LRB-2916/1
ZDW:klm
2023 - 2024 LEGISLATURE
2023 ASSEMBLY BILL 275
May 17, 2023 - Introduced by Representatives STEFFEN, EDMING, BODDEN, GREEN,
MAXEY, MURSAU, PLUMER, RETTINGER, SCHMIDT, SPIROS, SWEARINGEN,
VANDERMEER and WITTKE, cosponsored by Senators TOMCZYK, COWLES, TESTIN
and JAMES. Referred to Committee on Transportation.
***AUTHORS SUBJECT TO CHANGE***
AN ACT to renumber 84.063 (1) (a) and 84.063 (1) (b); to amend 84.01 (31) and
84.062 (1) (L); and to create 84.063 (1) (c), 84.063 (1) (e), 84.063 (1) (g) and
84.063 (4m) of the statutes; relating to: damages claims relating to delayed
relocation of utilities in a highway right-of-way and modifying administrative
rules promulgated by the Department of Transportation.
Analysis by the Legislative Reference Bureau
This bill creates a process for a highway improvement contractor to seek
damages for project delays that are the result of an uncompleted relocation or
adjustment of a utility facility located in the right-of-way of the highway. “Utility
facility” means any pipe, pipeline, duct, wire line, conduit, pole, tower, equipment,
or other structure used for transmission, distribution, or delivery of electrical power,
light, heat, water, gas, sewer, telegraph, or telecommunication services.
Under current law, if a utility facility is within the right-of-way of a proposed
highway project, the Department of Transportation must notify the owner, who must
then provide DOT with a description and general location of each utility facility. DOT
must then provide the owner with a set of plans for the proposed project. The owner
must submit a work plan to DOT proposing any relocations or adjustments to utility
facilities required by the proposed project. DOT must review work plans for
compliance with permit requirements and, once approved, notify the owner when
utility facility relocation work may begin.
Under the bill, a contractor that incurs costs as a result of a utility relocation
delay may file a utility delay damages claim with the department. “Utility relocation
1
2
3
4
5 - 2 -2023 - 2024 Legislature LRB-2916/1
ZDW:klm
ASSEMBLY BILL 275
delay” means a change in operations of a contractor or the rescheduling of work by
a contractor that is caused by the uncompleted relocation or adjustment of a utility
facility located in the right-of way, regardless of whether the relocation or
adjustment of the utility facility is identified in a plan.
The bill requires DOT to notify the owner of the relevant utility facility upon
receipt of a damages claim. The owner may respond to the claim by providing
additional information related to the claim. DOT must consider all information
provided and, if DOT determines that a utility relocation delay occurred, must
compensate the contractor for costs incurred as a result.
Under the bill, if a utility relocation delay was caused by a utility facility
owner's failure to complete a relocation in accordance with an approved plan, the
utility facility owner is liable to DOT for any compensation paid to a contractor as
a result of a utility relocation delay. The owner must make payment to DOT within
60 days, subject to the right to appeal DOT's determination. If the owner fails to
make the required payment, DOT may seek remedy by filing a civil suit against the
owner.
The bill requires DOT to submit a report to the Joint Committee on Finance
within four years providing specified information about utility relocation damages
claims received by DOT. Within six months of receipt of the report, JFC must make
a recommendation as to whether the process created by the bill should be amended
or repealed.
For further information see the state fiscal estimate, which will be printed as
an appendix to this bill.
The people of the state of Wisconsin, represented in senate and assembly, do
enact as follows:
SECTION 1. 84.01 (31) of the statutes is amended to read:
84.01 (31) ACCOMMODATION OF UTILITY FACILITIES WITHIN HIGHWAY RIGHTS-OF-WAY.
Notwithstanding ss. 84.06 (4), 84.063, 84.065, and 84.093, the department may, upon
finding that it is feasible and advantageous to the state, negotiate and enter into an
agreement to accept any plant or equipment used for the conveyance, by wire, optics,
radio signal, or other means, of voice, data, or other information at any frequency
over any part of the electromagnetic spectrum, or to accept any services associated
with the collection, storage, forwarding, switching, and delivery incidental to such
communication, as payment for the accommodation of a utility facility, as defined in
s. 84.063 (1) (b) (f), within a highway right-of-way. Any agreement under this
1
2
3
4
5
6
7
8
9
10 - 3 -2023 - 2024 Legislature
LRB-2916/1
ZDW:klm
SECTION 1
ASSEMBLY BILL 275
subsection is exempt from ss. 16.70 to 16.75, 16.755 to 16.82, and 16.85 to 16.89, but
ss. 16.528, 16.752, and 16.754 apply to such agreement.
SECTION 2. 84.062 (1) (L) of the statutes is amended to read:
84.062 (1) (L) “Project” means a project involving a highway improvement, as
defined in s. 84.063 (1) (a) (d).
SECTION 3. 84.063 (1) (a) of the statutes is renumbered 84.063 (1) (d).
SECTION 4. 84.063 (1) (b) of the statutes is renumbered 84.063 (1) (f).
SECTION 5. 84.063 (1) (c) of the statutes is created to read:
84.063 (1) (c) “Contractor” means a person who is seeking or has entered into
a highway improvement contract with the department under s. 84.06.
SECTION 6. 84.063 (1) (e) of the statutes is created to read:
84.063 (1) (e) “Owner” means an owner of a utility facility.
SECTION 7. 84.063 (1) (g) of the statutes is created to read:
84.063 (1) (g) “Utility relocation delay” means a change in operations of a
contractor or the rescheduling of work by a contractor that is caused by the
uncompleted relocation or adjustment of a utility facility located in the right-of way,
regardless of whether the relocation or adjustment of the utility facility is identified
in a plan under sub. (3).
SECTION 8. 84.063 (4m) of the statutes is created to read:
84.063 (4m) UTILITY RELOCATION DELAY DAMAGES CLAIMS. (a) A contractor that
incurs costs as a result of a utility relocation delay may file a utility relocation delay
damages claim with the department.
(b) The department shall notify the owner of the relevant utility facility upon
receipt of a claim under par. (a). The owner may respond to the claim by providing
additional information related to the claim.
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25 - 4 -2023 - 2024 Legislature LRB-2916/1
ZDW:klm
SECTION 8 ASSEMBLY BILL 275
(c) The department shall consider all information provided by the contractor
under par. (a) and, if applicable, the owner under par. (b). If the department
determines that a utility relocation delay occurred, the department shall compensate
the contractor for costs incurred as a result of the utility relocation delay and may
not impose liquidated damages. The amount of compensation under this paragraph
shall be calculated and paid in accordance with the department's standard
specifications for compensable delays.
(d) 1. If a utility relocation delay identified under par. (c) was caused by an
owner's failure to complete a relocation in accordance with a work plan approved by
the department under sub. (3), the owner shall be liable to the department for
compensation paid to a contractor under par. (c). An owner shall not be liable under
this subdivision when the failure to complete a relocation is caused by circumstances
outside of the owner's reasonable control. The department may not assess against
the owner any fees, costs, or expenses in excess of the compensation paid under par.
(c). Subject to subd. 2., an owner shall make payment to the department no later than
60 days after receiving notice of the amount owed.
2. An owner may appeal the decision of the department under subd. 1. as
provided in s. 227.42 if the owner previously responded to the claim as provided in
par. (b). Any amount that the owner owes to the department under subd. 1. shall be
stayed pending the appeal.
3. If an owner fails to make payment of amounts owed to the department under
this paragraph, the department may seek remedy by filing a civil suit against the
owner.
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23 - 5 -2023 - 2024 Legislature
LRB-2916/1
ZDW:klm
SECTION 8
ASSEMBLY BILL 275
(e) The department may not consider amounts paid or owed under par. (d) when
making a determination on an owner's permit application, amounts paid to the
owner under par. (4) (a) or s. 84.09, or any other matter involving the owner.
SECTION 9. Trans 220.06 (7) (c) of the administrative code is amended to read:
Trans 220.06 (7) (c) If the owner fails to provide a work plan as provided in s.
Trans 220.05, or fails to complete the alteration or relocation of its facilities in
accordance with the work plan approved by the department as provided in s. Trans
220.05, the owner shall be liable to the contractor for all delay costs and liquidated
damages incurred by the contractor which are The department shall compensate the
contractor for any costs caused by or which grow out of failure of the owner to carry
out and complete its work in accordance with the approved work plan attributed to
a utility relocation delay as defined in s. 84.063 (1) (g), Stats., and may not impose
liquidated damages. The owner shall be liable, subject to the right to appeal the
decision of the department under s. 227.42, Stats., for compensation paid by the
department to a contractor under this paragraph for a utility relocation delay, as
defined in s. 84.063 (1) (g), Stats., that was caused by the owner's failure to complete
a relocation in accordance with the work plan approved by the department as
provided in s. Trans 220.05. The owner shall not be liable to the department for any
delay if the owner's failure to complete the relocation in accordance with the work
plan approved by the department was due to circumstances outside of the owner's
reasonable control.
SECTION 10.0Nonstatutory provisions.
(1) No later than the last day of the first month following the effective date of
this subsection, the department of transportation shall update its standard
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24 - 6 -2023 - 2024 Legislature LRB-2916/1
ZDW:klm
SECTION 10 ASSEMBLY BILL 275
specifications for compensable delays to conform with the requirements under s.
84.063 (4m).
(2) No later than 4 years after the effective date of this subsection, the
department of transportation shall submit a report to the joint committee on finance
detailing utility relocation damages claims received by the department, including
total claims received, claims denied, payments made to contractors, damages
recovered from owners, the length and impact of delays, and net expenditures by the
department. No later than 6 months after receipt of the report under this subsection,
the joint committee on finance shall make a recommendation to the legislature as to
whether s. 84.063 (4m) should be amended or repealed.
(END)
1
2
3
4
5
6
7
8
9
10
11