+payroll records available to DOES as a part of compliance monitoring, upon request at job sites.
2206+
2207+VIII. FINAL REPORT AND GOOD FAITH EFFORTS
2208+
2209+A. With the submission of the final request for payment from the Contracting Agency,
2210+the Beneficiary and/or EMPLOYER shall:
2211+
2212+1. Report to DOES its compliance with the hiring or hours worked percentage
2213+requirements for all jobs created by the Project, and report the hours that DC
2214+residents worked for each trade classifications in each area of the Project; or
2215+
2216+2. Submit to DOES a request for a waiver of the hiring or hours worked percentage
2217+requirements for all jobs created by the Project that will include the following
2218+documentation:
2219+a. Documentation supporting EMPLOYER’S good faith effort to comply;
2220+b. Referrals provided by DOES and other referral sources; and
2221+c. Advertisement of job openings listed with DOES and other referral sources. Page 9 of 11
2222+First Source Employment Agreement, Revised February 15, 2 018
2223+
2224+
2225+
2226+
2227+B. DOES may waive or partially waive the hiring or hours worked percentage requirements for
2228+jobs created by the Project, and/or the required hours of DC residents for each trade
2229+classifications, if DOES finds that the Beneficiary or EMPLOYER, including its contractors
2230+or subcontractors:
2231+
2232+1. DOES certified that Beneficiary or Employer demonstrated a good faith effort to
2233+comply, as set forth in Section VIII.C.; or
2234+
2235+2. Is located outside the Washington Metropolitan Statistical Area, and none of the
2236+contract work is performed inside the Washington Metropolitan Statistical Area;
2237+
2238+3. The beneficiary published each job opening or part-time work needed for 7 calendar
2239+days in a District newspaper of city-wide circulation; and
2240+
2241+4. The DOES certified that there are insufficient eligible applicants from the First Source
2242+Register that possess the skills required by the positions, or the eligible applicants are not
2243+available for part-time work or do not have a means to travel to the onsite jobs; or
2244+
2245+5. Beneficiary/Employer entered into a special workforce development training or
2246+placement arrangement with DOES or with the District of Columbia Workforce
2247+Intermediary.
2248+
2249+C. DOES shall consider documentation of the following when making a determination of a
2250+good-faith effort to comply:
2251+
2252+1. DOES has certified that there are insufficient numbers of District residents in the
2253+labor market possessing the skills required by the EMPLOYER for the positions
2254+created as a result of the Project.
2255+
2256+2. Whether the EMPLOYER posted the jobs on the DOES job website for a minimum
2257+of 10 calendar days;
2258+
2259+3. Whether the EMPLOYER advertised each job opening in a District newspaper with
2260+city-wide circulation for a minimum of 7 calendar days;
2261+
2262+4. Whether the EMPLOYER advertised each job opening in special interest publications
2263+and on special interest media for a minimum of 7 calendar days;
2264+
2265+5. Whether the EMPLOYER hosted informational/recruiting or hiring fairs;
2266+
2267+6. Whether the EMPLOYER contacted churches, unions, and/or additional Workforce
2268+Development Organizations;
2269+
2270+7. Whether the EMPLOYER interviewed employable candidates;
2271+
2272+8. Whether the EMPLOYER created or participated in a workforce development
2273+program approved by DOES;
2274+
2275+9. Whether the EMPLOYER created or participated in a workforce development
2276+program approved by the District of Columbia Workforce Intermediary;
2277+
2278+10. Whether the EMPLOYER substantially complied with the relevant monthly reporting
2279+requirements set forth in this section; Page 10 of 11
2280+First Source Employment Agreement, Revised February 15, 2 018
2281+
2282+
2283+
2284+
2285+11. Whether the EMPLOYER has submitted and substantially complied with its most
2286+recent employment plan that has been approved by DOES; and
2287+
2288+12. Any additional documented efforts.
2289+
2290+IX. MONITORING
2291+A. DOES is the District agency authorized to monitor and enforce the requirements of the
2292+Workforce Intermediary Establishment and Reform of the First Source Amendment Act
2293+of 2011 (D.C. Official Code §§ 2 219.01 – 2.219.05), and relevant provisions of the
2294+Apprenticeship Requirements Amendment Act of 2004 (D.C. Official Code § 2-219.03
2295+and § 32-1431). As a part of monitoring and enforcement, DOES may require and
2296+EMPLOYER shall grant access to Project sites, employees, and documents.
2297+
2298+B. EMPLOYER’S noncompliance with the provisions of this Agreement may result in the
2299+imposition of penalties.
2300+
2301+C. All EMPLOYER information reviewed or gathered, including social security numbers, as a
2302+result of DOES’ monitoring and enforcement activities will be held confidential in
2303+accordance with all District and federal confidentiality and privacy laws and used only for the
2304+purposes that it was reviewed or gathered.
2305+
2306+D. DOES shall monitor all Projects as authorized by law. DOES will:
2307+
2308+1. Review all contract controls to determine if the Beneficiary or EMPLOYER,
2309+including any Contractors or Subcontractors, are subject to the Workforce
2310+Intermediary Establishment and Reform of the First Source Amendment Act of 2011.
2311+
2312+2. Notify stakeholders and company officials and establish meetings to provide
2313+technical assistance involving the First Source Process.
2314+
2315+3. Make regular construction site visits to determine if the Prime or Subcontractors’
2316+workforce is in concurrence with the submitted Agreement and Monthly Compliance
2317+Reports.
2318+
2319+4. Inspect and copy certified payroll, personnel records and any other records or
2320+information necessary to ensure the required workforce utilization is in compliance
2321+with the First Source Law.
2322+
2323+5. Conduct desk reviews of Monthly Compliance Reports.
2324+
2325+6. Educate EMPLOYERS about additional services offered by DOES, such as On-the-
2326+Job training programs and tax incentives for EMPLOYERS who hire from certain
2327+categories.
2328+
2329+7. Monitor and complete statistical reports that identify the overall project, contractor,
2330+and subcontractors’ hiring or hours worked percentages.
2331+
2332+8. Provide formal notification of non-compliance with the required hiring or hours
2333+worked percentages, or any alleged breach of the First Source Law to all contracting
2334+agencies, and stakeholders. (Please note: EMPLOYERS are granted 30 days to
2335+correct any alleged deficiencies stated in the notification.)
2336+
2337+ x.PENALTIES
2338+A.WillfulBreachoftheAgreementbytheEMPLOYER,failuretosubmitthecontract
2339+compliancereports,deliberatesubmissionoffalsifieddatamayresultinDOESimposinga
2340+fineof5%ofthetotalamountofthedirectandindirectlaborcostsoftheProject,inaddition
2341+tootherpenaltiesprovidedbylaw.Failuretomeettherequiredhiringrequirementsorfailure
2342+toreceivegoodfaithwaivermayresultintheDepartmentofEmploymentServices
2343+imposingapenaltyequalto1/8of1%ofthetotalamountofthedirectandindirectlabor
2344+costsoftheProjectforeachpercentagebywhichthebeneficiaryfailstomeetthehiring
2345+requirements.
2346+B.EMPLOYERSwhohavebeenfoundinviolation2timesormoreovera10yearperiodmay
2347+bedebarredand/ordeemedineligibleforconsiderationforProjectsforaperiodofSyears.
2348+C.Within90daysofaDeterminationofaPenalty,theBeneficiaryorEmployermayappealthe
2349+violationsorfinesbyfilingacomplaintwiththeContractAppealsBoardinaccordancewith
2350+D.C.Code§2-360.03and§2-360.04,
2351+TherebycertifythatIhavetheauthoritytobindtheEMPLOYERtothisAgreementfromthestartofwork
2352+ontheProject,throughoutthedurationoftheProject,andagreetoalltermsandconditionsherein.
2353+By:
2354+GabeOliver n/>4 [2024
2355+EMPLOYERSeniorOfficial(Print) Da
2356+
2357+
2358+EMPLOYERSeniorOfficial(Signature)
2359+GCS,Inc.DBAGCS-SIGAL
2360+NameofCompany
2361+11403rdStNE,Ste320
2362+Washington,DC20002
2363+Address Ss—S
2364+202.944.6600
2365+Telephone
2366+goliver@gcs-sigal.com
2367+Emil
2368+
2369+‘SignatureDepartmentofEmploymentServices Date
2370+Page11of11FistSourceEmploymentAgreement,RevisedFebrary15,2018 *** ***
2371+GOVERNMENT OF THE DISTRICT OF COLUMBIA
2372+REVISED EMPLOYMENT PLAN
2373+I. REVISED FIRST SOURCE EMPLOYMENT PIAN
2374+GOVERNMENT-ASSISTEDPROJ ECT/CONTRACT INFORMATION
2375+DISTRICT CONTRACTING AGENCY:
2376+_
2377+De
2378+_
2379+pa
2380+_
2381+rtm
2382+_
2383+en
2384+_
2385+t o
2386+_
2387+l
2388+G_
2389+en
2390+_
2391+e,a
2392+_
2393+l
2394+s_
2395+erv
2396+_
2397+ice
2398+_
2399+s
2400+_____ ___ __ _
2401+CONTRACTING OFFICER:i
2402+TELEPHONE NUMBER:
2403+---------------------
2404+__________________ _
2405+TOTAL CONTRACT AMOUNT: $15
2406+,
2407+ao1.253 --------------------
2408+EMPLOYER CONTRACT AMOUNT: $15
2409+,
2410+801
2411+,
2412+2
2413+53 ------------------
2414+PROJECT NAME: Stead Park Recreation Center
2415+-------------------------
2416+PROJECT ADDRESS: 162
2417+5
2418+PSlreel
2419+NW -------- ----------------
2420+CITY: Washington
2421+STATE:�ZIP CODE: _
2422+20
2423+_
2424+0
2425+3_
2426+6
2427+_____ ____ _
2428+PROJECT D ESCRJPTJ QN QF WORK:
2429+Modernization of !he Stead Park Recreation Center lo include renova1ing the existing carriage house building,
2430+providing a new addition, replacing the existing playground
2431+,
2432+and renovating the spray park.
2433+PROJECT START DATE:_Au_gu_st_
2434+9
2435+·_
2436+2
2437+0
2438+2
2439+_
2440+2
2441+___ _ PROJECT END DATE: _oc
2442+_
2443+io_be,
2444+_
2445+4._
2446+20
2447+_
2448+24
2449+___
2450+_
2451+EMPLOYER START DATE: August9•2
2452+0
2453+22 EMPLOYER END DATE: Oclober4,2024 -------
2454+EMPLOYER INFORMATION
2455+EMPLOYER NAME: _Gc_s_, r
2456+n
2457+_
2458+c
2459+d_
2460+ba
2461+_Gc_s_-s,_G
2462+A
2463+_L _ ___ ________ _____
2464+_
2465+_
2466+COMPANY NAME: _a_cs_-s,_a
2467+A
2468+_L ____ _____________ ____ _
2469+EMPLOYER ADDRESS: _,,_
2470+40
2471+_3
2472+rd
2473+_s_
2474+t
2475+N_E s_
2476+te
2477+_3
2478+2
2479+_0
2480+_______ ______ ____ _
2481+CITY: Washington STATE:
2482+D.C. ZIP CODE:
2483+20002 ------
2484+TELEPHONE NUMBER: (
2485+2
2486+0
2487+2
2488+>
2489+944
2490+-
2491+550
2492+° FEDERAL IDENTIFICATION NO.: 5
2493+2
2494+-
2495+1
2496+4
2497+88921
2498+-----
2499+CONTACT PERSON:
2500+G
2501+abeOlkiver ------------------------
2502+TITLE: Partner and Senior Vice President
2503+E-MAJL: goliver@gcs-sigal.com
2504+TELEPHONE NUMBER:
2505+_
2506+20
2507+_
2508+2.9
2509+_4
2510+4
2511+_
2512+_ 66
2513+_
2514+00
2515+_
2516+_
2517+_
2518+EMPLOYER D ESCRJPTI ON OF WORK: Construction Manager at Risk (CMAR) services lorthe renovation ol Stead Park Recreation Center.
2519+ARE YOU A SUBCONTRACTOR YES 0 NO [i]
2520+IF YES, NAME OF PRIME CONTRACTOR: _______________ _
2521+PRIME CO NTRACTOR WILL MEET HOURS WORKED PERCENTAGES REQUIREMENTS
2522+FOR ENTIRE PROJECT □ OR PER EACH SUBCONTRACTOR [.i
2523+11.EMPLOYMENT HOURS TO BE WORKED PROJECTIONS
2524+A
2525+JO
2526+t
2527+GCS-SIGAL is the Construction Manager at Risk (CMAR) for this project. We
2528+s
2529+will not have hourly/classifiable staff assigned to this project. We will staff this
2530+project using existing employees.
2531+Pr"""'"---------------------------------·· e
2532+project or contract and the total number of journey worker hours, by trade, to be worked by
2533+District residents.
2534+This page to be completed by Employer
2535+Employer Initials Obaidullah Ranjbar 202-359-3362 +
2536+*
2537++
2538+GOVERNMENTOFTHEDISTRICTOFCOLUMBIA
2539+*
2540+*
2541+REVISEDEMPLOYMENT PLAN
2542+
2543+Journey
2544+ProjectionofTotalNumberof Trade
2545+WorkerHours
2546+ProjectionofTotalNumberofJourney
2547+WorkerHoursbyDCResidents
2548+(FirstSourceLawrequires20%)
2549+
2550+
2551+
2552+
2553+APPRENTICE
2554+Provideaprojectionofthetotalnumberofapprenticeh
2555+projectorcontractandthetotalnumberofapprenticehours,bytrade,tobeworkedbyDistrict
2556+residents.
2557+jours,bytrade,tobeworkedonthe
2558+
2559+Apprenti
2560+ProjectionofTotalNumberof Trade
2561+iceHours
2562+ProjectionofTotalNumberof
2563+ApprenticeHoursbyDCResidents
2564+(FirstSourceLawrequires60%)
2565+
2566+
2567+SKILLEDWORKER
2568+Provideaprojectionofthetotalnumberofskilledlaborerhours,bytrade,tobeworkedonthe
2569+projectorcontractandthetotalnumberofskilledlaborerhours,bytrade,tobeworkedby
2570+Districtresidents.
2571+
2572+ProjectionofTotalNumberof
2573+SkilledLaborHours
2574+‘Trade ProjectionofTotalNumberof
2575+SkilledLaborHoursbyDC
2576+Residents
2577+(FirstSourceLawrequires51%)
2578+
2579+
2580+
2581+COMMONLABORER
2582+Provideaprojectionofthetotalnumberofcommonlaborerhourstobeworkedontheproject
2583+orcontractandthetotalnumberofcommonlaborerhourstobeworkedbyDistrictresidents.
2584+
2585+ProjectionofTotalNumberof
2586+CommonLaborerHours
2587+‘Trade ProjectionofTotalNumberofCommon
2588+LaborerHoursbyDCResidents
2589+(FirstSourceLawrequires70%)
2590+Il:
2591+
2592+
2593+
2594+
2595+ThispagetobecompletedbyEmployer bee
2596+
2597+
2598+poo GOVERNMENTOFTHEDISTRICTOFCOLUMBIA
2599+REVISEDEMPLOYMENT PLAN
2600+B.EMPLOYMENTHIRINGPROJECTIONS
2601+ALLEMPLOYERS:
2602+PleaseindicateALLnewposition(s)youwillcreateasaresultoftheproject.IfyouWILLNOT
2603+becreatinganynewemploymentopportunities,pleasecompletetheattachedjustification
2604+sheetwithanexplanation.Attachadditionalsheetsasneeded.
2605+
2606+
2607+
2608+
2609+
2610+
2611+
2612+
2613+
2614+
2615+
2616+
2617+
2618+JOBTITLE #OFJOBS|SALARY UNIONMEMBERSHIP PROJECTE
2619+F/T_P/T_|RANGE REQUIREDNAMELOCAL# DHIRE
2620+A
2621+B GCS-SIGALwillnotbecreatingnewpositionsforthiscontract.
2622+ic
2623+D
2624+iE
2625+iF
2626+IG
2627+H
2628+I
2629+K
2630+
2631+
2632+
2633+
2634+
2635+
2636+ThispagetobecompletedbyEmployer bet
2637+EmployerInitials
2638+
2639+ +
2640+*
2641++
2642+GOVERNMENTOFTHEDISTRICTOFCOLUMBIA
2643+REVISEDEMPLOYMENT PLAN
2644+C.JUSTIFICATIONSHEET:PleaseprovideadetailedexplanationofwhytheEmployerwillnot
2645+haveanynewhiresontheproject.
2646+GCS-SIGAListheConstructionManageratRisk(CMAR)forthisproject.Wewillnothave
2647+hourly/classifiablestaffassignedtothisproject.Wewillstaffthisprojectusingexisting
2648+employees.
2649+ga— ThispagetobecompletedbyEmployer
2650+
2651+EmployerInitials
2652+
2653+ * +
2654+*
2655+*
2656+*
2657+GOVERNMENTOFTHEDISTRICTOFCOLUMBIA
2658+REVISEDEMPLOYMENT PLAN
2659+D.EMPLOYMENTPROJECTIONS.
2660+Provideatimetableoutliningthetotalhoursworkedbytradeoverthelifeoftheprojector
2661+contractandanassociatedhiringschedule.
2662+
2663+N/A-NonewpositionstobecreatedfortheCMAR
2664+
2665+
2666+Providedescriptionsoftheskillrequirementsbyjobtitleorposition,includingindustry-
2667+recognizedcertificationsrequiredforthedifferentpositions.
2668+
2669+N/A-NonewpositionstobecreatedfortheCMAR.
2670+
2671+
2672+ProvideastrategytofillthehoursrequiredtobeworkedbyDistrictresidents,includinga
2673+componentoncommunicatingtheserequirementstocontractorsandsubcontractorsanda
2674+componentonpotentialcommunityoutreachpartnershipswiththeUniversityoftheDistrict
2675+ofColumbia,theUniversityoftheDistrictofColumbiaCommunityCollege,theDepartment
2676+ofEmploymentServices,JointlyFundedApprenticeshipPrograms,theDistrictofColumbia
2677+WorkforceIntermediary,orothergovernment-approved,community-basedjobtraining
2678+providers.
2679+
2680+N/A-NonewpositionstobecreatedfortheCMAR
2681+
2682+
2683+
2684+ThispagetobecompletedbyEmployer pe —i
2685+Employerh
2686+
2687+
2688+ *
2689+*
2690++
2691+*
2692+REVISEDEMPLOYMENT PLAN
2693+D.EMPLOYMENTPROJECTIONS(Continued)
2694+Ww
2695+vi
2696+vil.
2697+**
2698+GOVERNMENTOFTHEDISTRICTOFCOLUMBIA ae
2699+Aremediationstrategytoameliorateanyproblemsassociatedwithmeetingtheseworked
2700+hourspercentagerequirements,includinganyproblemsencounteredwithcontractorsand
2701+subcontractors.
2702+
2703+N/A-NonewpositionstobecreatedfortheCMAR
2704+
2705+Thedesignationofaseniorofficialfromthegeneralcontractorwhowillberesponsi
2706+implementingthehoursworkedpercentagesandreportingrequirements.
2707+iblefor
2708+
2709+DanWaldo,PartnerandSVPatGCS-SIGAL,willbethedesignatedperson.
2710+
2711+residentsworkingontheprojectorcontract.
2712+ProvidedescriptionsofthehealthandretirementbenefitsthatwillbeprovidedtoDistrict
2713+
2714+GCS-SIGALoffersfullhealth,dental,STD,LTD,401(k),familyleave,and
2715+otherbenefitstoallemployees.
2716+
2717+ProvideastrategytoensurethatDistrictresidentswhoworkontheprojectorcontract
2718+receiveongoingemploymentandtrainingopportunitiesaftertheycompleteworkonthejob
2719+forwhichtheywereinitiallyhiredandareviewofpastpracticesincontinuingtoemploy
2720+Districtresidentsfromoneprojectorcontracttothenext.
2721+
2722+N/A-NonewpositionstobecreatedfortheCMAR
2723+
2724+
2725+ hee
2726+ThispagetobecompletedbyEmployer
2727+
2728+EmployerInitials
2729+
2730+ *
2731+*
2732+D.
2733+vill.
2734+IK.
2735+*
2736+*
2737+*
2738++
2739+GOVERNMENTOFTHEDISTRICTOFCOLUMBIA
2740+REVISEDEMPLOYMENT PLAN
2741+EMPLOYMENTPROJECTIONS(continued)
2742+ProvideastrategytohiregraduatesofDistrictofColumbiaPublicSchools,Districtof
2743+ColumbiaPublicCharterSchools,community-basedjobtrainingproviders,andhard-to-
2744+employresidents.
2745+
2746+N/A-NonewpositionstobecreatedfortheCMAR
2747+
2748+
2749+PleasedisclosepastcompliancewiththeFirstSourceEmploymentAgreementActof1984or
2750+theWorkforceIntermediaryEstablishmentandReformofFirstSourceAmendmentActof
2751+2011andtheDavis-BaconAct,whereapplicable,andthebidderorofferor'sgeneralDistrict-
2752+residenthiringpracticesonprojectsorcontractscompletedwithinthelasttwo(2)years.
2753+
2754+GCS-SIGALhasastrongtrackrecordofmeetingtherequirementsofthe
2755+FirstSourceactonourDGSprojects.
2756+
2757+
2758+PleasenotethatEMPLOYERSonconstructionprojectsmustsubmitweeklycertifiedpayrolls
2759+fromallsubcontractorsatanytierworkingontheprojectorcontract,aswellasmakesuch
2760+payrollandpersonnelrecordsavailableuponrequestatjobsitestothecontractingDistrictof
2761+Columbiaagency.
2762+
2763+‘Acknowledged.
2764+
2765+
2766+
2767+ThispagetobecompletedbyEmployer eeren
2768+EmployerInitials
2769+
2770+ xk
2771+GOVERNMENTOFTHEDISTRICTOFCOLUMBIA ieee
2772+xkk
2773+=F
2774+REVISEDEMPLOYMENT PLAN
2775+Onceapproved,thisrevisedemploymentplanshallnotbeamendedexceptwiththeapprovalofDepartment
2776+ofEmploymentServices.
2777+B
2778+ithe OM]wy
2779+EMPLOYERSeniorOfficial(Print) Dat
2780+EMPLO™Zon -
2781+GCS,Inc.GCS-SIGAL
2782+NameofCompany
2783+11403rdStNE,Ste320
2784+Washington,DCDC20002
2785+Address OO
2786+202.944.6600
2787+Telephone
2788+goliver@gcs-sit
2789+Email
2790+
2791+SignatureDepartmentofEmploymentServicesDate 1101 4
2792+th
2793+Street, SW
2794+Washington, DC 20024
2795+Date of Notice:April 3, 2024 L0011586783Notice Number:
2796+FEIN: **-***8921
2797+Case ID: 2542283
2798+ 
2799+Government of the District of Columbia
2800+Office of the Chief Financial Officer
2801+Office of Tax and Revenue
2802+GCS INC
2803+1140 3RD ST NE STE 320
2804+WASHINGTON DC 20002-7899
2805+
2806+Branch Chief, Collection and Enforcement Administration
2807+Authorized By Melinda Jenkins
2808+To validate this certificate, please visit MyTax.DC.gov. On the MyTax DC homepage, click the
2809+“Validate a Certificate of Clean Hands” hyperlink under the Clean Hands section.
2810+CERTIFICATE OF CLEAN HANDS
2811+As reported in the Clean Hands system, the above referenced individual/entity has no outstanding
2812+liability with the District of Columbia Office of Tax and Revenue or the Department of Employment
2813+Services. As of the date above, the individual/entity has complied with DC Code § 47-2862, therefore
2814+this Certificate of Clean Hands is issued.
2815+TITLE 47. TAXATION, LICENSING, PERMITS, ASSESSMENTS, AND FEES
2816+CHAPTER 28 GENERAL LICENSE
2817+SUBCHAPTER II. CLEAN HANDS BEFORE RECEIVING A LICENSE OR PERMIT
2818+D.C. CODE § 47-2862 (2006)
2819+§ 47-2862 PROHIBITION AGAINST ISSUANCE OF LICENSE OR PERMIT
2820+1101 4th Street SW, Suite W270, Washington, DC 20024/Phone: (202) 724-5045/MyTax.DC.gov
2821+  INCREASEPENALTYRIDER
2822+
2823+BONDAMOUNT$15,301,683.00BONDNO.0682881
2824+TobeattachedandformapartofBondNo.0682881datedthe22ndDayofJuly,
2825+2021,executedbyHarcoNationalInsuranceCompanyassurety,onbehalfofGCS,
2826+Inc.dbaGCS-SIGALascurrentprincipalofrecord,andinfavorofDistrictof
2827+ColumbiaGovernment,asObligeeforContractNo.DCAM-20-C:1021
2828+ConstructionManagementAt-RiskServicesforSteadParkRecreationCenter,andin
2829+theamountofFifteenMillionThreeHundredOneThousandSixHundredEighty
2830+ThreeDollarsand00/100($15,301,683.00).
2831+
2832+
2833+
2834+Inconsiderationoftheagreedpremiumchargedforthisbond,itisunderstoodand
2835+agreedthatHarcoNationalInsuranceCompanyherebyconsentsthateffectivefrom
2836+the18thDayofMarch,2024,saidbondshallbeamendedasfollows:
2837+THEBONDPENALTYSHALLBEINCREASED:
2838+FROM:FifteenMillionThreeHundredOneThousandSixHundredEightyThree
2839+Dollarsand00/100($15,301,683.00)
2840+TO:FifteenMillionEightHundredOneThousandTwoHundredFiftyThreeDollars
2841+and00/100($15,801,253.00)
2842+TheINCREASEofsaidbondpenaltyshallbeeffectiveasofthe18thDayofMarch,
2843+2024,anddoesherebyagreethatthecontinuityofprotectionundersaidbond
2844+subjecttochangesinpenaltyshallnotbeimpairedhereby,providedthatthe
2845+aggregateliabilityoftheabovementionedbondshallnotexceedtheamountof
2846+liabilityassumedbyitatthetimetheactand/oractsofdefaultwerecommitted
2847+andinnoeventshallsuchliabilitybecumulative.
2848+Signed,sealedanddatedthis18thDayofMarch,2024
2849+
2850+
2851+S,Inc.dbaGCS-SIGAL
2852+PRINCIPAL
2853+YBorlVEN
2854+iti InsuranceCompany
2855+SURETY
2856+ny =a
2857+'M.Coen,ATTORNEY-IN-FACT
2858+‘THEABOVEBONDISHEREBYAGREEDTOANDACCEPTEDBY:
2859+DistrictofColumbiaGovernment
2860+OBLIGEE
2861+
2862+
2863+
2864+LE POWEROFATTORNEY
2865+HARCONATIONALINSURANCECOMPANY
2866+INTERNATIONALFIDELITYINSURANCECOMPANY
2867+‘MembercompaniesofIATInsuranceGroup,Headquartered:4200SixForksRd,Suite1400,Raleigh,NC27609
2868+Bond osazea1
2869+Principal_GCS,Inc.dbaGCS-SIGAL
2870+Obiigee_DistrictofColumbiaGovernment
2871+KNOWALLMENBYTHESEPRESENTS:ThatHARCONATIONALINSURANCECOMPANY,acorporationorganizedandexistingunderthelawsof
2872+theStateofilinois,andINTERNATIONALFIDELITYINSURANCECOMPANY.acorporationorganizedandexistingunderthelawsoftheStateofNew
2873+Jersey,andhavingtheirprncipalofficeslocatedrespectivelyinthecitesofRolingMeadows,tina'sandNewark,NewJersey,doherebyconstituteand
2874+‘appoint
2875+KathleenM.Coon
2876+{heirtrueandlawfulatlomey(s)-in-facttoexecute,sealanddeliverforandonitsbehalfassurety,anyandallbondsandundertakings,contractsof
2877+indemnityandotherwritingsobligatoryinthenaturethereof,whicharoormaybeallowed,requiredorpermittedbylaw,statute,ule,raguation,contract
2878+fFotherwise,andtheexecutionofsuchinstrument(s)inpursuanceofthesepresents,shallbeasbindinguponthesaidHARCONATIONAL,
2879+INSURANCECOMPANYandINTERNATIONALFIDELITYINSURANCECOMPANY,asfullyandamply,toallnlentsandpurposes,asthesamehad
2880+‘beendulyexecutedandacknowledgedbytheirregularlyelectedofficersattheirprincipaloffices.
2881+‘ThisPowerofAltomeyisexecuted,andmayberevoked,pursuanttoandbyauthontyoftheBy-LawsofHARCONATIONALINSURANCECOMPANY
2882+‘andINTERNATIONALFIDELITYINSURANCECOMPANYandisgrantedunderandbyauthontyofthefolowingresolutionadoptedbytheBoardof
2883+DirectorsofINTERNATIONALFIDELITYINSURANCECOMPANYalameetingdulyheldonthe13thdayofDecember,2018andbytheBoardof
2884+DwrectorsofHARCONATIONALINSURANCECOMPANYalameetingheldonthet3thdayofDecember,2018.
2885+“RESOLVED,that(1)theChiefExecutiveOficar,President,ExecutiveVicePresident,SeniorVicePresident,VicePresident,orSecretaryofthe
2886+Corporationshallhavethepowertoappoint,andtorevoketheappointmentsof,Altomeys-in-FactoragentswithpowerandauthorityasdefinedoFlited
2887+Intheirrespectivepowersofattomey,andtoexecuteonbehalfoftheCorporationandaffixtheCorporation'ssealthereto,bonds,undertakings,
2888+‘ocognizances,contractsofindemnityandothrwrittenobligationsinthenaturethereoforrelatedthereto;and(2)anysuchOfficersoftheCorporation
2889+‘mayappointandrevoketheappointmentsofjoint-controtcustodians,agentsforacceptanceofprocess,andAltomeys-in-lactwithauthontytoexecute
2890+waiversandconsentsonbehalloftheCorporation,and(3)thesignatureofanysuchOtficeroftheCorporationandtheCorporation'ssealmaybeaffixed
2891+byfacsimiletoanypowerofattomeyoFcatificationgivenfortheexecutionofanybond,undertaking,recognizance,contractofindemnityorotherwriten
2892+‘obligationinthenaturethereoforrelatedthereto,suchsignatureandsealswhensousedwhetherheretoloreorhereatter,beingherebyadoptedbythe
2893+CorporationastheonginalsignatureofsuchofficerandtheonginalsealoftheCorporation,tobevalidandbindingupontheCorporationwaththesame
2894+forceandeffectasthoughmanuallyaffixed."
2895+INWITNESSWHEREOF,HARCONATIONALINSURANCECOMPANYandINTERNATIONAL
2896+FIDELITYINSURANCECOMPANYhaveeachexecutedandattestedthesepresents,
2897+fonthis31stdayofDecember,2023,
2898+‘STATEOFNEWJERSEY ‘STATEOFILLINOIS
2899+CountyofEssex ‘CountyofCook
2900+WichaelF.Zurcher
2901+ExecutiveVicePresident,HarcoNationalInsuranceCompany
2902+‘andIntemationalFidelityInsuranceCompany
2903+Onthis31stdayofDecember,2023_,beforemocametheindividualwhoexecutedtheprecedinginstrument,tomepersonallyknown,and,
2904+beingbymedulysworn,saidhe'SthethereindescribedandauthorizedofficerofHARCONATIONALINSURANCECOMPANYand
2905+INTERNATIONALFIDELITYINSURANCECOMPANY;thatthosealsaffxedtosaidinstrumentaretheCorporateSealsofsaidCompanies;thatthe
2906+‘saidCorporateSealsandhissignatureweredulyaffixedbyorderoftheBoardsofDirectorsofsaidCompanies,
2907+oyCo INTESTIMONYWHEREOF,|havehereuntosotmyhandaffixedmyOfficialSeal,attheCityofNewark,
2908+NewJerseythedayandyearfirstabovewriten,
2909+HE
2910+CatiryCruzaNolaryPublicofNewJersey
2911+‘MyCommissionExpiresApril16,2029
2912+CERTIFICATION
2913+|,theundersignedofficerofHARCONATIONALINSURANCECOMPANYandINTERNATIONALFIDELITYINSURANCECOMPANYdoherebycertify
2914+tat|RavecomparedtheforegoingcopyofthePowerofAttorneyandalidavil,andthecopyoftheSactionsoftheBy-LawsofsaidCompaniosassot
2915+{orthinsaidPowerofAttomey,withtheoriginalsonfilointhehomeofficeofsaidcompanies,andthatthesamearecorrecttranscriptsthereof,andofthe
2916+wholeofthesaidonginals,andthatthesexdPovierofAllomeyhasnotbeenrevokedandisnowinfullforceandeffect
2917+(hudba
2918+
2919+INTESTIMONYWHEREOF,|havehoreuntosetmyhandthis18thdayofMarch,2024