81R4908 BEF-F
By: Farrar H.B. No. 2095
A BILL TO BE ENTITLED
AN ACT
relating to the regulation of and claims against residential home
builders.
BE IT ENACTED BY THE LEGISLATURE OF THE STATE OF TEXAS:
ARTICLE 1. CHANGES TO TEXAS RESIDENTIAL
CONSTRUCTION COMMISSION ACT
SECTION 1.01. Section 401.003(a), Property Code, is amended
to read as follows:
(a) In this title, "builder" means any person who, for a
fixed price, commission, fee, wage, or other compensation, sells,
constructs, or supervises or manages the construction of, or
contracts for the construction of or the supervision or management
of the construction of:
(1) a new home;
(2) a material improvement to a home, other than an
improvement solely to replace or repair a roof of an existing home;
or
(3) an improvement to the interior of an existing home
[when the cost of the work exceeds $10,000].
SECTION 1.02. Chapter 401, Property Code, is amended by
adding Section 401.008 to read as follows:
Sec. 401.008. HOMEOWNER FEES NOT REQUIRED. A homeowner may
not be charged a fee in connection with:
(1) filing a complaint with the commission;
(2) a state-sponsored inspection or dispute
resolution process;
(3) an arbitration required by this title; or
(4) a complaint, request, or other proceeding under
Chapter 409 or Subtitle D or E.
SECTION 1.03. Section 406.001(a), Property Code, is amended
to read as follows:
(a) The Texas Residential Construction Commission consists
of nine members appointed by the governor with the advice and
consent of the senate as follows:
(1) four members must be builders who each hold a
certificate of registration under Chapter 416;
(2) three members must be representatives of the
general public who have consistently shown an interest in consumer
protection;
(3) one member must be a licensed professional
engineer who practices in the area of residential construction; and
(4) one member must be either a licensed architect who
practices in the area of residential construction or a building
inspector who meets the requirements set forth in Chapter 427 and
practices in the area of residential construction.
SECTION 1.04. Section 416.004, Property Code, is amended by
amending Subsections (a) and (b), and adding Subsection (a-1) to
read as follows:
(a) The commission shall charge and collect:
(1) a filing fee for an application for an original
certificate of registration of at least [that does not exceed]
$500;
(2) a fee for renewal of a certificate of registration
of at least [that does not exceed] $300; and
(3) a late fee that does not exceed the amount of the
fee due if payment of a registration application or renewal fee due
under this title is late.
(a-1) A fee charged under Subsection (a) applies to each
builder, including a corporation, limited liability company,
partnership, limited partnership, limited liability partnership,
sole proprietor, and any subsidiary of those persons.
(b) The commission shall establish a fee schedule that takes
into consideration the unit volume or dollar volume of potential
applicants. The commission may raise registration and renewal fees
as necessary to provide public service in connection with
investigations of construction defect complaints filed by
homeowners under this title.
SECTION 1.05. Section 416.005, Property Code, is amended to
read as follows:
Sec. 416.005. GENERAL ELIGIBILITY REQUIREMENTS. A person
may not receive a certificate of registration under this chapter
unless:
(1) the person, at the time of the application:
(A) is at least 18 years of age; [and]
(B) is a citizen of the United States or a
lawfully admitted alien; and
(C) provides proof of financial responsibility
as required by Section 416.013; and
(2) the commission is satisfied with the person's
honesty, trustworthiness, and integrity based on information
supplied or discovered in connection with the person's application.
SECTION 1.06. Section 416.010(c), Property Code, is amended
to read as follows:
(c) If a builder operates under any name other than the name
that is set forth on the builder's certificate of registration, the
builder shall, within 20 [45] days of operating under this other
name, disclose this other name to the commission.
SECTION 1.07. Sections 416.011(a) and (b), Property Code,
are amended to read as follows:
(a) The commission shall establish rules and procedures for
a program through which a builder can be designated as a "Texas Star
Builder." A builder's participation in the program is mandatory
[voluntary] and is [not] a requirement for holding and renewing
[the issuance of] a certificate of registration required under this
chapter.
(b) A builder shall [who participates in this program will
be allowed to] represent to the public that the builder is a "Texas
Star Builder" and meets all of the requirements and qualifications
that are set forth by the commission for the program.
SECTION 1.08. Chapter 416, Property Code, is amended by
adding Sections 416.013 and 416.014 to read as follows:
Sec. 416.013. INSURANCE REQUIREMENTS. (a) To be eligible
for an original or renewal certificate of registration under this
chapter, a builder must provide proof of financial responsibility
to the commission by maintaining a general liability insurance
policy with a limit of at least $500,000.
(b) The commission may increase the insurance requirements
based on the builder's unit or dollar volume.
Sec. 416.014. BOND REQUIREMENT. A builder shall maintain a
surety bond for each construction project described by Section
401.003. The bond must:
(1) guarantee the builder's performance under the
builder's contract with the owner; and
(2) be issued in an amount not less than the fair
market value of the completed project if the project had no defects.
SECTION 1.09. Section 418.001, Property Code, is amended to
read as follows:
Sec. 418.001. GROUNDS FOR DISCIPLINARY ACTION. A person,
including a builder or a person who is designated as a builder's
agent under Section 416.006, or a person who owns or controls a
majority ownership interest in the builder is subject to
disciplinary action under this chapter for:
(1) fraud or deceit in obtaining a registration or
certification under this subtitle;
(2) misappropriation or misapplication of trust funds
in the practice of residential construction, including a violation
of Chapter 32, Penal Code, or Chapter 162, if found by a final
nonappealable court judgment;
(3) naming false consideration in a contract to sell a
new home or in a construction contract;
(4) discriminating on the basis of race, color,
religion, sex, national origin, or ancestry;
(5) publishing a false or misleading advertisement;
(6) failure to honor, within a reasonable time, a
check issued to the commission, or any other instrument of payment,
including a credit or debit card or electronic funds transfer,
after the commission has sent by certified mail a request for
payment to the person's last known business address, according to
commission records;
(7) failure to pay an administrative penalty assessed
by the commission under Chapter 419 or a fee due under Chapter 426;
(8) failure to pay a final nonappealable court
judgment arising from a construction defect or other transaction
between the person and a homeowner;
(9) failure to register a home as required by Section
426.003;
(10) failure to remit the fee for registration of a
home under Section 426.003;
(11) failure to reimburse a homeowner the amount
ordered by the commission as provided by Section 428.004(d);
(12) engaging in statutory or common-law fraud or
misappropriation of funds, as determined by the commission after a
hearing under Section 418.003;
(13) a repeated failure to participate in the
state-sponsored inspection and dispute resolution process if
required by this title;
(14) failure to register as a builder as required
under Chapter 416;
(15) using or attempting to use a certificate of
registration that has expired or that has been revoked;
(16) falsely representing that the person holds a
certificate of registration issued under Chapter 416;
(17) acting as a builder using a name other than the
name or names disclosed to the commission;
(18) aiding, abetting, or conspiring with a person who
does not hold a certificate of registration to evade the provisions
of this title or rules adopted under this title, if found by a final
nonappealable court judgment;
(19) allowing the person's certificate of registration
to be used by another person;
(20) acting as an agent, partner, or associate of a
person who does not hold a certificate of registration with the
intent to evade the provisions of this title or rules adopted under
this title;
(21) a failure to reasonably perform on an accepted
offer to repair or a repeated failure to make an offer to repair
based on:
(A) the recommendation of a third-party
inspector under Section 428.004; or
(B) the final holding of an appeal under Chapter
429;
(22) a repeated failure to respond to a commission
request for information;
(23) a failure to obtain a building permit required by
a political subdivision before constructing a new home or an
improvement to an existing home;
(24) abandoning, without justification, any home
improvement contract or new home construction project engaged in or
undertaken by the person, if found to have done so by a final,
nonappealable court judgment;
(25) a repeated failure to comply with the
requirements of Subtitle F; [or]
(26) failure by the builder to complete a home under
the contract terms with a homeowner;
(27) failure by the builder to correct a failure to
comply with building codes or standards;
(28) failure by the builder to comply with
architectural drawings specified in a contract to build or purchase
a home;
(29) failure by the builder to comply with an
engineering design of a home, including the home's foundation;
(30) failure by the builder to satisfy a court
judgment or a judgment in a binding arbitration; or
(31) otherwise violating this title or a commission
rule adopted under this title.
SECTION 1.10. Section 426.001(b), Property Code, is amended
to read as follows:
(b) This subtitle does not apply to a dispute arising out
of:
(1) an alleged violation of Section 27.01, Business &
Commerce Code; or
(2) [a builder's wrongful abandonment of an
improvement project before completion; or
[(3)] a violation of Chapter 162.
SECTION 1.11. Sections 428.001(a), (b), and (d), Property
Code, are amended to read as follows:
(a) If a dispute between a homeowner and a builder arises
out of an alleged construction defect, the homeowner [or the
builder] may submit to the commission a written request for
state-sponsored inspection and dispute resolution.
(b) The request must:
(1) specify in reasonable detail each alleged
construction defect that is a subject of the request;
(2) state the amount of any known out-of-pocket
expenses and engineering or consulting fees incurred by the
homeowner in connection with each alleged construction defect; and
(3) [include any evidence that depicts the nature and
cause of each alleged construction defect and the nature and extent
of repairs necessary to remedy the construction defect, including,
if available, expert reports, photographs, and videotapes, if that
evidence would be discoverable under Rule 192, Texas Rules of Civil
Procedure;
[(4) be accompanied by the fees required under Section
426.004; and
[(5)] state the name of any person who has, on behalf
of the homeowner [requestor], inspected the home in connection with
an alleged construction defect.
(d) At the time a person submits a request under this
section, the person must send by certified mail, return receipt
requested, a copy of the request[, including evidence submitted
with the request,] to each other party involved in the dispute.
SECTION 1.12. Section 428.002(a), Property Code, is amended
to read as follows:
(a) In addition to the right of inspection provided by
Section 428.001(c), [at any time] before the conclusion of the
state-sponsored inspection and dispute resolution process and on
the builder's written request, the builder shall be given
reasonable opportunity to inspect the home that is the subject of
the request or have the home inspected to determine the nature and
cause of the construction defect and the nature and extent of
repairs necessary to remedy the construction defect.
SECTION 1.13. Sections 428.004(b) and (d), Property Code,
are amended to read as follows:
(b) If the dispute involves a structural matter in the home,
the commission shall appoint an approved engineer to be the
third-party inspector. The third-party inspector shall inspect the
home not later than the 15th [30th] day after the date the request
is submitted and issue a recommendation not later than the 30th
[60th] day after the date the third-party inspector receives the
assignment from the commission[, unless additional time is
requested by the third-party inspector or a party to the dispute.
The commission shall adopt rules governing the extension of time
under this subsection].
(d) Except as provided by this subsection, the third-party
inspector's recommendation may not include payment of any monetary
consideration. [If the inspector finds for the party who submitted
the request, the commission may order the other party to reimburse
all or part of the fees and inspection expenses paid by the
requestor under Section 426.004.]
SECTION 1.14. Section 429.001(c), Property Code, is amended
to read as follows:
(c) The panel shall:
(1) review the recommendation for compliance with this
title as required by rules adopted by the commission;
(2) approve, reject, or modify the recommendation of
the third-party inspector or remand the dispute for further action
by the third-party inspector; and
(3) issue written findings of fact and a ruling on the
appeal not later than the 15th [30th] day after the date the notice
of appeal is filed with the commission.
SECTION 1.15. Section 430.001(b), Property Code, is amended
to read as follows:
(b) The warranty periods shall be:
(1) two years [one year] for workmanship and
materials;
(2) two years for plumbing, electrical, heating, and
air-conditioning delivery systems; and
(3) 10 years for major structural components of the
home.
SECTION 1.16. Chapter 430, Property Code, is amended by
adding Section 430.0075 to read as follows:
Sec. 430.0075. FULL DISCLOSURE WITH INFORMED CONSENT. (a)
Before a contract may be executed between a builder and seller and a
buyer for construction of a new home and before money may be
exchanged between the parties to the contract, the builder and
seller must provide to the buyer a full disclosure and informed
consent document that meets the following requirements:
(1) the buyer must receive from the builder and seller
full disclosure of product installation, care and component
warranties, building standards, risks, and hazards of the
particular property and home to be purchased;
(2) the buyer must receive from the builder and seller
full disclosure in understandable terms of any mandatory
alternative dispute resolution provisions, including mandatory
binding arbitration, and the associated costs of the various
processes; and
(3) the buyer must consent in writing to accept the
terms of the builder's and seller's disclosures and provisions for
new home construction by signing and dating the consent document.
(b) The builder and seller shall fully disclose in writing:
(1) the products that are installed in the home;
(2) care and component warranties;
(3) building standards; and
(4) risks and hazards of the home.
SECTION 1.17. Section 430.008(a), Property Code, is amended
to read as follows:
(a) The commission may approve as a third-party warranty
company for the purposes of Section 430.009:
(1) [an entity that has operated warranty programs in
this state for at least five years;
[(2)] a company whose performance is insured by an
insurance company authorized to engage in the business of insurance
in this state; or
(2) [(3)] an insurance company that insures the
warranty obligations of a builder under the statutory warranty and
building and performance standards.
SECTION 1.18. Section 430.010, Property Code, is amended to
read as follows:
Sec. 430.010. MINIMUM STANDARDS FOR DETERMINATION OF
DEFECT. A third-party warranty company shall use defect inspection
procedures substantially similar to the procedures adopted by the
commission under this subtitle. A warranty company may adopt
warranty standards in addition to the standards adopted by the
commission. A third-party warranty company may not reduce the
limited statutory warranty and building and performance
standards[, except that a third-party warranty company shall not be
required to provide a warranty of habitability].
SECTION 1.19. Section 430.011(c), Property Code, is amended
to read as follows:
(c) Breach of a limited statutory warranty adopted by the
commission or breach of the statutory warranty of habitability is
[shall not, by itself, constitute] a violation of the Deceptive
Trade Practices-Consumer Protection Act (Subchapter E, Chapter 17,
Business & Commerce Code).
SECTION 1.20. Sections 416.011(c), 426.004, 426.007,
426.008(b), 428.004(e), and 430.009(e), Property Code, are
repealed.
SECTION 1.21. (a) On the effective date of this Act, the
terms of the three public members of the Texas Residential
Construction Commission serving on that date expire.
(b) Not later than the 30th day after the effective date of
this Act, the governor shall appoint three members to the Texas
Residential Construction Commission to comply with Section
406.001(a), Property Code, as amended by this article, as follows:
(1) one member for a term expiring February 1, 2011;
(2) one member for a term expiring February 1, 2013;
and
(3) one member for a term expiring February 1, 2015.
SECTION 1.22. Not later than March 1, 2010, the Texas
Residential Construction Commission shall adopt any rules
necessary to implement the changes in law made by this article,
including Section 416.011, Property Code.
ARTICLE 2. CHANGES TO RESIDENTIAL CONSTRUCTION LIABILITY CHAPTER
SECTION 2.01. Section 27.002(d), Property Code, is amended
to read as follows:
(d) This chapter does not apply to an action to recover
damages that arise from:
(1) a violation of Section 27.01, Business & Commerce
Code; or
(2) [a contractor's wrongful abandonment of an
improvement project before completion; or
[(3)] a violation of Chapter 162.
SECTION 2.02. Sections 27.004(a), (b), (g), and (l),
Property Code, are amended to read as follows:
(a) In a claim not subject to Subtitle D, Title 16, before
the 60th day preceding the date a claimant seeking from a contractor
damages or other relief arising from a construction defect
initiates an action, the claimant shall give written notice by
certified mail, return receipt requested, to the contractor, at the
contractor's last known address, specifying in reasonable detail
the construction defects that are the subject of the complaint. [On
the request of the contractor, the claimant shall provide to the
contractor any evidence that depicts the nature and cause of the
defect and the nature and extent of repairs necessary to remedy the
defect, including expert reports, photographs, and videotapes, if
that evidence would be discoverable under Rule 192, Texas Rules of
Civil Procedure.] During the 20-day [35-day] period after the date
the contractor receives the notice, [and on the contractor's
written request,] the contractor shall be given a reasonable
opportunity to inspect and have inspected the property that is the
subject of the complaint to determine the nature and cause of the
defect and the nature and extent of repairs necessary to remedy the
defect. The contractor may take reasonable steps to document the
defect. In a claim subject to Subtitle D, Title 16, a contractor is
entitled to make an offer of repair in accordance with Subsection
(b). A claimant is not required to give written notice to a
contractor under this subsection in a claim subject to Subtitle D,
Title 16.
(b) Not later than the 15th day after the date of a final,
unappealable determination of a dispute under Subtitle D, Title 16,
if applicable, or not later than the 45th day after the date the
contractor receives the notice under this section, if Subtitle D,
Title 16, does not apply, the contractor may make a written offer of
settlement to the claimant. The offer must be sent to the claimant
at the claimant's last known address or to the claimant's attorney
by certified mail, return receipt requested. The offer may include
either an agreement by the contractor to repair or to have repaired
by an independent contractor partially or totally at the
contractor's expense or at a reduced rate to the claimant any
construction defect described in the notice and shall describe in
reasonable detail the kind of repairs which will be made. The
repairs shall be made not later than the 20th [45th] day after the
date the contractor receives written notice of acceptance of the
settlement offer, unless completion is delayed by the claimant or
by other events beyond the control of the contractor. If a
contractor makes a written offer of settlement that the claimant
considers to be unreasonable:
(1) on or before the 25th day after the date the
claimant receives the offer, the claimant shall advise the
contractor in writing and in reasonable detail of the reasons why
the claimant considers the offer unreasonable; and
(2) not later than the 10th day after the date the
contractor receives notice under Subdivision (1), the contractor
may make a supplemental written offer of settlement to the claimant
by sending the offer to the claimant or the claimant's attorney.
(g) In [Except as provided by Subsection (e), in] an action
subject to this chapter the claimant may recover only the following
economic damages proximately caused by a construction defect:
(1) the reasonable cost of repairs necessary to cure
any construction defect;
(2) the reasonable and necessary cost for the
replacement or repair of any damaged goods in the residence;
(3) reasonable and necessary engineering and
consulting fees;
(4) the reasonable expenses of temporary housing
reasonably necessary during the repair period;
(5) the reduction in current market value, if any,
after the construction defect is repaired if the construction
defect is a structural failure; and
(6) reasonable and necessary attorney's fees.
(l) If Subtitle D, Title 16, applies to the claim and the
contractor's offer of repair is accepted by the claimant, the
contractor, on completion of the repairs and at the contractor's
expense, shall engage the third-party inspector who provided the
recommendation regarding the construction defect involved in the
claim to inspect the repairs and determine whether the residence,
as repaired, complies with the applicable limited statutory
warranty and building and performance standards adopted by the
commission. [The contractor is entitled to a reasonable period not
to exceed 15 days to address minor cosmetic items that are necessary
to fully complete the repairs.] The determination of the
third-party inspector of whether the repairs comply with the
applicable limited statutory warranty and building and performance
standards adopted by the commission establishes a rebuttable
presumption on that issue. A party seeking to dispute, vacate, or
overcome that presumption must establish by clear and convincing
evidence that the determination is inconsistent with the applicable
limited statutory warranty and building and performance standards.
SECTION 2.03. Section 27.0042(c), Property Code, is amended
to read as follows:
(c) If a contractor elects to purchase the residence under
Subsection (a):
(1) the contractor shall pay the current market value
[original purchase price] of the residence determined as if the
residence did not have the construction defects, and closing costs
incurred by the homeowner and the cost of transferring title to the
contractor under the election;
(2) the homeowner may recover:
(A) reasonable and necessary attorney's and
expert fees as identified in Section 27.004(g);
(B) reimbursement for permanent improvements the
owner made to the residence after the date the owner purchased the
residence from the builder; and
(C) reasonable costs to move from the residence;
and
(3) conditioned on the payment of the purchase price,
the homeowner shall tender a special warranty deed to the
contractor, free of all liens and claims to liens as of the date the
title is transferred to the contractor, and without damage caused
by the homeowner.
SECTION 2.04. Sections 27.004(e) and (f), Property Code,
are repealed.
SECTION 2.05. The changes in law made by this article apply
only to a cause of action that accrues on or after the effective
date of this Act. A cause of action that accrues before the
effective date of this Act is governed by the law in effect
immediately before that date, and that law is continued in effect
for that purpose.
ARTICLE 3. EFFECTIVE DATE
SECTION 3.01. This Act takes effect September 1, 2009.